Compliance with Certain Requirements of Regulations; Deficit Capital Accounts In the event the Company is “liquidated” within the meaning of Regulations Section 1.704-1(b)(2)(ii)(g), distributions shall be made pursuant to this Article X to the Unit Holders who have positive Capital Accounts in compliance with Regulations Section 1.704-1(b)(2)(ii)(b)(2). If any Unit Holder has a deficit balance in such Member’s Capital Account (after giving effect to all contributions, distributions and allocations for all Fiscal Years, including the Fiscal Year during which such liquidation occurs), such Unit Holder shall have no obligation to make any contribution to the capital of the Company with respect to such deficit, and such deficit shall not be considered a debt owed to the Company or to any other Person for any purpose whatsoever. In the discretion of the Liquidator, a pro rata portion of the distributions that would otherwise be made to the Unit Holders pursuant to this Article X may be: (i) distributed to a trust established for the benefit of the Unit Holders for the purposes of liquidating Company assets, collecting amounts owed to the Company, and paying any contingent or unforeseen liabilities or obligations of the Company, in which case the assets of any such trust shall be distributed to the Unit Holders from time to time, in the reasonable discretion of the Liquidator, in the same proportions as the amount distributed to such trust by the Company would otherwise have been distributed to the Unit Holders pursuant to Section 10.2 of this Agreement; or (b) withheld to provide a reasonable reserve for Company liabilities (contingent or otherwise) and to reflect the unrealized portion of any installment obligations owed to the Company, provided that such withheld amounts shall be distributed to the Unit Holders as soon as practicable.
Performance of Services in Accordance with Regulatory Requirements; Furnishing of Books and Records In performing the services set forth in this Agreement, the Manager: A. shall conform with the 1940 Act and all rules and regulations thereunder, with all other applicable federal, state and foreign laws and regulations, with any applicable procedures adopted by the Trust’s Board of Trustees, and with the provisions of the Trust’s Registration Statement filed on Form N-1A as supplemented or amended from time to time; B. will make available to the Trust, promptly upon request, any of the Fund’s books and records as are maintained under this Agreement, and will furnish to regulatory authorities having the requisite authority any such books and records and any information or reports in connection with the Manager’s services under this Agreement that may be requested in order to ascertain whether the operations of the Trust are being conducted in a manner consistent with applicable laws and regulations.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
Regulation RR Risk Retention Ford Credit, as Sponsor, and the Depositor agree that (i) Ford Credit will cause the Depositor to, and the Depositor will, retain the Residual Interest on the Closing Date and (ii) Ford Credit will not permit the Depositor to, and the Depositor will not, sell, transfer, finance or hedge the Residual Interest except as permitted by Regulation RR.
COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS The Contractor, it’s Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor’s obligations under this paragraph.
FEDERAL ACQUISITION REGULATION CONTRACT CLAUSES 52.246-02 INSPECTION OF SUPPLIES -- FIXED-PRICE (AUG 1996) 52.246-02 INSPECTION OF SUPPLIES -- FIXED-PRICE (AUG 1996) - ALTERNATE I (JUL 1985) 52.246-02 INSPECTION OF SUPPLIES -- FIXED-PRICE (AUG 1996) - ALTERNATE II (JUL 1985) 52.246-03 INSPECTION OF SUPPLIES -- COST-REIMBURSEMENT (MAY 2001) 52.246-04 INSPECTION OF SERVICES -- FIXED-PRICE (AUG 1996) 52.246-05 INSPECTION OF SERVICES -- COST-REIMBURSEMENT (APR 1984) 52.246-06 INSPECTION -- TIME-AND-MATERIAL AND LABOR-HOUR (MAY 2001) 52.246-06 INSPECTION -- TIME-AND-MATERIAL AND LABOR-HOUR (MAY 2001) - ALTERNATE I (APR 1984) 52.246-15 CERTIFICATE OF CONFORMANCE (APR 1984) 52.246-16 RESPONSIBILITY FOR SUPPLIES (APR 1984)
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Compliance with Record Keeping Requirements Participating Dealer agrees to comply with the record keeping requirements of the Exchange Act, including but not limited to, Rules 17a-3 and 17a-4 promulgated under the Exchange Act. Participating Dealer further agrees to keep such records with respect to each customer who purchases Primary Shares, his suitability and the amount of Primary Shares sold, and to retain such records for such period of time as may be required by the Commission, any state securities commission, FINRA or the Company.
