RECONSTRUCTION OF THE CHARGEE, CHARGOR AND SECURITY PARTY Sample Clauses

RECONSTRUCTION OF THE CHARGEE, CHARGOR AND SECURITY PARTY. (a) The security, liabilities and/or obligations created by this Charge shall continue to be valid and binding for all purposes whatsoever notwithstanding any change by amalgamation, merger, acquisition, restructuring, reconstruction, take-over, dissolution, revocation or otherwise which may be made in the constitution of the Chargee or any of any company by which the business of the Chargee may for the time being be carried on and shall be available to the company carrying on that business for the time being (b) The security, liabilities and/or obligations created by this Charge shall continue to be valid and binding for all purposes whatsoever notwithstanding any change whether by reason of bankruptcy, death, insanity or otherwise howsoever in the name, style or composition of the Chargor and notwithstanding any change in the name of the Chargor, and the expression “the Chargor” in this Charge includes the person for the time being deriving title form the Chargor and it is expressly declared that no change whatsoever in relation to or affecting the Chargee or the Chargor, or both, shall in any way affect the security, liabilities and/or obligations created hereunder in relation to any transaction whatsoever whether past present or future.
Sample 1
AutoNDA by SimpleDocs

Related to RECONSTRUCTION OF THE CHARGEE, CHARGOR AND SECURITY PARTY

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • GRANTOR'S RIGHT TO POSSESSION AND TO COLLECT ACCOUNTS Until default and except as otherwise provided below with respect to accounts, Grantor may have possession of the tangible personal property and beneficial use of all the Collateral and may use it in any lawful manner not inconsistent with this Agreement or the Related Documents, provided that Grantor's right to possession and beneficial use shall not apply to any Collateral where possession of the Collateral by Lender is required by law to perfect Lender's security interest in such Collateral. Until otherwise notified by Lender, Grantor may collect any of the Collateral consisting of accounts. At any time and even though no Event of Default exists, Lender may exercise its rights to collect the accounts and to notify account debtors to make payments directly to Lender for application to the Indebtedness. If Lender at any time has possession of any Collateral, whether before or after an Event of Default, Lender shall be deemed to have exercised reasonable care in the custody and preservation of the Collateral if Lender takes such action for that purpose as Grantor shall request or as Lender, in Lender's sole discretion, shall deem appropriate under the circumstances, but failure to honor any request by Grantor shall not of itself be deemed to be a failure to exercise reasonable care. Lender shall not be required to take any steps necessary to preserve any rights in the Collateral against prior parties, nor to protect, preserve or maintain any security interest given to secure the Indebtedness.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

  • Construction or Rehabilitation of Mortgaged Property No Mortgage Loan was made in connection with the construction or rehabilitation of a Mortgaged Property or facilitating the trade-in or exchange of a Mortgaged Property;

  • Transfer Upon Realization of Pledged, Mortgaged or Charged Escrow Securities (1) You may transfer within escrow to a financial institution the escrow securities you have pledged, mortgaged or charged under section 4.2 to that financial institution as collateral for a loan on realization of the loan. (2) Prior to the transfer the Escrow Agent must receive: (a) a statutory declaration of an officer of the financial institution that the financial institution is legally entitled to the escrow securities; (b) a transfer power of attorney, executed by the transferor in accordance with the requirements of the Issuer’s transfer agent; and (c) an acknowledgement in the form of Schedule “B” signed by the financial institution. (3) Within 10 days after the transfer, the transferee of the escrow securities will file a copy of the acknowledgment with the securities regulators in the jurisdictions in which the Issuer is a reporting issuer.

  • Routine Maintenance, Construction, and Repair The NYISO or Connecting Transmission Owner may interrupt interconnection service or curtail the output of the Small Generating Facility and temporarily disconnect the Small Generating Facility from the New York State Transmission System or Distribution System when necessary for routine maintenance, construction, and repairs on the New York State Transmission System or Distribution System. The NYISO or the Connecting Transmission Owner shall provide the Interconnection Customer with five Business Days notice prior to such interruption. The NYISO and Connecting Transmission Owner shall use Reasonable Efforts to coordinate such reduction or temporary disconnection with the Interconnection Customer.

