Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT.
B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate.
B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner.
B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment.
B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.
TEACHERS’ RIGHTS A. Pursuant to the Employer-Employee Relations Act, the Board and the Association agree that every member of the unit shall have the right freely to organize, join and support the Association and its affiliates for the purpose of engaging in collective negotiations and other concerted activities for mutual aid and protection, or to refrain from such activities. The Board and the Association undertake and agree that they shall not directly or indirectly discourage or deprive or coerce any teacher in the enjoyment of any rights conferred by the Employer-Employee Relations Act, or other laws of New Jersey or the constitutions of New Jersey or the United States.
B. Nothing contained herein shall be construed to deny or restrict to any teacher such rights as he/she may have under New Jersey School Laws or other applicable laws and regulations. The rights granted to teachers hereunder shall be deemed to be in addition to those provided elsewhere.
C. No teacher shall be disciplined, reprimanded or reduced in rank or compensation without just cause. Any such action asserted by the Board, or any agent or representative thereof, shall be subject to the grievance procedure herein set forth. For purposes of this provision, discharge, removal, or non-renewal shall not be considered as discipline, reprimand or reduction in rank or compensation.
D. Whenever any teacher is required to appear before any Administrator or Supervisor, the Superintendent, Board or any committee thereof for a meeting or conference, the purpose of which adversely concerns the continuance of that teacher in his/her office, position, or employment or adversely concerns salary or any increments pertaining thereto, he/she shall be given prior written notice of the reason for such meeting or conference and shall be entitled to have a representative of the Association present to advise and represent him/her during such meeting or conference, provided that no unreasonable delay shall be incurred in the scheduling of such meeting due to a lack of representation.
E. The Board shall provide a job description of co- curricular jobs for which compensation is provided. This description shall be prepared by the Board of Education in consultation with the Association.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Access Rights Upon reasonable notice and supervision by the Granting Party, and subject to any required or necessary regulatory approvals, either the Connecting Transmission Owner or Developer (“Granting Party”) shall furnish to the other of those two Parties (“Access Party”) at no cost any rights of use, licenses, rights of way and easements with respect to lands owned or controlled by the Granting Party, its agents (if allowed under the applicable agency agreement), or any Affiliate, that are necessary to enable the Access Party to obtain ingress and egress at the Point of Interconnection to construct, operate, maintain, repair, test (or witness testing), inspect, replace or remove facilities and equipment to: (i) interconnect the Large Generating Facility with the New York State Transmission System; (ii) operate and maintain the Large Generating Facility, the Attachment Facilities and the New York State Transmission System; and (iii) disconnect or remove the Access Party’s facilities and equipment upon termination of this Agreement. In exercising such licenses, rights of way and easements, the Access Party shall not unreasonably disrupt or interfere with normal operation of the Granting Party’s business and shall adhere to the safety rules and procedures established in advance, as may be changed from time to time, by the Granting Party and provided to the Access Party. The Access Party shall indemnify the Granting Party against all claims of injury or damage from third parties resulting from the exercise of the access rights provided for herein.
THE CONTRACTS (RIGHTS OF THIRD PARTIES ACT 1999
MANAGEMENT'S RIGHTS 3.01 The Employer’s rights include but are not limited to the following:
a) The right to maintain order, discipline and efficiency; to make, alter and enforce rules and regulations, policies and practices, to be adhered to by its employees; to discipline and discharge employees for just cause, provided however that probationary employees may be terminated without regard to cause within the probationary period and such probationary employees will not be entitled to have the benefit of the grievance procedure set out herein.
b) The right to select, hire and direct the workforce and employees; to transfer, assign, promote, demote, classify, layoff, recall and suspend employees; to select and retain employees for positions excluded from the bargaining unit; provided such actions are consistent with the further terms of this agreement.
c) The right to operate and manage the Employer’s business in order to satisfy its commitments and responsibilities. The right to determine the kind and location of business to be done by the Employer, the direction of the working forces, the scheduling of work, the number of shifts, the methods, processes and means by which work is to be performed, job content, quality and quantity standards, the right to use improved methods, machinery and equipment, the right to determine the number of employees needed by the Employer at any time and generally, the right to manage the business of the Employer, and to plan, direct and control the operations of the Employer, without interference.
3.02 The sole and exclusive jurisdiction over operations, building, machinery, and equipment shall be vested in the Employer.
3.03 The Employer may subcontract out work where:
a) he does not possess the necessary facilities or equipment
b) he does not have and/or cannot acquire the required manpower Work normally performed by members of the bargaining unit will not be subcontracted out if employees qualified to do the work are on layoff, or if employees qualified to do the work must be laid off, transferred, demoted or discharged as the result of the subcontracting out of work.
GRANTOR'S RIGHT TO POSSESSION AND TO COLLECT ACCOUNTS Until default and except as otherwise provided below with respect to accounts, Grantor may have possession of the tangible personal property and beneficial use of all the Collateral and may use it in any lawful manner not inconsistent with this Agreement or the Related Documents, provided that Grantor's right to possession and beneficial use shall not apply to any Collateral where possession of the Collateral by Lender is required by law to perfect Lender's security interest in such Collateral. Until otherwise notified by Lender, Grantor may collect any of the Collateral consisting of accounts. At any time and even though no Event of Default exists, Lender may exercise its rights to collect the accounts and to notify account debtors to make payments directly to Lender for application to the Indebtedness. If Lender at any time has possession of any Collateral, whether before or after an Event of Default, Lender shall be deemed to have exercised reasonable care in the custody and preservation of the Collateral if Lender takes such action for that purpose as Grantor shall request or as Lender, in Lender's sole discretion, shall deem appropriate under the circumstances, but failure to honor any request by Grantor shall not of itself be deemed to be a failure to exercise reasonable care. Lender shall not be required to take any steps necessary to preserve any rights in the Collateral against prior parties, nor to protect, preserve or maintain any security interest given to secure the Indebtedness.
Contracts (Rights of Third Parties ACT 1999
Contracts (Rights of Third Parties) Xxx 0000 No term of this Agreement is enforceable under the Contracts (Rights of Third Parties) Xxx 0000 by a person who is not a party to this Agreement.
