Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
Contractor Sales Reporting Vendor Management Fee Contractor Reports Master Contract Sales Reporting. Contractor shall report total Master Contract sales quarterly to Enterprise Services, as set forth below. Master Contract Sales Reporting System. Contractor shall report quarterly Master Contract sales in Enterprise Services’ Master Contract Sales Reporting System. Enterprise Services will provide Contractor with a login password and a vendor number. The password and vendor number will be provided to the Sales Reporting Representative(s) listed on Contractor’s Bidder Profile. Data. Each sales report must identify every authorized Purchaser by name as it is known to Enterprise Services and its total combined sales amount invoiced during the reporting period (i.e., sales of an entire agency or political subdivision, not its individual subsections). The “Miscellaneous” option may be used only with prior approval by Enterprise Services. Upon request, Contractor shall provide contact information for all authorized purchasers specified herein during the term of the Master Contract. If there are no Master Contract sales during the reporting period, Contractor must report zero sales. Due dates for Master Contract Sales Reporting. Quarterly Master Contract Sales Reports must be submitted electronically by the following deadlines for all sales invoiced during the applicable calendar quarter: March 31: April 30 June 30: July 31 September 30: October 31 December 31: January 31 Vendor Management Fee. Contractor shall pay to Enterprise Services a vendor management fee (“VMF”) of 1.50 percent on the purchase price for all Master Contract sales (the purchase price is the total invoice price less applicable sales tax). The sum owed by Contractor to Enterprise Services as a result of the VMF is calculated as follows: Amount owed to Enterprise Services = Total Master Contract sales invoiced (not including sales tax) x .0150. The VMF must be rolled into Contractor’s current pricing. The VMF must not be shown as a separate line item on any invoice unless specifically requested and approved by Enterprise Services. Enterprise Services will invoice Contractor quarterly based on Master Contract sales reported by Contractor. Contractors are not to remit payment until they receive an invoice from Enterprise Services. Contractor’s VMF payment to Enterprise Services must reference this Master Contract number, work request number (if applicable), the year and quarter for which the VMF is being remitted, and the Contractor’s name as set forth in this Master Contract, if not already included on the face of the check. Failure to accurately report total net sales, to submit a timely usage report, or remit timely payment of the VMF, may be cause for Master Contract termination or the exercise of other remedies provided by law. Without limiting any other available remedies, the Parties agree that Contractor’s failure to remit to Enterprise Services timely payment of the VMF shall obligate Contractor to pay to Enterprise Services, to offset the administrative and transaction costs incurred by the State to identify, process, and collect such sums. The sum of $200.00 or twenty-five percent (25%) of the outstanding amount, whichever is greater, or the maximum allowed by law, if less. Enterprise Services reserves the right, upon thirty (30) days advance written notice, to increase, reduce, or eliminate the VMF for subsequent purchases, and reserves the right to renegotiate Master Contract pricing with Contractor when any subsequent adjustment of the VMF might justify a change in pricing. Annual Master Contract Sales Report. Upon request, Contractor shall provide to Enterprise Services a detailed annual Master Contract sales report. Such report shall include, at a minimum: Product description, part number or other Product identifier, per unit quantities sold, and Master Contract price. This report must be provided in an electronic format that can be read by compatible with MS Excel. Small Business Inclusion. Upon Request by Enterprise Services, Contractor shall provide, within thirty (30) days, an Affidavit of Amounts Paid. Such Affidavit of Amounts Paid either shall state, if applicable, that Contractor still maintains its MWBE certification or state that its subcontractor(s) still maintain(s) its/their MWBE certification(s) and specify the amounts paid to each certified MWBE subcontractor under this Master Contract. Contractor shall maintain records supporting the Affidavit of Amounts Paid in accordance with this Master Contract’s records retention requirements.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Residence Life or the Director’s designee.
Production Report and Lease Operating Statements Within 60 days after the end of each fiscal quarter, a report setting forth, for each calendar month during the then current fiscal year to date, the volume of production and sales attributable to production (and the prices at which such sales were made and the revenues derived from such sales) for each such calendar month from the Oil and Gas Properties, and setting forth the related ad valorem, severance and production taxes and lease operating expenses attributable thereto and incurred for each such calendar month.
Sales Reports On or before the twentieth (20th) day of each calendar month after the First Month, Tenant shall submit to City a report (the “Sales Report”) showing all Gross Revenues achieved with respect to the prior month by location, segregated by each source or general type of article sold or service rendered. Such report shall be certified as being true and correct by Tenant and shall otherwise be in form and substance satisfactory to Director. As described below, City shall have the right, in addition to all other rights herein, to impose a fine in the event Tenant shall fail to submit such Sales Report timely.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Required Vendor Sales Reporting By responding to this Solicitation, you agree to report to TIPS all sales made under any awarded Agreement with TIPS. Vendor is required to report all sales under the TIPS contract to TIPS. If the TIPS Member entity requesting a price from the awarded Vendor requests the TIPS contract, Vendor must include the TIPS Contract number on any communications with the TIPS Member entity. If awarded, you will be provided access to the Vendor Portal. To report sales, login to the TIPS Vendor Portal and click on the PO’s and Payments tab. Pages 3-7 of the Vendor Portal User Guide will walk you through the process of reporting sales to TIPS. Please refer to the TIPS Accounting FAQ’s for more information about reporting sales and if you have further questions, contact the Accounting Team at xxxxxxxxxx@xxxx-xxx.xxx. The Vendor or vendor assigned dealers are responsible for keeping record of all sales that go through the TIPS Agreement and submitting same to TIPS.
Cost Reports Seller, at its expense, shall prepare and timely file all terminating and other cost reports required or permitted by law to be filed under the Medicare and Medicaid or other third party payor programs and the Licensing Agency for periods ending on or prior to the Effective Time, or as a result of the consummation of the transactions described herein (“Seller Cost Reports”). In addition, Xxxxx shall assist Seller in providing certain information needed by Seller when preparing the terminating cost reports, including but not limited to completion of Seller’s standard hospital data collection template, invoice and general ledger analysis, and other documentation historically prepared by the Hospitals for cost reporting purposes. The applicable Buyer Entity shall forward to Seller any and all correspondence relating to the Seller Cost Reports within five (5) business days after receipt by such Buyer Entity. The applicable Buyer Entity shall remit any receipts of funds relating to the Seller Cost Reports or the Seller Entity’s Medicare bad debt within five (5) business days after receipt by such Buyer Entity and shall forward to Seller any demand for payments within five (5) business days after receipt by such Buyer Entity. Notwithstanding anything to the contrary in this Agreement, Seller shall retain all rights to the Seller Cost Reports including any amounts receivable or payable in respect of such reports or reserves relating to such reports and all liabilities relating thereto. Such rights shall include the right to appeal any Medicare or Medicaid determinations relating to the Seller Cost Reports. Seller shall retain the originals of the Seller Cost Reports, correspondence, work papers and other documents relating to the Seller Cost Reports. Seller will furnish copies of such cost reports to any Buyer Entity upon request.
Subcontract Costs Payments made by the Construction Manager to Subcontractors in accordance with the requirements of the subcontracts and this Agreement.
