Scope of Landlords Responsibilities
Scope of Landlords Responsibilities Sample Clauses
Related to Scope of Landlords Responsibilities
Landlord’s Responsibilities (a) Landlord shall correct, repair or replace, at Landlord's sole cost and expense and not as a Project Cost, any non-compliance of the Building exterior and the Common Areas with all applicable building permits and codes in effect as of the Commencement Date, including, without limitation, the provisions of Title III of the Americans With Disabilities Act ("ADA") in effect as of the Commencement Date. Said costs of compliance shall be Landlord's sole cost and shall not be part of Project Costs. Landlord shall correct, repair or replace any non-compliance of the Building exterior and the Common Areas with any revisions or amendments to the ADA in effect after the Commencement Date, provided that the amortized cost of such repairs or replacements (amortized over the useful life thereof using a market cost of funds reasonably determined by Landlord) shall be included as Project Costs payable by Tenant. All other ADA compliance issues which pertain to the Premises, including, without limitation, in connection with Tenant's construction of any alterations or other improvements in the Premises (and any resulting ADA compliance requirements in the Common Areas), the Tenant Improvements and the operation of Tenant's business and employment practices in the Premises, shall be the responsibility of Tenant at its sole cost and expense. Landlord shall, during the initial Lease Term, correct, repair or replace, at Landlord's sole cost and expense and not as a Project Cost, any failure of the structural components of the roof, foundations, footings and load-bearing walls of the Building. The repairs, corrections or replacements required of Landlord or of Tenant under the foregoing provisions of this Section 2.4 shall be made promptly following notice of non-compliance from any applicable governmental agency. (b) Landlord warrants to Tenant that the Shell Building Improvements as defined in the Discovery Outline Specifications (as defined in the Work Letter) and the Tenant Improvements to be completed pursuant to the Work Letter shall be free from defects in workmanship or materials for a period of twelve (12) months from the Commencement Date. Landlord shall promptly rectify any non-compliance at its sole cost and expense after receipt of written notice from Tenant within such time setting forth the nature and extent of any such non-compliance. Landlord shall obtain customary warranties and guaranties from the contractor(s) performing the Tenant Improvement work and/or the manufacturers of equipment installed but shall be under no obligation to incur additional expense in order to obtain or extend such warranties. If after expiration of the initial twelve (12) months of the Lease Term, Tenant is required to make repairs to any component of the Premises or any of its systems for which Landlord may have obtained a warranty, Landlord shall, upon request by Tenant, use its good faith efforts to pursue its rights under any such warranties for the benefit of Tenant. Landlord shall be under no obligation to incur any expense in connection with asserting rights under such warranties or guaranties against either the contractor or the manufacturer, but shall use reasonable good faith efforts to enforce such warranties and guaranties for Tenant's benefit. (c) Notwithstanding the provisions of Section 7.2 of this Lease, Landlord agrees to maintain and repair, at its sole cost and expense and not as an Operating Expense the structural components of the roof and Building, including floor/ceiling slabs, columns, beams, walls and the foundations and footings of the Building during the initial Lease Term. If a non-compliance with the foregoing warranty exists, Landlord shall, promptly after receipt of the written notice from Tenant setting forth the nature and extent of such non-compliance, rectify same at Landlord's sole cost and expense.
Landlord’s Responsibility During the term of this Lease, Landlord shall maintain in good condition and repair, and replace as necessary, the roof, exterior walls, foundation and structural frame of the Building and the parking and landscaped areas, the costs of which shall be included in Operating Expenses; provided, however, that to the extent any of the foregoing items require repair because of the negligence, misuse, or default of Tenant, its employees, agents, customers or invitees, Landlord shall make such repairs solely at Tenant's expense.