  • Compromises and Collection of Collateral The Grantors and the Administrative Agent recognize that setoffs, counterclaims, defenses and other claims may be asserted by obligors with respect to certain of the Receivables, that certain of the Receivables may be or become uncollectible in whole or in part and that the expense and probability of success in litigating a disputed Receivable may exceed the amount that reasonably may be expected to be recovered with respect to a Receivable. In view of the foregoing, each Grantor agrees that the Administrative Agent may at any time and from time to time, if an Event of Default has occurred and is continuing, compromise with the obligor on any Receivable, accept in full payment of any Receivable such amount as the Administrative Agent in its sole discretion shall determine or abandon any Receivable, and any such action by the Administrative Agent shall be commercially reasonable so long as the Administrative Agent acts in good faith based on information known to it at the time it takes any such action.

  • Maintenance of PMI Policy and/or LPMI Policy; Claims The Servicer shall comply with all provisions of applicable state and federal law relating to the cancellation of, or collection of premiums with respect to, PMI Policies, including, but not limited to, the provisions of the Homeowners Protection Act of 1998, and all regulations promulgated thereunder, as amended from time to time. With respect to each Mortgage Loan (other than LPMI Loans) with a loan to value ratio at origination in excess of 80%, the Servicer shall maintain or cause the Mortgagor to maintain (to the extent that the Mortgage Loan requires the Mortgagor to maintain such insurance) in full force and effect a PMI Policy, and shall pay or shall cause the Mortgagor to pay the premium thereon on a timely basis, until the LTV of such Mortgage Loan is reduced to 80%. In the event that such PMI Policy shall be terminated, the Servicer shall obtain from another Qualified Insurer a comparable replacement policy, with a total coverage equal to the remaining coverage of such terminated PMI Policy, at substantially the same fee level. The Servicer shall not take any action which would result in noncoverage under any applicable PMI Policy of any loss which, but for the actions of the Servicer would have been covered thereunder. In connection with any assumption or substitution agreements entered into or to be entered into with respect to a Mortgage Loan, the Servicer shall promptly notify the insurer under the related PMI Policy, if any, of such assumption or substitution of liability in accordance with the terms of such PMI Policy and shall take all actions which may be required by such insurer as a condition to the continuation of coverage under such PMI Policy. If such PMI Policy is terminated as a result of such assumption or substitution of liability, the Servicer shall obtain a replacement PMI Policy as provided above. The Servicer shall take all such actions as are necessary to service, maintain and administer the LPMI Loans in accordance with the LPMI Policy and to perform and enforce the rights of the insured under such LPMI Policy. Except as expressly set forth herein, the Servicer shall have full authority on behalf of the Trust Fund to do anything it reasonably deems appropriate or desirable in connection with the servicing, maintenance and administration of the LPMI Policy. The Servicer shall not modify or assume a Mortgage Loan covered by the LPMI Policy or take any other action with respect to such Mortgage Loan which would result in non-coverage under the LPMI Policy of any loss which, but for the actions of the Servicer, would have been covered thereunder. If the LPMI Insurer fails to pay a claim under the LPMI Policy as a result of breach by the Servicer of its obligations hereunder or under the LPMI Policy, the Servicer shall be required to deposit in the Custodial Account on or prior to the next succeeding Remittance Date an amount equal to such unpaid claim from its own funds without any right to reimbursement from the Trust Fund. The Servicer shall cooperate with the LPMI Insurer and the Master Servicer and shall use its best efforts to furnish all reasonable aid, evidence and information in the possession of the Servicer to which the Servicer has access with respect to any LPMI Loan; provided, however, notwithstanding anything to the contrary contained in any LPMI Policy, the Servicer shall not be required to submit any reports to the LPMI Insurer until a reporting date that is at least 15 days after the Servicer has received sufficient loan level information from the Seller, the Master Servicer or the LPMI Insurer to appropriately code its servicing system in accordance with the LPMI Insurer’s requirements. In connection with its activities as servicer, the Servicer agrees to prepare and present, on behalf of itself and the Trustee, claims to the insurer under any PMI Policy or LPMI Policy in a timely fashion in accordance with the terms of such PMI Policy or LPMI Policy and, in this regard, to take such action as shall be necessary to permit recovery under any PMI Policy or LPMI Policy respecting a defaulted Mortgage Loan. Any amounts collected by the Servicer under any PMI Policy or LPMI Policy shall be deposited in the Custodial Account, subject to withdrawal pursuant to Section 3.04.

