Remedies Against Contractors, etc Sample Clauses

Remedies Against Contractors, etc. If any vendor, contractor or subcontractor shall default under any contract or purchase order in connection with the acquisition or construction of the Bond-Financed Facilities, the Board shall follow the written instructions of, and shall cooperate in good faith with, the Corporation in the pursuit of any remedies that may be available under the circumstances. Upon the written request of the Corporation, the Board shall assign to the Corporation all rights of the Board under any such contract or purchase order and the Corporation may, in its own name or in the name of the Board, pursue any such remedies.
AutoNDA by SimpleDocs
Remedies Against Contractors, etc. If the Contractor, the Project Architect or any vendor or Subcontractor shall default under any contract or purchase order with Borrower in connection with the construction of the Project, the Borrower shall pursue any remedies that may be available under the circumstances, including, without limitation, pursuit under the Payment and Performance Bonds,
Remedies Against Contractors, etc. If any vendor, contractor or subcontractor shall default under any contract or purchase order in connection with the acquisition or construction of the Bond-Financed Facilities, the Issuer shall follow the written instructions of, and shall cooperate in good faith with, the Corporation in the pursuit of any remedies that may be available under the circumstances. Upon the written request of the Corporation, the Issuer shall assign to the Corporation all rights of the Issuer under any such contract or purchase order and the Corporation may, in its own name or in the name of the Issuer, pursue any such remedies.
Remedies Against Contractors, etc. If any vendor, contractor or subcontractor shall default under any contract or purchase order in connection with the acquisition, construction, rehabilitation, installation or equipping of the Project, the Issuer shall follow the written instructions of, and shall cooperate in good faith with, the Lessee in the pursuit of any remedies that may be available under the circumstances. Upon the written request of the Lessee, the Issuer shall assign to the Lessee all rights of the Issuer under any such contract or purchase order and the Lessee may, in its own name or in the name of the Issuer, pursue any such remedies.

Related to Remedies Against Contractors, etc

  • Governing Law; No Construction Against Drafter This Agreement shall be deemed to be made in the State of Delaware, and the validity, interpretation, construction, and performance of this Agreement in all respects shall be governed by the laws of the State of Delaware without regard to its principles of conflicts of law. No provision of this Agreement or any related document will be construed against or interpreted to the disadvantage of any party hereto by any court or other governmental or judicial authority by reason of such party having or being deemed to have structured or drafted such provision.

  • Laws Applicable to Construction; Consent to Jurisdiction The interpretation, performance and enforcement of this Agreement shall be governed by the laws of the State of Delaware without reference to principles of conflict of laws, as applied to contracts executed in and performed wholly within the State of Delaware. In addition to the terms and conditions set forth in this Agreement, the Restricted Stock Units are subject to the terms and conditions of the Plan, which is hereby incorporated by reference.

  • REMEDIES, ETC CUMULATIVE. Each and every right, power and remedy of the Pledgee provided for in this Agreement or in any other Secured Debt Agreement, or now or hereafter existing at law or in equity or by statute shall be cumulative and concurrent and shall be in addition to every other such right, power or remedy. The exercise or beginning of the exercise by the Pledgee or any other Secured Creditor of any one or more of the rights, powers or remedies provided for in this Agreement or any other Secured Debt Agreement or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Pledgee or any other Secured Creditor of all such other rights, powers or remedies, and no failure or delay on the part of the Pledgee or any other Secured Creditor to exercise any such right, power or remedy shall operate as a waiver thereof. No notice to or demand on any Pledgor in any case shall entitle it to any other or further notice or demand in similar or other circumstances or constitute a waiver of any of the rights of the Pledgee or any other Secured Creditor to any other or further action in any circumstances without notice or demand. The Secured Creditors agree that this Agreement may be enforced only by the action of the Administrative Agent or the Pledgee, in each case acting upon the instructions of the Required Lenders (or, after the date on which all Credit Document Obligations have been paid in full, the holders of at least the majority of the outstanding Other Obligations) and that no other Secured Creditor shall have any right individually to seek to enforce or to enforce this Agreement or to realize upon the security to be granted hereby, it being understood and agreed that such rights and remedies may be exercised by the Administrative Agent or the Pledgee or the holders of at least a majority of the outstanding Other Obligations, as the case may be, for the benefit of the Secured Creditors upon the terms of this Agreement.

