Right to Inspect, Cure and Correct Sample Clauses

Right to Inspect, Cure and Correct. Any Respondent shall have the right (without obligation), before the institution by the Claimant of binding arbitration below, to inspect, cure and correct any improvement or condition within the Community with respect to a Defect Claim, as follows: 18.4.4.1 In addition to other rights and obligations set forth in this Article, a Respondent may elect to inspect the Alleged Defect, in which event the Respondent shall complete the initial inspection and testing within thirty (30) days after the date that the Claimant has provided notice to each Respondent pursuant to Section 18.4.2 above, and at a mutually agreeable date and time. The Respondent shall bear all costs of inspection and testing, including any damage caused by the inspection and testing. Before entering onto the Community for the inspection, the Respondent shall supply the Claimant with proof of liability insurance coverage. The Respondent shall, upon request, allow the inspection to be observed and recorded or photographed. Nothing that occurs during a Respondent’s inspection may be used or introduced as evidence to support a defense of spoliation of evidence by the Claimant or any potential party in subsequent litigation. 18.4.4.2 Within sixty (60) days of completion of the initial inspection or testing, the Respondent may elect to repair some or all of the Alleged Defects by sending a written notice of election to repair to the Claimant. Notwithstanding any tolling provided by law, the applicable statutes of limitation and repose on any and all Claims relating to the Alleged Defects shall be tolled (i) from the completion of the initial inspection and/or testing until (a) Respondent’s written notice of election to repair, or (b) the expiration of sixty (60) days, whichever is sooner; and (ii) from the date of any written notice of election to repair by Respondent until sixty (60) days after substantial completion of the repairs. This tolling applies to any and all Claims relating to Alleged Defects for which Claimant has given written notice pursuant to subparagraph 18.4.2 (regardless of whether Respondent has elected to repair none, some or all of the Alleged Defects). If the Respondent elects to repair some or all of the Alleged Defects, then (i) Respondent has the right to do so and the Claimant may not, directly or indirectly, impair, impede or prohibit the Respondent from making repairs; and (ii) until after the substantial completion of the repairs (a) the Claimant shall not file or pur...
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs

Related to Right to Inspect, Cure and Correct

  • Right to Inspect and Audit AHS and the Minister shall have the right (including all access rights required) to inspect or audit the Facility and all of the equipment, Staff and records of the Operator (and to take copies of records where either desires to do so) related to Services performed or to be performed (and goods and services sold or otherwise provided to persons receiving such Services) at all reasonable times and without prior notice in cases of emergency or whenever there is any reasonable apprehension of any ongoing danger to Clients for the purposes of determining compliance with this Agreement, the accuracy of any information provided and compliance with all Applicable Laws.

  • Right to Inspect Records Engineer agrees that City shall have access to and the right to examine any directly pertinent books, documents, papers and records of Engineer involving transactions relating to this contract. Engineer agrees that City shall have access during normal working hours to all necessary Engineer facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. City shall give Engineer reasonable advance notice of intended audits. Engineer further agrees to include in subcontract(s), if any, a provision that any subcontractor or consultant agrees that City shall have access to and the right to examine any directly pertinent books, documents, papers and records of such consultant or subcontractor involving transactions to the subcontract, and further, that City shall have access during normal working hours to all consultant or subcontractor facilities, and shall be provided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this paragraph. City shall give the consultant or subcontractor reasonable advance notice of intended audits.

  • Right to Inspect Bank (through any of its officers, employees, or agents) shall have the right, upon reasonable prior notice, from time to time during Borrower’s usual business hours but no more than twice a year (unless an Event of Default has occurred and is continuing), to inspect Borrower’s Books and to make copies thereof and to check, test, and appraise the Collateral in order to verify Borrower’s financial condition or the amount, condition of, or any other matter relating to, the Collateral.

  • DXC’s Right to Inspect DXC may, at any time, inspect the software, Services, or Products and associated manufacturing processes. Inspection may occur at Supplier’s facility, plant or subcontractor’s plant. Supplier will inform its vendors and subcontractors of DXC’s right to inspect and shall secure that right for DXC if necessary.

  • Books and Records; Inspection and Audit Rights Each of Holdings and the Borrower will, and will cause each Restricted Subsidiary to, maintain proper books of record and account in which entries that are full, true and correct in all material respects and are in conformity with GAAP consistently applied shall be made of all material financial transactions and matters involving the assets and business of Holdings, the Borrower or its Restricted Subsidiary, as the case may be. Each of Holdings and the Borrower will, and will cause each Restricted Subsidiary to, permit any representatives designated by the Administrative Agent or any Lender, upon reasonable prior notice, to visit and inspect its properties, to examine and make extracts from its books and records, and to discuss its affairs, finances and condition with its officers and independent accountants, all at such reasonable times and as often as reasonably requested; provided that, excluding any such visits and inspections during the continuation of an Event of Default, only the Administrative Agent on behalf of the Lenders may exercise visitation and inspection rights of the Administrative Agent and the Lenders under this Section 5.08 and the Administrative Agent shall not exercise such rights more often than two times during any calendar year absent the existence of an Event of Default and only one such time shall be at the Borrower’s expense; provided further that (a) when an Event of Default exists, the Administrative Agent or any Lender (or any of their respective representatives or independent contractors) may do any of the foregoing at the expense of the Borrower at any time during normal business hours and upon reasonable advance notice and (b) the Administrative Agent and the Lenders shall give Holdings and the Borrower the opportunity to participate in any discussions with Holdings’ or the Borrower’s independent public accountants.