How Are Distributions from a Xxxx XXX Taxed for Federal Income Tax Purposes Amounts distributed to you are generally excludable from your gross income if they (i) are paid after you attain age 59½, (ii) are made to your beneficiary after your death, (iii) are attributable to your becoming disabled, (iv) subject to various limits, the distribution is used to purchase a first home or, in limited cases, a second or subsequent home for you, your spouse, or you or your spouse’s grandchild or ancestor, or (v) are rolled over to another Xxxx XXX. Regardless of the foregoing, if you or your beneficiary receives a distribution within the five-taxable-year period starting with the beginning of the year to which your initial contribution to your Xxxx XXX applies, the earnings on your account are includable in taxable income. In addition, if you roll over (convert) funds to your Xxxx XXX from another individual retirement plan (such as a Traditional IRA or another Xxxx XXX into which amounts were rolled from a Traditional IRA), the portion of a distribution attributable to rolled-over amounts which exceeds the amounts taxed in connection with the conversion to a Xxxx XXX is includable in income (and subject to penalty tax) if it is distributed prior to the end of the five-tax-year period beginning with the start of the tax year during which the rollover occurred. An amount taxed in connection with a rollover is subject to a 10% penalty tax if it is distributed before the end of the five-tax-year period. As noted above, the five-year holding period requirement is measured from the beginning of the five-taxable-year period beginning with the first taxable year for which you (or your spouse) made a contribution to a Xxxx XXX on your behalf. Previously, the law required that a separate five-year holding period apply to regular Xxxx XXX contributions and to amounts contributed to a Xxxx XXX as a result of the rollover or conversion of a Traditional IRA. Even though the holding period requirement has been simplified, it may still be advisable to keep regular Xxxx XXX contributions and rollover/ conversion Xxxx XXX contributions in separate accounts. This is because amounts withdrawn from a rollover/conversion Xxxx XXX within five years of the rollover/conversion may be subject to a 10% penalty tax. As noted above, a distribution from a Xxxx XXX that complies with all of the distribution and holding period requirements is excludable from your gross income. If you receive a distribution from a Xxxx XXX that does not comply with these rules, the part of the distribution that constitutes a return of your contributions will not be included in your taxable income, and the portion that represents earnings will be includable in your income. For this purpose, certain ordering rules apply. Amounts distributed to you are treated as coming first from your non-deductible contributions. The next portion of a distribution is treated as coming from amounts which have been rolled over (converted) from any non-Xxxx IRAs in the order such amounts were rolled over. Any remaining amounts (including all earnings) are distributed last. Any portion of your distribution which does not meet the criteria for exclusion from gross income may also be subject to a 10% penalty tax. Note that to the extent a distribution would be taxable to you, neither you nor anyone else can qualify for capital gains treatment for amounts distributed from your account. Similarly, you are not entitled to the special five- or ten- year averaging rule for lump-sum distributions that may be available to persons receiving distributions from certain other types of retirement plans. Rather, the taxable portion of any distribution is taxed to you as ordinary income. Your Xxxx XXX is not subject to taxes on excess distributions or on excess amounts remaining in your account as of your date of death. You must indicate on your distribution request whether federal income taxes should be withheld on a distribution from a Xxxx XXX. If you do not make a withholding election, we will not withhold federal or state income tax. Note that, for federal tax purposes (for example, for purposes of applying the ordering rules described above), Xxxx IRAs are considered separately from Traditional IRAs.
DEFENSE FEDERAL ACQUISITION REGULATION SUPPLEMENT CONTRACT CLAUSES 252.246-7000 MATERIAL INSPECTION AND RECEIVING REPORT (MAR 2008)
