Contractor Responsibility for System Agency’s Termination Costs If the System Agency terminates the Contract for cause, the Contractor shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Contractor. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Contractor’s failure to perform any Work in accordance with the terms of the Contract.
Responsibility for Property Except as expressly set forth in Section 3.25, Contractor shall limit its operations to the Stage 2 Site. Contractor shall plan and conduct its operations so that neither Contractor nor any of its Subcontractors or Sub-subcontractors shall (i) enter upon lands (other than the Stage 2 Site and Off-Site Rights of Way and Easements) or waterbodies in their natural state unless authorized by the appropriate owner or entity; (ii) close or obstruct any utility installation, highway, waterway, harbor, road or other property unless Permits are obtained and authorized by the appropriate entity or authority; or (iii) disrupt or otherwise interfere with the operation of any portion of any pipeline, telephone, conduit or electric transmission line, ditch, navigational aid, dock or structure unless otherwise specifically authorized by the appropriate entity or authority. The foregoing includes damage arising from performance of the Work through operation of Construction Equipment or stockpiling of materials. If damage occurs to Subproject 1 or Subproject 2 prior to substantial completion of such applicable Subproject 1 or Subproject 2, liability for such damage shall be governed by the Stage 1 EPC Agreement.
Responsibility for Payment The Company shall not be responsible for the payment of time used by an employee in the investigation and settlement of a grievance.
Responsibility for Charges 4.1 CBB shall be responsible for and pay to Verizon all charges for any Telecommunications Services provided by Verizon or provided by persons other than Verizon and billed for by Verizon, that are ordered, activated or used by CBB, CBB Customers or any other persons, through, by means of, or in association with, Telecommunications Services provided by Verizon to CBB pursuant to this Resale Attachment.
4.2 Upon request by CBB, Verizon will provide for use on resold Verizon retail Telecommunications Service dial tone lines purchased by CBB such Verizon retail Telecommunications Service call blocking and call screening services as Verizon provides to its own end user retail Customers, where and to the extent Verizon provides such Verizon retail Telecommunications Service call blocking services to Verizon’s own end user retail Customers. CBB understands and agrees that certain of Verizon’s call blocking and call screening services are not guaranteed to block or screen all calls and that notwithstanding CBB’s purchase of such blocking or screening services, CBB’s end user Customers or other persons ordering, activating or using Telecommunications Services on the resold dial tone lines may complete or accept calls which CBB intended to block. Notwithstanding the foregoing, CBB shall be responsible for and shall pay Verizon all charges for Telecommunications Services provided by Verizon or provided by persons other than Verizon and billed for by Verizon in accordance with the terms of Section 4.1 above.
Responsibility for Content Vendor is solely responsible for administration, content, intellectual property rights, and all materials at Vendor’s website. DIR reserves the right to require a change of listed content if, in the opinion of DIR, it does not adequately represent the Contract.
Responsibility For Use (a) The Company alone will be responsible for furnishing, or arranging for a third party to furnish, all data and information required by the Documentation and the specifications therein for the Licensed System to function and perform in accordance with the Documentation, other than the data and information residing in the Licensed System in connection with BNYM’s performance of the Core Services. BNYM shall have no liability or responsibility for any Loss caused in whole or in part by the Company’s or a Permitted User’s exercise of the Licensed Rights or use of the Licensed System or by data or information of any nature inputted into the Licensed System by or under the direction or authorization of Company or a Permitted User; provided, however, this Section 2.5 shall not relieve BNYM of its obligation to act in accordance with its obligations under the Main Agreement. Company shall be responsible and solely liable for the cost or expense of regenerating any output or other remedial action if the Company, a Permitted User or an agent of either shall have failed to transmit properly and in the correct format any data or information, shall have transmitted erroneous or incorrect information or data, or shall have failed to timely verify or reconcile any such data or information when it is generated by the Licensed System (“Data Faults”).
ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals.
§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project.
§ 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project.
§ 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project.
§ 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9.
§ 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage.
§ 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage.
§ 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Responsibilities of Contractor A. The Contractor shall perform all work on the described project as required by the Contract documents. The work to be performed includes the labor and services necessary to produce such replacement, and all materials, supplies, tools, transportation, equipment, and machinery required for replacement.
B. This project bid includes all materials, labor and equipment to complete the reconstruction and resurfacing of streets as outlined in the Project Manual for WWREYN - XXXXXXXX SANITARY SEWER - PHASE 1 dated March 25th, 2021 as outlined in Attachment A.
Patent Filing Responsibilities and Costs 1. The invention and patent rights herein apply to any patent application or patents covering an invention made under this Agreement. Each Party is responsible for its own costs of obtaining and maintaining patents covering sole inventions of its employees. The Parties may agree otherwise, upon the reporting of any invention (sole or joint) or in any license granted.
2. Partner shall include the following in patent applications for an invention made jointly between NASA employees, its Related Entity employees and Partner employees: The invention described herein may be manufactured and used by or for the U.S. Government for U.S. Government purposes without the payment of royalties thereon or therefore.
RESPONSIBILITIES OF THE UNIVERSITY The UNIVERSITY shall designate in writing a faculty member to coordinate with a designee of the FIELDWORK SITE.