  • Inspections and Tests 26.1 The Supplier shall at its own expense and at no cost to the Procuring Entity carry out all such tests and/or inspections of the Goods and Related Services as are specified in the SCC. 26.2 The inspections and tests may be conducted on the premises of the Supplier or its Subcontractor, at point of delivery, and/or at the Goods' final destination, or in another place in Kenya as specified in the SCC. Subject to GCC Sub-Clause 26.3, if conducted on the premises of the Supplier or its Subcontractor, all reasonable facilities and assistance, including access to drawings and production data, shall be furnished to the inspectors at no charge to the Procuring Entity. 26.3 The Procuring Entity or its designated representative shall be entitled to attend the tests and/or inspections referred to in GCC Sub-Clause 26.2, provided that the Procuring Entity bear all of its own costs and expenses incurred in connection with such attendance including, but not limited to, all travelling and board and lodging expenses. 26.4 Whenever the Supplier is ready to carry out any such test and inspection, it shall give a reasonable advance notice, including the place and time, to the Procuring Entity. The Supplier shall obtain from any relevant third party or manufacturer any necessary permission or consent to enable the Procuring Entity or its designated representative to attend the test and/or inspection. 26.5 The Procuring Entity may require the Supplier to carry out any test and/or inspection not required by the Contract but deemed necessary to verify that the characteristics and performance of the Goods comply with the technical specifications codes and standards under the Contract, provided that the Supplier's reasonable costs and expenses incurred in the carrying out of such test and/or inspection shall be added to the Contract Price. Further, if such test and/or inspection impedes the progress of manufacturing and/or the Supplier's performance of its other obligations under the Contract, due allowance will be made in respect of the Delivery Dates and Completion Dates and the other obligations so affected. 26.6 The Supplier shall provide the Procuring Entity with a report of the results of any such test and/or inspection. 26.7 The Procuring Entity may reject any Goods or any part thereof that fail to pass any test and/or inspection or do not conform to the specifications. The Supplier shall either rectify or replace such rejected Goods or parts thereof or make alterations necessary to meet the specifications at no cost to the Procuring Entity, and shall repeat the test and/or inspection, at no cost to the Procuring Entity, upon giving a notice pursuant to GCC Sub- Clause 26.4. 26.8 The Supplier agrees that neither the execution of a test and/or inspection of the Goods or any part thereof, nor the attendance by the Procuring Entity or its representative, nor the issue of any report pursuant to GCC Sub-Clause 26.6, shall release the Supplier from any warranties or other obligations under the Contract.

  • Inspection of Property, Books and Records The Borrower will keep, and will cause each Subsidiary to keep, proper books of record and account in which full, true and correct entries shall be made of all dealings and transactions in relation to its business and activities; and will permit, and will cause each Subsidiary to permit, representatives of any Bank at such Bank's expense to visit and inspect any of their respective properties, to examine and make abstracts from any of their respective books and records and to discuss their respective affairs, finances and accounts with their respective officers, employees and independent public accountants, all at such reasonable times and as often as may reasonably be desired.

  • Inspection; Compliance with Law Lessor, Lessor's agents, employees, contractors and designated representatives, and the holders of any mortgages, deeds of trust or ground leases on the Premises ("Lenders") shall have the right to enter the Premises at any time in the case of an emergency, and otherwise at reasonable times, for the purpose of inspecting the condition of the Premises and for verifying compliance by Lessee with this Lease and all Applicable Requirements (as defined in Paragraph 6.3), and Lessor shall be entitled to employ experts and/or consultants in connection therewith to advise Lessor with respect to Lessee's activities, including but not limited to Lessee's installation, operation, use, monitoring, maintenance, or removal of any Hazardous Substance on or from the Premises. The costs and expenses of any such inspections shall be paid by the party requesting same, unless a Default or Breach of this Lease by Lessee or a violation of Applicable Requirements or a contamination, caused or materially contributed to by Lessee, is found to exist or to be imminent, or unless the inspection is requested or ordered by a governmental authority as the result of any such existing or imminent violation or contamination. In such case, Lessee shall upon request reimburse Lessor or Lessor's Lender, as the case may be, for the costs and expenses of such inspections.

  • Right of Inspection Buyer shall have the right to inspect the goods at the time and place of delivery, and within 5 business days after delivery, Buyer must give notice to Seller of any claim for damages on account of the condition, quality, or grade of the goods, and Buyer must specify in detail the basis of such claim. The failure of Buyer to comply with these conditions shall constitute irrevocable acceptance of the goods by Buyer.

  • Books and Records; Inspection and Examination The Borrower will keep accurate books of record and account for itself pertaining to the Collateral and pertaining to the Borrower's business and financial condition and such other matters as the Lender may from time to time request in which true and complete entries will be made in accordance with GAAP and, upon the Lender's request, will permit any officer, employee, attorney or accountant for the Lender to audit, review, make extracts from or copy any and all corporate and financial books and records of the Borrower at all times during ordinary business hours, to send and discuss with account debtors and other obligors requests for verification of amounts owed to the Borrower, and to discuss the Borrower's affairs with any of its directors, officers, employees or agents. The Borrower will permit the Lender, or its employees, accountants, attorneys or agents, to examine and inspect any Collateral, other collateral covered by the Security Documents or any other property of the Borrower at any time during ordinary business hours.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!