  • CONSTRUCTION OF PREMISES A. Lessor agrees that it will supply, at its own expense, its standard office space, as more particularly described and set forth on Exhibit “B” annexed hereto and made a part hereof (“Lessor’s Work”). /s/ Lessor /s/ Lessee B. Lessee agrees to perform, at its own cost and expense, all work other than Lessor’s Work, including without limitation that work, as particularly described in Exhibit “E” annexed hereto (“Lessee’s Work”), which is necessary to make the Premises conform with Lessee’s plans as approved by Lessor. Within thirty (30) days after the execution of this Lease, Lessee shall furnish to Lessor, for Lessor’s written approval, plans and specifications for the Lessee’s Work, showing a layout, lighting plan, fixturing plan, interior finish and material samples, and any work or equipment to be done or installed by Lessee affecting any structural, mechanical or electrical part of the Premises or the Building. Failure to provide same within said thirty (30) day period shall constitute a default by Lessee under this Lease. Lessor’s failure to disapprove of Lessee’s plans within fifteen (15) days of receipt shall constitute acceptance by Lessor of such plans. Design elements as aforesaid will be displayed in color renderings in such detail as may be sufficient for Lessor’s needs. It is the purpose of this requirement that Lessee’s Premises be fixtured, designed and laid out so as not to be a detriment to the other tenants in the Building and that Lessee’s Work shall not be detrimental to the Building or other tenants therein, and Lessor’s approval of the plans and specifications as aforesaid for Lessee’s Work shall be at the Lessor’s sole discretion. Lessee agrees and acknowledges that all Lessee’s Work, improvements, alterations or additions performed by Lessee (hereinafter collectively “Alterations”) whether pursuant to this Section or otherwise, shall be carried out in compliance with all Requirements and is performed and accomplished solely for the benefit and convenience of Lessee, and not for the benefit of Lessor, such Alterations being nevertheless subject to each and every of the provisions of this Lease,.

  • Maintenance of PMI Policy; Claims With respect to each Mortgage Loan with a loan-to-value ratio in excess of 80% for which a PMI Policy is both required and has been issued, the Servicer shall, to the extent permitted by Accepted Servicing Practices, maintain or cause the Mortgagor to maintain in full force and effect a PMI Policy insuring that portion of the Mortgage Loan in excess of 75% of value, and shall cause the Mortgagor to pay the premium thereon on a timely basis, until the loan-to-value ratio of such Mortgage Loan is reduced to 80% or PMI can otherwise no longer be mandated pursuant to applicable law. In the event that such PMI Policy shall be terminated, the Servicer shall attempt to obtain from another Qualified Insurer a comparable replacement policy, with a total coverage equal to the remaining coverage of such terminated PMI Policy. The Servicer shall not take any action which would result in noncoverage under any applicable PMI Policy of any loss which, but for the actions of the Servicer would have been covered thereunder. In connection with any assumption or substitution agreement entered into or to be entered into pursuant to this Agreement, the Servicer shall promptly notify the insurer under the related PMI Policy, if any, of such assumption or substitution of liability in accordance with the terms of such PMI Policy and shall take all actions which may be required by such insurer as a condition to the continuation of coverage under such PMI Policy. If such PMI Policy is terminated as a result of such assumption or substitution of liability, the Servicer shall obtain a replacement PMI Policy as provided above. With respect to each Mortgage Loan covered by a PMI Policy or LPMI Policy, the Servicer shall take all such actions on behalf of the Owner as are necessary to service, maintain and administer the related Mortgage Loan in accordance with such Policy and to enforce the rights under such Policy. Except as expressly set forth herein, the Servicer shall have full authority on behalf of the Owner to do anything it deems appropriate or desirable in connection with the servicing, maintenance and administration of such Policy; provided that the Servicer shall not take any action to permit any modification or assumption of a Mortgage Loan covered by a LPMI or PMI Policy, or take any other action with respect to such Mortgage Loan, which would result in non-coverage under such Policy of any loss which, but for actions of the Servicer, would have been covered thereunder. The Servicer shall cooperate with the PMI insurers and shall furnish all reasonable evidence and information in the possession of the Servicer to which the Servicer has access with respect to the related Mortgage Loan. The Servicer agrees to prepare and present, on behalf of itself and the Owner, claims to the insurer under any PMI Policy or LPMI Policy in a timely fashion in accordance with the terms of such PMI Policy or LPMI Policy and, in this regard, to take such action as shall be necessary to permit recovery under any PMI Policy or LPMI Policy respecting a defaulted Mortgage Loan. Pursuant to Section 3.04, any amounts collected by the Servicer under any PMI Policy or LPMI Policy shall be deposited in the Collection Account, subject to withdrawal pursuant to Section 3.05.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!