DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS REQUIREMENTS/ STATEMENTS OF WORK
Benchmarks for Measuring Accessibility For the purposes of this Agreement, the accessibility of online content and functionality will be measured according to the W3C’s Web Content Accessibility Guidelines (WCAG) 2.0 Level AA and the Web Accessibility Initiative Accessible Rich Internet Applications Suite (WAI-ARIA) 1.0 for web content, which are incorporated by reference.
Evaluation, Testing, and Monitoring 1. The System Agency may review, test, evaluate and monitor Grantee’s Products and services, as well as associated documentation and technical support for compliance with the Accessibility Standards. Review, testing, evaluation and monitoring may be conducted before and after the award of a contract. Testing and monitoring may include user acceptance testing. Neither the review, testing (including acceptance testing), evaluation or monitoring of any Product or service, nor the absence of review, testing, evaluation or monitoring, will result in a waiver of the State’s right to contest the Grantee’s assertion of compliance with the Accessibility Standards. 2. Grantee agrees to cooperate fully and provide the System Agency and its representatives timely access to Products, records, and other items and information needed to conduct such review, evaluation, testing, and monitoring.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Penalties for Non-compliance to Service Level Agreement Where the Supplier/Service Provider fails to deliver the Goods/Services within the agreed and accepted milestone timelines and provided that the cause of the delay was not due to a fault of Transnet, penalties shall be imposed at …………………………………………………… .
Operation and Maintenance Manuals Receipts for transmittal of Operation and Maintenance Manuals, Brochures and Data to the Design Professional (or Commissioning Agent) as required by Section 6.1.1.5.
Program Monitoring and Evaluation The Recipient shall prepare, or cause to be prepared, and furnish to the Association not later than six months after the Closing Date, a report of such scope and in such detail as the Association shall reasonably request, on the execution of the Program, the performance by the Recipient and the Association of their respective obligations under the Legal Agreements and the accomplishment of the purposes of the Financing.”
Research Analyst Independence The Company acknowledges that the Underwriters’ research analysts and research departments are required to be independent from their respective investment banking divisions and are subject to certain regulations and internal policies, and that such Underwriters’ research analysts may hold views and make statements or investment recommendations and/or publish research reports with respect to the Company and/or the offering that differ from the views of their respective investment banking divisions. The Company hereby waives and releases, to the fullest extent permitted by law, any claims that the Company may have against the Underwriters with respect to any conflict of interest that may arise from the fact that the views expressed by their independent research analysts and research departments may be different from or inconsistent with the views or advice communicated to the Company by such Underwriters’ investment banking divisions. The Company acknowledges that each of the Underwriters is a full service securities firm and as such from time to time, subject to applicable securities laws, may effect transactions for its own account or the account of its customers and hold long or short positions in debt or equity securities of the companies that may be the subject of the transactions contemplated by this Agreement.
Tests, Labs, and Imaging and X rays (diagnostic)
Project Monitoring Reporting and Evaluation The Recipient shall furnish to the Association each Project Report not later than forty-five (45) days after the end of each calendar semester, covering the calendar semester.
