Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.
Modifications and Updates to the Wire Center List and Subsequent Transition Periods 5.4.6.1 In the event AT&T identifies additional wire centers that meet the criteria set forth in Sections 5.4.2.1 or 5.4.2.2 above, but that were not included in the Master List of Unimpaired Wire Centers or AT&T’s List of Unimpaired Wire Centers, AT&T shall include such additional wire centers in a CNL. Each such list of additional wire centers shall be considered a Subsequent Wire Center List. AT&T will follow any limitations on the frequency with which it may issue such lists and notification procedures set forth in applicable Commission orders.
5.4.6.2 TWTC shall have thirty (30) business days to dispute the additional wire centers listed on AT&T’s CNL. Absent such dispute, effective thirty (30) business days after the date of a AT&T CNL providing a Subsequent Wire Center List, AT&T shall not be required to provide DS1 and DS3 Dedicated Transport, as applicable, in such additional wire center(s), except pursuant to the self-certification process as set forth in Section 1.9.1 of this Attachment.
5.4.6.3 For purposes of Section 5.4.6.1 above, AT&T shall make available DS1 and DS3 Dedicated Transport that were in service for TWTC in a wire center on the Subsequent Wire Center List as of the thirtieth (30th) business day after the date of AT&T’s CNL identifying the Subsequent Wire Center List (Subsequent Embedded Base) until one hundred eighty (180) days after the thirtieth (30th) business day Version: 4Q06 Standard ICA 11/30/06 from the date of AT&T’s CNL identifying the Subsequent Wire Center List (Subsequent Transition Period).
5.4.6.4 The rates set forth in Exhibit B shall apply to the Subsequent Embedded Base during the Subsequent Transition Period.
5.4.6.5 No later than one hundred eighty (180) days from AT&T’s CNL identifying the Subsequent Wire Center List, TWTC shall submit an LSR(s) or spreadsheet(s) as applicable, identifying the Subsequent Embedded Base of circuits to be disconnected or converted to other AT&T services.
5.4.6.5.1 In the case of disconnection, the applicable disconnect charges set forth in this Agreement shall apply.
5.4.6.5.2 If TWTC chooses to convert DS1 and/or DS3 Dedicated Transport to special access circuits in existence as of the Effective Date of this Agreement, AT&T will include such DS1 and/or DS3 Dedicated Transport within TWTC’s total special access circuits, and apply any discounts to which TWTC is entitled from the transition period of 3/11/2006 to the conversion date. Conversions will be subject to the switch-as-is charge set forth in Exhibit A to this Attachment 2.
5.4.6.5.3 AT&T shall not impose disconnect or nonrecurring installation charges when transitioning the Subsequent Embedded Base of DS1 and DS3 Dedicated Transport in existence as of the Effective Date of this Agreement.
5.4.6.6 If TWTC fails to submit the LSR(s) or spreadsheet(s) for all of its Subsequent Embedded Base by one hundred eighty (180) days after the date of AT&T’s CNL identifying the Subsequent Wire Center List, AT&T will identify TWTC’s remaining Subsequent Embedded Base, if any, and will transition such circuits to the equivalent tariffed AT&T service(s), or in the case of Georgia, to the equivalent 271 service(s) set forth in Exhibit 1. In the states of Florida, Kentucky, Mississippi and South Carolina, those circuits identified and transitioned by AT&T shall be subject to the applicable disconnect charges as set forth in this Agreement and the full nonrecurring charges for installation of the equivalent tariffed AT&T service as set forth in AT&T’s tariffs. In the states of Alabama, Georgia, North Carolina and Tennessee, those circuits identified and transitioned by AT&T shall be subject to the applicable switch-as-is rates set forth in Exhibit A of Attachment
Contractor Sales Reporting Vendor Management Fee Contractor Reports Cooperative Master Contract Sales Reporting. Contractor shall report total Cooperative Master Contract sales quarterly to Enterprise Services, as set forth below. Cooperative Master Contract Sales Reporting System. Contractor shall report quarterly Cooperative Master Contract sales in Enterprise Services’ Cooperative Master Contract Sales Reporting System. Enterprise Services will provide Contractor with a login password and a vendor number. The password and vendor number will be provided to the Sales Reporting Representative(s) listed on Contractor’s Bidder Profile. Data. Each sales report must identify every authorized Purchaser by name as it is known to Enterprise Services and its total combined sales amount invoiced during the reporting period (i.e., sales of an entire agency or political subdivision, not its individual subsections). The “Miscellaneous” option may be used only with prior approval by Enterprise Services. Upon request, Contractor shall provide contact information for all authorized Purchasers specified herein during the term of the Cooperative Master Contract. If there are no Cooperative Master Contract sales during the reporting period, Contractor must report zero sales. Due dates for Cooperative Master Contract Sales Reporting. Quarterly Cooperative Master Contract Sales Reports must be submitted electronically by the following deadlines for all Cooperative Master Contract sales invoiced during the applicable calendar quarter: Vendor Management Fee. Contractor shall pay to Enterprise Services a vendor management fee (“VMF”) of 1.5 percent on the purchase price for all Cooperative Master Contract sales (the purchase price is the total invoice price less applicable sales tax). The sum owed by Contractor to Enterprise Services as a result of the VMF is calculated as follows: Amount owed to Enterprise Services = Total Cooperative Master Contract sales invoiced (not including sales tax) x .015. The VMF must be rolled into Contractor’s current pricing. The VMF must not be shown as a separate line item on any invoice unless specifically requested and approved by Enterprise Services. Enterprise Services will invoice Contractor quarterly based on Cooperative Master Contract sales reported by Contractor. Contractor is not to remit payment until Contractor receives an invoice from Enterprise Services. Contractor’s VMF payment to Enterprise Services must reference this Cooperative Master Contract number, the year and quarter for which the VMF is being remitted, and Contractor’s name as set forth in this Cooperative Master Contract, if not already included on the face of the check. Contractor’s failure to