Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
EVENTS CONSTITUTING MATERIAL BREACH OF AGREEMENT The Applicant shall be in Material Breach of this Agreement if it commits one or more of the following acts or omissions (each a “Material Breach”):
A. The Application, any Application Supplement, or any Application Amendment on which this Agreement is approved is determined to be inaccurate as to any material representation, information, or fact or is not complete as to any material fact or representation or such application;
B. The Applicant failed to complete Qualified Investment as required by Section 2.5.A. of this Agreement during the Qualifying Time Period;
C. The Applicant failed to create and maintain the number of New Qualifying Jobs required by the Act;
D. The Applicant failed to create and maintain the number of New Qualifying Jobs specified in Schedule C of the Application;
E. The Applicant failed to pay at least the average weekly wage of all jobs in the county in which the jobs are located for all New Non-Qualifying Jobs created by the Applicant;
F. The Applicant failed to provide payments to the District sufficient to protect future District revenues through payment of revenue offsets and other mechanisms as more fully described in Article IV of this Agreement;
G. The Applicant failed to provide the payments to the District that protect the District from the payment of extraordinary education-related expenses related to the project to the extent and in the amounts that the Applicant agreed to provide such payments in Article V of this Agreement;
H. The Applicant failed to provide the Supplemental Payments to the extent and in the amounts that the Applicant agreed to provide such Supplemental Payments in Article VI of this Agreement;
I. The Applicant failed to create and Maintain Viable Presence on or with the Qualified Property as more fully specified in Article VIII of this Agreement;
J. The Applicant failed to submit the reports required to be submitted by Section 8.2 to the satisfaction of the Comptroller;
K. The Applicant failed to provide the District or the Comptroller with all information reasonably necessary for the District or the Comptroller to determine whether the Applicant is in compliance with its obligations, including, but not limited to, any employment obligations which may arise under this Agreement;
L. The Applicant failed to allow authorized employees of the District, the Comptroller, the Appraisal District, or the State Auditor’s Office to have access to the Applicant’s Qualified Property or business records in order to inspect the project to determine compliance with the terms hereof or as necessary to properly appraise the Taxable Value of the Applicant’s Qualified Property under Sections 8.5 and 8.6;
M. The Applicant failed to comply with a request by the State Auditor’s office to review and audit the Applicant’s compliance with this Agreement;
N. The Applicant has made any payments to the District or to any other person or persons in any form for the payment or transfer of money or any other thing of value in recognition of, anticipation of, or consideration for this Agreement for limitation on Appraised Value made pursuant to Chapter 313 of the TEXAS TAX CODE, in excess of the amounts set forth in Articles IV, V and VI of this Agreement;
O. The Applicant failed to comply with the conditions included in the certificate for limitation issued by the Comptroller.
Retention or Repurchase of Assets Essential to Receiver (a) The Receiver may refuse to sell to the Assuming Institution, or the Assuming Institution agrees, at the request of the Receiver set forth in a written notice to the Assuming Institution, to assign, transfer, convey, and deliver to the Receiver all of the Assuming Institution's right, title and interest in and to, any Asset or asset essential to the Receiver as determined by the Receiver in its discretion (together with all Credit Documents evidencing or pertaining thereto), which may include any Asset or asset that the Receiver determines to be:
(i) made to an officer, director, or other Person engaging in the affairs of the Failed Bank, its Subsidiaries or Affiliates or any related entities of any of the foregoing;
(ii) the subject of any investigation relating to any claim with respect to any item described in Section 3.5(a) or (b), or the subject of, or potentially the subject of, any legal proceedings;
(iii) made to a Person who is an Obligor on a loan owned by the Receiver or the Corporation in its corporate capacity or its capacity as receiver of any institution;
(iv) secured by collateral which also secures any asset owned by the Receiver; or
(v) related to any asset of the Failed Bank not purchased by the Assuming Institution under this Article III or any liability of the Failed Bank not assumed by the Assuming Institution under Article II.