  • Remedies; Waivers (a) Upon the occurrence of an Event of Default, Financial Security may exercise any one or more of the rights and remedies set forth below:

  • Protections Against Violations of Agreement No purported sale, assignment, mortgage, hypothecation, transfer, pledge, encumbrance, gift, transfer in trust (voting or other) or other disposition of, or creation of a security interest in or lien on, any of the Restricted Stock Units by any holder thereof in violation of the provisions of this Agreement or the Certificate of Incorporation or the Bylaws of the Company, will be valid, and the Company will not transfer any shares resulting from the settlement of Restricted Stock Units on its books nor will any of such shares be entitled to vote, nor will any dividends be paid thereon, unless and until there has been full compliance with such provisions to the satisfaction of the Company. The foregoing restrictions are in addition to and not in lieu of any other remedies, legal or equitable, available to enforce such provisions.

  • SUBMISSION TO JURISDICTION; WAIVER OF IMMUNITIES In the Deposit Agreement, the Company has (i) appointed CT Corporation System, with an office in the State of New York at the date hereof at 000 Xxxxxx Xxxxxx, Xxx Xxxx, Xxx Xxxx 00000, as the Company's authorized agent upon which process may be served in any suit or proceeding arising out of or relating to the Shares or Deposited Securities, the American Depositary Shares, the Receipts or this Agreement, (ii) consented and submitted to the jurisdiction of any state or federal court in the State of New York in which any such suit or proceeding may be instituted, and (iii) agreed that service of process upon said authorized agent shall be deemed in every respect effective service of process upon the Company in any such suit or proceeding. To the extent that the Company or any of its properties, assets or revenues may have or hereafter become entitled to, or have attributed to it, any right of immunity, on the grounds of sovereignty or otherwise, from any legal action, suit or proceeding, from the giving of any relief in any respect thereof, from setoff or counterclaim, from the jurisdiction of any court, from service of process, from attachment upon or prior to judgment, from attachment in aid of execution or judgment, or other legal process or proceeding for the giving of any relief or for the enforcement of any judgment, in any jurisdiction in which proceedings may at any time be commenced, with respect to its obligations, liabilities or any other matter under or arising out of or in connection with the Shares or Deposited Securities, the American Depositary Shares, the Receipts or the Deposit Agreement, the Company, to the fullest extent permitted by law, hereby irrevocably and unconditionally waives, and agrees not to plead or claim, any such immunity and consents to such relief and enforcement.

