Disagreement on Decision Should the parties disagree as to the meaning of the Board's decision, either party may apply to the Chairperson of the Board of Arbitration to reconvene the Board to clarify the decision, which it shall do within five (5) days.
Time Limits on Claims Claims by either party must be made within twenty-one (21) days after occurrence of the event giving rise to such Claim or within twenty-one (21) days after the claimant first recognizes the condition giving rise to the Claim, whichever is later. Claims must be made by written notice and include all facts and detailed cost data substantiating the Claim. An additional Claim made after the initial Claim has been implemented by Change Order will not be considered unless submitted in a timely manner.
Notification of Incidents, Claims or Suits 21 CONTRACTOR shall report to COUNTY:
Product Claims You acknowledge that Company, not an App Distributor, is responsible for addressing any claims of yours or any third party relating to the Company application or your possession and/or use of the Company application, including, but not limited to: (i) product liability claims; (ii) any claim that the Company application fails to conform to any applicable legal or regulatory requirement; and (iii) claims arising under consumer protection or similar legislation. (5)
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Settlement of Third Party Claims Notwithstanding any other provision of this Agreement, the Indemnifying Party shall not enter into settlement of any Third Party Claim without the prior written consent of the Indemnified Party, except as provided in this Section 8.05(b). If a firm offer is made to settle a Third Party Claim without leading to liability or the creation of a financial or other obligation on the part of the Indemnified Party and provides, in customary form, for the unconditional release of each Indemnified Party from all liabilities and obligations in connection with such Third Party Claim and the Indemnifying Party desires to accept and agree to such offer, the Indemnifying Party shall give written notice to that effect to the Indemnified Party. If the Indemnified Party fails to consent to such firm offer within ten days after its receipt of such notice, the Indemnified Party may continue to contest or defend such Third Party Claim and in such event, the maximum liability of the Indemnifying Party as to such Third Party Claim shall not exceed the amount of such settlement offer. If the Indemnified Party fails to consent to such firm offer and also fails to assume defense of such Third Party Claim, the Indemnifying Party may settle the Third Party Claim upon the terms set forth in such firm offer to settle such Third Party Claim. If the Indemnified Party has assumed the defense pursuant to Section 8.05(a), it shall not agree to any settlement without the written consent of the Indemnifying Party (which consent shall not be unreasonably withheld or delayed).
Third Party Claims If any Indemnified Party receives notice of the assertion or commencement of any Action made or brought by any Person who is not a party to this Agreement or an Affiliate of a party to this Agreement or a Representative of the foregoing (a “Third-Party Claim”) against such Indemnified Party with respect to which the Indemnifying Party is obligated to provide indemnification under this Agreement, the Indemnified Party shall give the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than thirty (30) calendar days after receipt of such notice of such Third-Party Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Third-Party Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have the right to participate in, or by giving written notice to the Indemnified Party, to assume the defense of any Third-Party Claim at the Indemnifying Party’s expense and by the Indemnifying Party’s own counsel, and the Indemnified Party shall cooperate in good faith in such defense. In the event that the Indemnifying Party assumes the defense of any Third-Party Claim, subject to Section 8.03(b), it shall have the right to take such action as it deems necessary to avoid, dispute, defend, appeal or make counterclaims pertaining to any such Third-Party Claim in the name and on behalf of the Indemnified Party. The Indemnified Party shall have the right to participate in the defense of any Third-Party Claim with counsel selected by it subject to the Indemnifying Party’s right to control the defense thereof, provided that the fees and disbursements of such counsel shall be at the expense of the Indemnified Party.
Defense of Third Party Claims Upon receipt by the Indemnifying Party of a notice from the Indemnified Party with respect to any claim of a third party against the Indemnified Party, for which the Indemnified Party seeks indemnification hereunder, the Indemnifying Party shall have the right to assume the defense of such claim, and the Indemnified Party shall cooperate to the extent reasonably requested by the Indemnifying Party in defense or prosecution thereof and shall furnish such records, information and testimony and attend all such conferences, discovery proceedings, hearings, trials and appeals as may be reasonably requested by the Indemnifying Party in connection therewith. If the Indemnifying Party shall elect to assume the defense of such claim, the Indemnified Party shall have the right to employ its own counsel in any such case, but the fees and expenses of such counsel shall be at the expense of the Indemnified Party. If the Indemnifying Party has assumed the defense of any claim against the Indemnified Party, the Indemnifying Party shall have the right to settle any claim for which indemnification has been sought and is available hereunder; provided that, to the extent that such settlement requires the Indemnified Party to take, or prohibits the Indemnified Party from taking, any action or purports to obligate the Indemnified Party, then the Indemnifying Party shall not settle such claim without the prior written consent of the Indemnified Party, such consent not to be unreasonably withheld, conditioned or delayed. If the Indemnifying Party does not assume the defense of a third party claim and disputes the Indemnified Party’s right to indemnification, the Indemnified Party shall have the right to assume control of the defense of such claim through counsel of its choice, the reasonable costs of which shall be at the Indemnifying Party’s expense in the event that the Indemnified Party’s right of indemnification is ultimately established through settlement, compromise or other legal proceeding. In no circumstance may the Indemnified Party compromise or settle a claim with a third party for which it seeks indemnification from the Indemnifying Party without first obtaining the prior written consent of the Indemnifying Party, such consent not to be unreasonably withheld, conditioned or delayed.
Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.
RETURNS, CLAIMS, REFUNDS The customer shall immediately upon receipt of goods supplied fully inspect such goods and satisfy itself that the goods are correct. If the customer is unsatisfied, the customer must immediately contact the Company and communicate all details of such dissatisfaction. Unless the above procedure is followed the Company is entitled to assume that the goods supplied are correct and no returns claims for refunds will be permitted or made.