Tenant’s Responsibilities Except as expressly provided in Paragraph 10.1 above, Tenant shall, at its sole cost, maintain the entire Premises and every part thereof, including without limitation, windows, skylights, window frames, plate glass, freight docks, doors and related hardware, interior walls and partitions, and the electrical, plumbing, lighting, heating and air conditioning systems in good order, condition and repair. Tenant shall deliver to Landlord, every six (6) months during the Lease Term, a certificate of maintenance or its equivalent, signed by a licensed HVAC repair and maintenance contractor and stating that the heating and air conditioning systems servicing the Premises have been inspected, serviced and are in good order, condition and repair. Tenant's failure to deliver said certificate or its equivalent within thirty (30) days following written notice from Landlord that said certificate is past due shall be a Default by Tenant. If Tenant fails to make repairs or perform maintenance work required of Tenant hereunder within fifteen (15) days after notice from Landlord specifying the need for such repairs or maintenance work, Landlord or Landlord's agents may, in addition to all other rights and remedies available hereunder or by law and without waiving any alternative remedies, enter into the Premises and make such repairs and/or perform such maintenance work. If Landlord makes such repairs and/or performs such maintenance work, Tenant shall reimburse Landlord upon demand and as Additional Rent, for the cost of such repairs and/or maintenance work. Landlord shall have no liability to Tenant for any damage, inconvenience or interference with the use of the Premises by Tenant or Tenant's agents as a result of Landlord performing any such repairs or maintenance (unless such damage, inconvenience or interference is caused by the gross negligence or willful misconduct of Landlord or its agents, employees or contractors); provided, however, under no circumstances shall Landlord be liable to Tenant for claims of lost profits, loss of business or lost income. Tenant shall reimburse Landlord, on demand and as Additional Rent, for the cost of damage to the Premises and/or Common Area caused by Tenant or Tenant's agents, employees or contractors. Tenant expressly waives the benefits of any statute now or hereafter in effect (including without limitation the provisions of subsection 1 of Section 1932, Section 1941 and Section 1942 of the California Civil Code and any similar law, statute or ordinance now or hereafter in effect) which would otherwise afford Tenant the right to make repairs at Landlord's expense (or to deduct the cost of such repairs from Rentals due hereunder) or to terminate this Lease because of Landlord's failure to keep the Premises in good and sanitary order.
Tenant Responsibilities Tenant will keep the Leased Premises and the fixtures and equipment therein in good order and condition, will take good care thereof and will suffer no waste or damage thereto. Tenant will promptly repair at its own expense any damage to the Leased Premises caused by bringing into the premises any property for Tenant's use or by the installation or removal of such property, regardless of fault or by who such damage shall be caused, unless caused by Landlord, its agents, employees or contractors; and, in default of such repairs by Tenant, Landlord shall make the same and Tenant agrees to pay the costs thereof to Landlord promptly upon Landlord's demand therefor. At the expiration or other termination of the Lease Term, Tenant will surrender the Leased Premises broom clean and in the same order and condition in which they were on the Rent Commencement Date, ordinary wear and tear excepted. All repairs and maintenance required to be performed by Tenant shall be made or performed immediately upon the occurrence of the necessity therefor, and shall be made or performed in a first class manner, using first class materials, by a contractor approved by Landlord and bonded unless waived by Landlord, and shall be made or performed in accordance with (i) all laws and all applicable governmental codes and requirements, and (ii) insurance requirements. Maintenance and repair of equipment such as kitchen fixtures, auxiliary air-conditioning equipment, private bathroom fixtures and any other type of special equipment, together with related plumbing or electrical services, whether installed by Tenant or by Landlord on behalf of Tenant, shall be the sole responsibility of Tenant, and Landlord shall have no obligation in connection therewith. If Tenant refuses or neglects to promptly commence and complete repairs or maintenance necessary to satisfy the provisions of this Section, the Landlord may, but shall not be required to, make and complete said repairs or maintenance and Tenant shall pay the cost therefor (including overhead) to Landlord upon demand, as Additional Rent.
Tenant’s Responsibility (a) Except to the extent contributed to by a Landlord Party and except for those matters listed in Section 9.5(a) for which the Landlord shall be responsible, the Tenant shall be solely responsible and liable for any work required by any governmental authority having jurisdiction with respect to any Contaminants on, in or under the Premises during the Term of the Lease. Except (i) as caused by or contributed to by a Landlord Party, and (ii) for those matters listed in Section 9.5(a), the Tenant shall indemnify, defend (utilizing counsel satisfactory to the Landlord) and hold harmless the Landlord and the Landlord’s respective officers, directors, beneficiaries, shareholders, partners, agents and employees from all Claims arising out of or in any way connected with any Release of any Contaminants that occurs during the Term of this Lease, at, in, on, from, under, or about the Premises or the Building, or which arises at any time from the Tenant’s use or occupancy of the Premises, or from the Tenant’s failure to provide all information, make all submissions, and take steps required by all authorities under Environmental Law. (b) Upon the occurrence of any material Release of a Contaminant at the Premises and upon the Tenant becoming aware of such Release, the Tenant shall immediately give written notice to the Landlord. In any event, the Tenant shall immediately take all steps required by Environmental Law to remedy or otherwise address the situation giving rise to any Release. (c) If any work is required in accordance with this section 9.2 the Tenant shall prepare all necessary studies, plans and proposals and submit them to the Landlord for approval, which approved shall not be unreasonably withheld, provide all bonds and other security required by any lawful governmental authorities and carry out the work required. In carrying out such work, the Tenant shall keep the Landlord fully informed of the progress of the work. If the Landlord has reasonable grounds for believing that the Tenant will not promptly or properly carry out such work, the Landlord may, in its sole discretion, elect to carry out all such work, or any part of it, and if the Landlord does so, the Tenant shall pay for all costs in connection therewith, within thirty (30) days after the Landlord has incurred the costs and made written demand to the Tenant. (d) The Tenant covenants, acknowledges and agrees that its obligations and liabilities under this Section shall survive the expiration or earlier termination of this Lease.