  • SUBMISSION TO JURISDICTION; JURY TRIAL WAIVER; WAIVER OF IMMUNITIES In the Deposit Agreement, the Company has (i) appointed The Bank of New York Mellon, 000 Xxxxxxx Xxxxxx, New York, New York 10286 in the State of New York, as the Company’s authorized agent upon which process may be served in any suit or proceeding arising out of or relating to the Shares or Deposited Securities, the American Depositary Shares, the Receipts or this Agreement, (ii) consented and submitted to the jurisdiction of any state or federal court in the State of New York in which any such suit or proceeding may be instituted, and (iii) agreed that service of process upon said authorized agent shall be deemed in every respect effective service of process upon the Company in any such suit or proceeding. EACH PARTY TO THE DEPOSIT AGREEMENT (INCLUDING, FOR AVOIDANCE OF DOUBT, EACH OWNER AND HOLDER) HEREBY IRREVOCABLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN ANY SUIT, ACTION OR PROCEEDING AGAINST THE COMPANY AND/OR THE DEPOSITARY DIRECTLY OR INDIRECTLY ARISING OUT OF OR RELATING TO THE SHARES OR OTHER DEPOSITED SECURITIES, THE AMERICAN DEPOSITARY SHARES OR THE RECEIPTS, THE DEPOSIT AGREEMENT OR ANY TRANSACTION CONTEMPLATED HEREIN OR THEREIN, OR THE BREACH HEREOF OR THEREOF, INCLUDING WITHOUT LIMITATION ANY QUESTION REGARDING EXISTENCE, VALIDITY OR TERMINATION (WHETHER BASED ON CONTRACT, TORT OR ANY OTHER THEORY). To the extent that the Company or any of its properties, assets or revenues may have or hereafter become entitled to, or have attributed to it, any right of immunity, on the grounds of sovereignty or otherwise, from any legal action, suit or proceeding, from the giving of any relief in any respect thereof, from setoff or counterclaim, from the jurisdiction of any court, from service of process, from attachment upon or prior to judgment, from attachment in aid of execution or judgment, or other legal process or proceeding for the giving of any relief or for the enforcement of any judgment, in any jurisdiction in which proceedings may at any time be commenced, with respect to its obligations, liabilities or any other matter under or arising out of or in connection with the Shares or Deposited Securities, the American Depositary Shares, the Receipts or the Deposit Agreement, the Company, to the fullest extent permitted by law, hereby irrevocably and unconditionally waives, and agrees not to plead or claim, any such immunity and consents to such relief and enforcement.

  • Agent for Service; Submission to Jurisdiction; Waiver of Immunities By the execution and delivery of this Agreement, the Company (i) acknowledges that it has, by separate written instrument, irrevocably designated and appointed CT Corporation System ("CT Corporation"), 000 Xxxxxx Xxxxxx, 00xx Xxxxx, Xxx Xxxx, Xxx Xxxx 00000 (and any successor entity), as its authorized agent upon which process may be served in any suit or proceeding arising out of or relating to this Agreement that may be instituted in any federal or state court in the State of New York or brought under federal or state securities law, and acknowledges that CT Corporation has accepted such designation, (ii) submits to the jurisdiction of any such court in any such suit or proceeding, and (iii) agrees that service of process upon CT Corporation and written notice of said service to the Company (mailed or delivered to the Company at its principal office in Xxxxxxx, Xxxxxxx, Xxxxxx currently being Xxx Xxxxx Xxxxxxxx Xxxx, Xxxxxxx, Xxxxxxx, X0X 0X0, attention: Senior Vice President and Chief Financial Officer, with a copy to Xxxxxx Communications Inc., 000 Xxxxx Xxxxxx Xxxx, Xxxxxxx, Xxxxxxx, X0X 0X0, attention: Vice-President, Treasurer on the 10th Floor, and Vice-President, General Counsel and Secretary on the 0xx Xxxxx), shall be deemed in every respect effective service of process upon the Company in any such suit or proceeding. The Company further agrees to take any and all action, including the execution and filing of any and all such documents and instruments, as may be necessary to continue such designation and appointment of CT Corporation in full force and effect so long as any of the Initial Securities shall be outstanding. To the extent that the Company has or hereafter may acquire any immunity from jurisdiction of any court or from any legal process (whether through service of notice, attachment prior to judgment, attachment in aid of execution, execution or otherwise) with respect to itself or its property, it hereby irrevocably waives such immunity in respect of its obligations under the above-referenced documents, to the extent permitted by law.

  • REMEDIES AND WAIVERS No failure to exercise, nor any delay in exercising, on the part of any Finance Party, any right or remedy under the Finance Documents shall operate as a waiver, nor shall any single or partial exercise of any right or remedy prevent any further or other exercise or the exercise of any other right or remedy. The rights and remedies provided in this Agreement are cumulative and not exclusive of any rights or remedies provided by law.

  • Consent to Jurisdiction; Waiver of Immunities EACH PARTY HERETO HEREBY ACKNOWLEDGES AND AGREES THAT:

Time is Money Join Law Insider Premium to draft better contracts faster.