Attorneys’ Fees and Cost of Collection In the event any suit, action or arbitration is filed by either party against the other to interpret or enforce any of the Transaction Documents, the unsuccessful party to such action agrees to pay to the prevailing party all costs and expenses, including attorneys’ fees incurred therein, including the same with respect to an appeal. The “prevailing party” shall be the party in whose favor a judgment is entered, regardless of whether judgment is entered on all claims asserted by such party and regardless of the amount of the judgment; or where, due to the assertion of counterclaims, judgments are entered in favor of and against both parties, then the arbitrator shall determine the “prevailing party” by taking into account the relative dollar amounts of the judgments or, if the judgments involve nonmonetary relief, the relative importance and value of such relief. Nothing herein shall restrict or impair an arbitrator’s or a court’s power to award fees and expenses for frivolous or bad faith pleading. If (i) the Note is placed in the hands of an attorney for collection or enforcement prior to commencing arbitration or legal proceedings, or is collected or enforced through any arbitration or legal proceeding, or Investor otherwise takes action to collect amounts due under the Note or to enforce the provisions of the Note, or (ii) there occurs any bankruptcy, reorganization, receivership of Company or other proceedings affecting Company’s creditors’ rights and involving a claim under the Note; then Company shall pay the costs incurred by Investor for such collection, enforcement or action or in connection with such bankruptcy, reorganization, receivership or other proceeding, including, without limitation, attorneys’ fees, expenses, deposition costs, and disbursements.
Collection Costs and Attorneys’ Fees If a Party fails to perform an obligation or otherwise breaches one or more of the terms of this Agreement, the other Party may recover from the non-performing breaching Party all its costs (including actual attorneys’ and investigative fees) to enforce the terms of this Agreement.
Direct Costs Insert the major cost elements. For each element, consider the application of the paragraph entitled “Costs Requiring Prior Approval” on page 1 of these instructions.
Disbursement of the Tenant Improvement Allowance Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord (each of which disbursement shall be made pursuant to Landlord’s standard disbursement process), only for the following items and costs (collectively, the “Tenant Improvement Allowance Items”):
Construction Costs Tenant shall pay for all construction costs, including, but not limited to permits, costs of materials and labor, sales tax, construction management fees and the like except to the extent of the Tenant Improvement Allowance which shall be paid by Landlord. The term “Tenant Improvement Allowance” shall mean the sum of $316,020.00 (or $15.00 per square foot of rentable area times 21,068 square feet of rentable area) which Landlord agrees to pay towards the construction costs. Landlord agrees to pay architectural fees and design services up to $1.25 per rentable square foot. Any services performed by the architect above the $1.25 per rentable square foot shall be the responsibility of the Tenant and may be paid out of the Tenant Improvement Allowance to the extent funds are available. Notwithstanding anything to the contrary, provided there is any unused portion of the Tenant Improvement Allowance, up to 20% of the allowance can be used by the Tenant as a moving allowance or for communications costs for cabling and data. Tenant must submit invoices for such allowances for Landlord to pay. Xxxxxx Development will act as General Contractor for the construction of tenant improvements, competitively bidding each trade to at least three subcontractors, the typical five percent (5%) construction management fee will not be charged to Tenant or deducted from the Tenant Improvement Allowance. Landlord shall obtain bids based on the Approved Pricing Plans and construct the Work as described in the Approved Pricing Plans. If after finalizing the Approved Working Drawings, it is determined that the construction costs will exceed the amount of the Tenant Improvement Allowance (an “Excess”), then Tenant shall pay to Landlord the amount of such Excess within ten (10) days of written request from Landlord. Notwithstanding anything to the contrary, if Tenant fails to pay any Excess timely, Landlord shall not be obligated to commence construction of the Work and such delay shall constitute a Tenant Delay for each day beyond the ten (10) day period until the Excess is paid to Landlord. If Tenant elects not to use Xxxxxx Development as the General Contractor, Tenant understands that Landlord, or its designated agent, shall serve as construction manager for all of Tenant’s refurbishment and renovations in the refurbishment and renovations in the Premises and the fee for such service is 5% of the total cost of all work performed in connection with such refurbishment and renovations. Tenant agrees to cooperate with Landlord in completing any such improvements on a timely basis and Tenant has approved the preliminary space plan and pricing documentation. Additional space on the 3rd floor which Tenant elects to lease pursuant [****] = CERTAIN CONFIDENTIAL INFORMATION CONTAINED IN THIS DOCUMENT, MARKED BY BRACKETS, HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO RULE 406 OF THE SECURITIES ACT OF 1933, AS AMENDED. to a right hereunder shall be finished out by Landlord pursuant to mutually agreed upon plans and Tenant shall receive an allowance of $15.00 per square foot of rentable area provided, however, Tenant acknowledges that Landlord is improving the entire third (3rd) floor prior to commencement of the Lease and Tenant shall not be entitled to any additional tenant finish when Tenant leases the remainder of the third floor.