report accurate total net Cooperative Master Contract sales, to submit a timely Cooperative Master Contract sales report, or to remit timely payment of the VMF to Enterprise Services, may be cause for Enterprise Services to suspend Contractor or terminate this Cooperative Master Contract or exercise remedies provided by law. Without limiting any other available remedies, the parties agree that Contractor’s failure to remit to Enterprise Services timely payment of the VMF shall obligate Contractor to pay to Enterprise Services, to offset the administrative and transaction costs incurred by the State to identify, process, and collect such sums, the sum of $200.00 or twenty-five percent (25%) of the outstanding amount, whichever is greater, or the maximum allowed by law, if less. Enterprise Services reserves the right, upon thirty (30) calendar days advance written notice, to increase, reduce, or eliminate the VMF for subsequent purchases, and reserves the right to renegotiate Cooperative Master Contract pricing with Contractor when any subsequent adjustment of the VMF might justify a change in pricing. Annual Cooperative Master Contract Sales Report. Contractor shall provide to Enterprise Services a detailed annual Cooperative Master Contract sales report. Such report shall include, at a minimum: the Goods/Services sold (including, as applicable, item number or other identifier), per unit quantities sold, items and volumes purchased by Purchaser, shipment/delivery locations by Purchaser, and Cooperative Master Contract price. This report must be provided in an electronic format that can be read by Microsoft (MS) Excel. Such report is due within thirty (30) calendar days of the annual anniversary of the effective date of this Cooperative Master Contract.
Quarterly Contractor Performance Reporting Customers shall complete a Contractor Performance Survey (Exhibit I) for each Contractor on a Quarterly basis. Customers will electronically submit the completed Contractor Performance Survey(s) to the Department Contract Manager no later than the due date indicated in Contract Exhibit D, Section 17, Additional Special Contract Conditions. The completed Contractor Performance Survey(s) will be used by the Department as a performance-reporting tool to measure the performance of Contractors. The Department reserves the right to modify the Contractor Performance Survey document and introduce additional performance-reporting tools as they are developed, including online tools (e.g. tools within MyFloridaMarketPlace or on the Department's website).
Recovery Schedule If the initial schedule or any current updates fail to reflect the Work’s actual plan or method of operation, or a contractual milestone date is more than fifteen (15) days behind, Owner may require that a recovery schedule for completion of the remaining Work be submitted. The Recovery Schedule must be submitted within seven (7) calendar days of Owner’s request. The Recovery Schedule shall describe in detail Construction Contractor’s plan to complete the remaining Work by the required Contract milestone date. The Recovery Schedule submitted shall meet the same requirements as the original Construction Schedule. The narrative submitted with the Recovery Schedule should describe in detail all changes that have been made to meet the Contract milestone dates.
Contract Quarterly Sales Reports The Contractor shall submit complete Quarterly Sales Reports to the Department’s Contract Manager within 30 calendar days after the close of each State fiscal quarter (the State’s fiscal quarters close on September 30, December 31, March 31, and June 30). Reports must be submitted in MS Excel using the DMS Quarterly Sales Report Format, which can be accessed at xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/ state_purchasing/vendor_resources/quarterly_sales_report_format. Initiation and submission of the most recent version of the Quarterly Sales Report posted on the DMS website is the responsibility of the Contractor without prompting or notification from the Department’s Contract Manager. If no orders are received during the quarter, the Contractor must email the DMS Contract Manager confirming there was no activity.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Project/Milestones Taxpayer is a food producer and full line grocery store chain, proposing to expand its in- house food manufacturing. In consideration for the Credit, Taxpayer agrees to maintain at least 44 full-time employees, determined on an annual full-time equivalent basis, at its Merced food manufacturing facility; and, to hire full-time employees and invest in a research and development equipment, manufacturing equipment, tenant improvements, and a facility as part of its expansion in Merced and/or Riverside, California (collectively, the “Project”). Taxpayer agrees that for the purposes of satisfying the milestones in Exhibit A (“Milestones”), Taxpayer will only count jobs and investment at its Merced food manufacturing facility and/or a new food manufacturing facility in Riverside, and that no other jobs or investment at any retail or other facility can be counted. For the purposes of calculating the number of full-time employees, no employee transferred from another affiliate, facility, or entity owned, related to, or controlled by the Taxpayer shall be included in the calculation. Taxpayer shall not be entitled to any portion of the Credit if it fails to maintain at least 44 full-time employees, determined on an annual full-time equivalent basis, at its Merced facility for the entire duration of the agreement. Further, Taxpayer agrees to satisfy the Milestones and must maintain Milestones for a minimum of three (3) taxable years thereafter. In the event Taxpayer employs more than the number of full- time employees, determined on an annual full-time equivalent basis, than required in Exhibit A, for purposes of satisfying the “Minimum Annual Wage of California Full-time Employees Hired” and the “Cumulative Average Annual Wage of California Full-time Employees Hired,” Taxpayer may use the wages of any of the full-time employees hired within the required time period. For purposes of calculating the “Minimum Annual Wage of California Full-time Employees Hired” and the “Cumulative Average Annual Wage of California Full-time
SCHEDULE AND MILESTONES The Parties shall execute one (1) Annex concurrently with this Umbrella Agreement. The initial Annex and any subsequent Annexes will be performed on the schedule and in accordance with the milestones set forth in each respective Annex.