(b) Each such Asset or asset purchased by the Receiver shall be purchased at a price equal to the Repurchase Price thereof less the Related Liability Amount with respect to any Related Liabilities related to such Asset or asset, in each case determined as of the date of the notice provided by the Receiver pursuant to Section 3.6(a). The Receiver shall pay the Assuming Institution not later than the twentieth (20th) Business Day following receipt of related Credit Documents and Credit Files together with interest on such amount at the Settlement Interest Rate for the period from and including the date of receipt of such documents to and including the day preceding the day on which payment is made. The Assuming Institution agrees to administer and manage each such Asset or asset in accordance with usual and prudent banking standards and business practices until each such Asset or asset is purchased by the Receiver. All transfers with respect to Asset or assets under this Section 3.6 shall be made as provided in Section 9.6. The Assuming Institution shall transfer all such Asset or assets and Related Liabilities to the Receiver without recourse, and shall indemnify the Receiver against any and all claims of any Person claiming by, through or under the Assuming Institution with respect to any such Asset or asset, as provided in Section 12.4.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.
Application of Proceeds of Sale The proceeds of any sale of Collateral pursuant to Section 6, as well as any Collateral consisting of cash, shall be applied by the Collateral Agent as follows: FIRST, to the payment of all costs and expenses incurred by the Collateral Agent in connection with such sale or otherwise in connection with this Agreement, any other Loan Document or any of the Obligations, including all court costs and the reasonable fees and expenses of its agents and legal counsel, the repayment of all advances made by the Collateral Agent hereunder or under any other Loan Document on behalf of any Pledgor and any other costs or expenses incurred in connection with the exercise of any right or remedy hereunder or under any other Loan Document; SECOND, to the payment in full of the Obligations (the amounts so applied to be distributed among the Secured Parties pro rata in accordance with the amounts of the Obligations owed to them on the date of any such distribution); and THIRD, to the Pledgors, their successors or assigns, or as a court of competent jurisdiction may otherwise direct. The Collateral Agent shall have absolute discretion as to the time of application of any such proceeds, moneys or balances in accordance with this Agreement. Upon any sale of the Collateral by the Collateral Agent (including pursuant to a power of sale granted by statute or under a judicial proceeding), the receipt of the purchase money by the Collateral Agent or of the officer making the sale shall be a sufficient discharge to the purchaser or purchasers of the Collateral so sold and such purchaser or purchasers shall not be obligated to see to the application of any part of the purchase money paid over to the Collateral Agent or such officer or be answerable in any way for the misapplication thereof.
Review by the Association of Procurement Decisions The Procurement Plan shall set forth those contracts which shall be subject to the Association’s Prior Review. All other contracts shall be subject to Post Review by the Association.
Actions following an Event of Default On, or at any time after, the occurrence and during the continuation of an Event of Default:
(a) the Agent may, and if so instructed by the Majority Lenders, the Agent shall:
(i) serve on the Borrowers a notice stating that all or part of the Commitments and of the other obligations of each Lender to the Borrowers under this Agreement are cancelled; and/or
(ii) serve on the Borrowers a notice stating that all or part of the Loan together with accrued interest and all other amounts accrued or owing under this Agreement are immediately due and payable or are due and payable on demand; and/or
(iii) take any other action which, as a result of the Event of Default or any notice served under paragraph (i) or (ii), the Agent and/or the Lenders are entitled to take under any Finance Document or any applicable law; and/or
(b) the Security Trustee may, and if so instructed by the Agent, acting with the authorisation of the Majority Lenders, the Security Trustee shall take any action which, as a result of the Event of Default or any notice served under paragraph (a)(i) or (a)(ii), the Security Trustee, the Agent and/or the Lenders and/or the Swap Counterparties are entitled to take under any Finance Document or any applicable law.
Governing Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the laws of the State of New York. The section headings in this Agreement have been inserted as a matter of convenience of reference and are not a part of this Agreement.
Default Not Exceeding 10% of Firm Units If any Underwriter or Underwriters shall default in its or their obligations to purchase the Firm Units and if the number of the Firm Units with respect to which such default relates does not exceed in the aggregate 10% of the number of Firm Units that all Underwriters have agreed to purchase hereunder, then such Firm Units to which the default relates shall be purchased by the non-defaulting Underwriters in proportion to their respective commitments hereunder.