Construction of Hotel (i) To Seller’s knowledge, the Hotel has been constructed in a good and workmanlike manner without encroachments except as noted on the Survey and in accordance in all material respects with the Construction Plans. To Seller’s knowledge, the Hotel has received all building permits and certificates of occupancy necessary for the operation thereof, and is in compliance with applicable zoning, platting, subdivision, health, safety and similar laws, rules, regulations, ordinances and codes.
Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.
Construction Allowance Landlord shall provide to Tenant a construction allowance not to exceed $45.00 per rentable square foot in the Premises (the “Construction Allowance”) to be applied toward the Total Construction Costs, as adjusted for any changes to the Tenant’s Work. No advance of the Construction Allowance shall be made by Landlord until Tenant has first paid to the contractor from its own funds (and provided reasonable evidence thereof to Landlord) the anticipated Excess Amount. Thereafter, Landlord shall pay to Tenant the Construction Allowance, to be applied solely toward the remaining Total Construction Costs and not in reimbursement of the Excess Amount paid by Tenant, in multiple disbursements (but not more than once in any calendar month) following the receipt by Landlord of the following items: (i) a request for payment, (ii) final, unconditional or partial lien waivers, as the case may be, from all persons performing work or supplying or fabricating materials for the Tenant’s Work, fully executed, acknowledged and in recordable form, (iii) copies of all invoices and proof of payment of same, and (iv) the Architect’s certification that the Tenant’s Work for which reimbursement has been requested has been finally completed, including (with respect to the last application for payment only) any punch-list items, on the appropriate AIA form or another form approved by Landlord, and, with respect to the disbursement of the last 10% of the Construction Allowance: (1) the permanent certificate of occupancy issued for the Premises, (2) Tenant’s occupancy of the Premises, (3) delivery of the “as-built” plans for the Tenant’s Work as constructed (and as set forth above) to Landlord’s construction representative (set forth below), and (4) an estoppel certificate confirming such factual matters as Landlord or Landlord’s Mortgagee may reasonably request (collectively, a “Completed Application for Payment”). Landlord shall pay the amount requested in the applicable Completed Application for Payment to Tenant within 30 days following Tenant’s submission of the Completed Application for Payment. If, however, the Completed Application for Payment is incomplete or incorrect, Landlord’s payment of such request shall be deferred until 30 days following Landlord’s receipt of the corrected Completed Application for Payment. Notwithstanding anything to the contrary contained in this Exhibit, Landlord shall not be obligated to make any disbursement of the Construction Allowance during the pendency of any of the following: (A) Landlord has received written notice of any unpaid claims relating to any portion of the Tenant’s Work or materials in connection therewith, other than claims which will be paid in full from such disbursement, (B) there is an unbonded lien outstanding against the Project or the Premises or Tenant’s interest therein by reason of work done, or claimed to have been done, or materials supplied or specifically fabricated, claimed to have been supplied or specifically fabricated, to or for Tenant or the Premises, (C) the conditions to the advance of the Construction Allowance are not satisfied, or (D) an Event of Default by Tenant exists. If the Total Construction Costs for the Premises are less than the Construction Allowance, then Tenant shall not be entitled to receive payment or credit for such difference and Landlord shall retain the same. The Construction Allowance must be used (that is, the Tenant’s Work must be fully complete and the Construction Allowance disbursed) within twenty-four (24) months following the Commencement Date or shall be deemed forfeited with no further obligation by Landlord with respect thereto, time being of the essence with respect thereto. The Construction Allowance may be used in Tenant’s discretion for Tenant’s Work with no stipulation from Landlord as to how much of the Construction Allowance is allocated within the various spaces in the Premises.
