Requirement for Contractor to retain Landlord’s Building Class. “E” system vendor to install all fire alarm related devices and wiring “TURN KEY” inclusive of required filings, inspections and permit fees.
Requirement for Contractor to retain Landlord’s Building Class Sample Clauses
Related to Requirement for Contractor to retain Landlord’s Building Class
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Maintenance and Repairs by Tenant Tenant, at its expense, shall --------------------------------- maintain and repair the interior of the Leased Premises, and all heating, air conditioning, ventilating, electrical, mechanical, sprinkler and plumbing systems, equipment, machinery or fixtures exclusively servicing the Leased Premises, together with all pipes, conduits, ducts and drains therefor. Furthermore Tenant, at its expense, shall replace any broken glass in the interior or exterior of the Leased Premises, and shall maintain and repair all entryway doors to the Leased Premises. Landlord shall assign to Tenant all assignable manufacturers' warranties with respect to equipment and fixtures installed in the Leased Premises. Tenant further agrees to keep the Leased Premises in good, tenantable, sanitary, sightly and clean condition and to keep all lobbies and entryways which are part of the Leased Premises clean and free from debris, refuse, obstructions or hazardous conditions. Tenant agrees to notify Landlord in the event an excessive amount of snow accumulates on the roof of the Leased Premises. Tenant shall be responsible for all maintenance or repairs wholly or partially (to the extent of Tenant's part) caused by the negligence or fault of Tenant or any of its agents, visitors or licensees, or by Tenant's breach of any provision of this Agreement. If Tenant does not make the repairs or perform the maintenance required hereunder in a prompt and adequate manner, then after notice to Tenant and opportunity cure as provided herein, Landlord may make such repairs or perform such maintenance and pay the costs thereof, and such costs shall be so much Additional Rent which shall become immediately due and payable by Tenant to Landlord.
Premises Parking and Common Areas 2.1 Letting Lessor hereby leases to Lessee, and Lessee hereby leases from Lessor, the Premises, for the term, at the rental, and upon all of the terms covenants and conditions set forth in this Lease. Unless otherwise provided herein, any statement of square footage set forth in this Lease, or that may have been used in calculating rental and/or Common Area Operating Expenses, is an approximation which Lessor and Lessee agree is reasonable and the rental and Lessee's Share (as defined in Paragraph 1.6(b)) based thereon is not subject to revision whether or not the actual square footage is more or less.
Tenant’s Compliance With Landlord’s Fire and Casualty Insurance Tenant shall, at Tenant’s expense, comply with all insurance company requirements pertaining to the use of the Premises. If Tenant’s conduct or use of the Premises causes any increase in the premium for such insurance policies then Tenant shall reimburse Landlord for any such increase. Tenant, at Tenant’s expense, shall comply with all rules, orders, regulations or requirements of the American Insurance Association (formerly the National Board of Fire Underwriters) and with any similar body.
Landlord’s Retention of Contractor Landlord shall independently retain the Contractor to perform the Tenant Improvement Work in accordance with the Approved Construction Drawings.
Landlord’s Compliance Landlord shall comply with (or cause to be complied with) all Requirements applicable to the Building which are not the obligation of Tenant, to the extent that non-compliance would materially impair Tenant’s use and occupancy of the Premises for the Permitted Uses.
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Tenant’s Compliance Tenant shall materially comply with all Applicable Laws and operational registrations and licenses, including without limitation, the Marijuana Code, and shall promptly comply with all governmental orders and directives for the correction, prevention, and abatement of any nuisances and any violation of Applicable Laws in, upon, or connected with the Premises, all at Tenant’s sole expense. Tenant warrants that all improvements or alterations of the Premises made by Tenant or Tenant’s employees, agents or contractors, either prior to Tenant’s occupancy of the Premises or during the Term, will comply with all Applicable Laws, including any and all on site security requirements set forth under Applicable Laws or as otherwise reasonably required by Landlord given the safety concerns associated with the Permitted Use hereunder. In the event that (i) Tenant’s specific use and occupancy of the Premises, or (ii) any alterations to the Premises performed by or on behalf of Tenant pursuant to this Lease, necessitates or triggers any modifications (including structural modifications) to the Premises or Buildings or alterations to the Buildings systems, the same shall be made by Landlord pursuant to a budget reasonably agreed upon by Landlord and Tenant and promptly reimbursed by Tenant within thirty (30) days after written demand by Landlord, including backup substantiating Tenant’s proportionate share of the expenses. In addition, Tenant warrants that its use of the Premises will be in material compliance with all Applicable Laws subject to the Legal Compliance Clarification.
Construction of Tenant Improvements by Tenants Agents Construction Contract; Cost Budget. Prior to Tenant's execution of ---------------------------------- the construction contract and general conditions with Contractor (the "Contract"), Tenant shall submit the Contract to Landlord for its approval, which approval shall not be unreasonably withheld or delayed. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, of the final costs to be incurred, or which have been incurred, as set forth more particularly in Sections 2.2.1.1 through ---------------- 2.2.1.8 above, in connection with the design and construction of the Tenant ------- Improvements to be performed by or at the direction of Tenant or the Contractor (which costs form a basis for the amount of the Contract, if any (the "Final Costs"). Prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with a completion bond in an amount equal to the Final Costs to ensure Landlord of the completion of the Tenant Improvements.
Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.