Tenant Responsibility Good housekeeping is expected of everyone. Tenant agrees to keep quarters clean and in a sanitary condition. The Tenants agree not to permit any deterioration or destruction to occur while they are occupying the property.
ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Construction Responsibilities The party named in Article 1, Responsible Parties, under AGREEMENT is responsible for the following: A. Advertise for construction bids, issue bid proposals, receive and tabulate the bids, and award and administer the contract for construction of the Project. Administration of the contract includes the responsibility for construction engineering and for issuance of any change orders, supplemental agreements, amendments, or additional work orders that may become necessary subsequent to the award of the construction contract. In order to ensure federal funding eligibility, projects must be authorized by the State prior to advertising for construction. B. If the State is the responsible party, the State will use its approved contract letting and award procedures to let and award the construction contract. C. If the Local Government is the responsible party, the Local Government shall submit its contract letting and award procedures to the State for review and approval prior to letting. D. If the Local Government is the responsible party, the State must concur with the low bidder selection before the Local Government can enter into a contract with the vendor. E. If the Local Government is the responsible party, the State must review and approve change orders. F. Upon completion of the Project, the party responsible for constructing the Project will issue and sign a “Notification of Completion” acknowledging the Project’s construction completion and submit certification(s) sealed by a professional engineer(s) licensed in the State of Texas. G. For federally funded contracts, the parties to this Agreement will comply with federal construction requirements cited in 23 CFR Part 635 and with requirements cited in 23 CFR Part 633, and shall include the latest version of Form “FHWA-1273” in the contract bidding documents. If force account work will be performed, a finding of cost effectiveness shall be made in compliance with 23 CFR 635, Subpart B.
Owner Responsibilities The project owner or the engineer or architect of record acting as the owner’s agent shall fund special inspection services.
OWNER’S RESPONSIBILITIES 2.1. The Owner shall designate in writing a project coordinator to act as OWNER's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Coordinator"). The Project Coordinator shall have authority to transmit instructions, receive information, interpret and define OWNER's policies and decisions with respect to CONTRACTOR's services for the Project. However, the Project Coordinator is not authorized to issue any verbal or written orders or instructions to the CONTRACTOR that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: (a) The scope of services to be provided and performed by the CONTRACTOR hereunder; (b) The time the CONTRACTOR is obligated to commence and complete all such services; or (c) The amount of compensation the OWNER is obligated or committed to pay the CONTRACTOR. 2.2. The Project Coordinator shall: (a) Review and make appropriate recommendations on all requests submitted by the CONTRACTOR for payment for services and work provided and performed in accordance with this Agreement; (b) Arrange for access to and make all provisions for CONTRACTOR to enter the Project site to perform the services to be provided by CONTRACTOR under this Agreement; and (c) Provide notice to CONTRACTOR of any deficiencies or defects discovered by the OWNER with respect to the services to be rendered by CONTRACTOR hereunder. 2.3. CONTRACTOR acknowledges that access to the Project Site, to be arranged by OWNER for CONTRACTOR, may be provided during times that are not the normal business hours of the CONTRACTOR. 3.1. Services to be rendered by CONTRACTOR shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from OWNER for all or any designated portion of the Project and shall be performed and completed by September 30, 2005. Based on the mutual agreement of both parties, this contract may be renewed a maximum of two one-year periods thereafter. 3.2. Should CONTRACTOR be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to its own fault or neglect, including but not restricted to acts of God or of public enemy, acts of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONTRACTOR shall notify OWNER in writing within five (5) working days after commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. 3.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONTRACTOR's services from any cause whatsoever, including those for which OWNER may be responsible in whole or in part, shall relieve CONTRACTOR of its duty to perform or give rise to any right to damages or additional compensation from OWNER. XXXXXXXXXX's sole remedy against OWNER will be the right to seek an extension of time to its schedule. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of the CONTRACTOR, the services to be provided hereunder have not been completed within 18 months of the date hereof, the CONTRACTOR's compensation may be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONTRACTOR after expiration of said 18 month period. 3.4. Should the CONTRACTOR fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely and reasonable manner, in addition to any other rights or remedies available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold any and all payments due and owing to the CONTRACTOR until such time as the CONTRACTOR resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the OWNER's satisfaction that the CONTRACTOR's performance is or will shortly be back on schedule.