Changes and Alterations Except as otherwise explicitly set forth herein, Tenant shall have no authority, without the express written consent of Landlord to alter, remodel, reconstruct, demolish, add to, improve or otherwise change the Leased Premises, except that Tenant shall have such authority, without the consent of Landlord, to build substructures; add, remove, or modify internal wiring; erect or remove non-load bearing walls; add or remove internal doors; construct internal clean room(s); make repairs to the Leased Premises and do such other things as are appropriate to comply with the obligations imposed on Tenant under other provisions of this Lease. Except as otherwise outlined herein, Tenant shall not construct or permit any alterations, installations, additions or improvements including any interior or exterior signs (“Alterations”) to the Leased Premises or the Building without having first submitted to Landlord plans and specifications therefor for Landlord’s approval, which approval shall not be unreasonably withheld or delayed provided that:
Expenses and Costs Each Borrower, jointly and severally, agrees to pay and to save the Agent and the Lenders harmless for the payment of all fees, out-of-pocket disbursements, and other costs and expenses incurred by or on behalf of the Agent or any Lender arising in any way in connection with this Amendment, or any other document relating to indebtedness described in the recitals to this Amendment, including the fees and expenses of Dickinson Wright PLLC, counsel to the Agent, and AlixPartners, LLC, cxxxxxxxxx xx xxx Agent, and specifically including, without limitation, (a) the cost of any financial audit or inquiry conducted by the Agent, any Lender or their consultants, (b) the fees and expenses of counsel for the Agent or any Lender for the work performed as a result of the Borrowers' defaults or financial problems, and for the preparation, examination and approval of this Amendment or any documents in connection with this Amendment, (c) for the payment of all fees and out-of-pocket disbursements incurred by the Agent or any Lender, including attorneys' fees, in any way arising from or in connection with any action taken by the Agent or any Lender to monitor, advise, enforce or collect the obligations described in the recitals hereto or to enforce any obligations of the Borrowers or any Guarantor under this Amendment or the other documents referred to herein, including any actions to lift the automatic stay or to otherwise in any way participate in any bankruptcy, reorganization or insolvency proceeding of any Borrower or Guarantor or in any trial or appellate proceedings, and (d) any expenses or fees (including attorneys' fees) incurred in relation to or in defense of any litigation instituted by any Borrower, any Guarantor or any third party against the Agent or any Lender arising from or relating to the obligations described in the recitals hereto or this Amendment, including any so-called "lender liability" action. All of these expenses and fees (including attorneys' fees) shall be part of the Obligations owing under the Credit Agreement, and shall be secured by all of the collateral described in the Collateral Documents. In the event the Borrowers fail to pay any such fees, expenses and costs within five (5) days of being invoiced therefor, the Agent or the Lenders, as the case may be, shall be permitted to charge the accounts of any Borrower for such fees, expenses and costs, without prejudice to any other rights or remedies of the Agent or the Lenders. The rights and remedies of the Agent and the Lenders contained in this paragraph shall be in addition to, and not in lieu of, the rights and remedies contained in the Credit Agreement, the Collateral Documents and as otherwise provided by law.
