Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever. (ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties. (iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority. (iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i). (v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party. (vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway. (vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
Management and Control Systems Grantee will: 1. maintain an appropriate contract administration system to ensure that all terms, conditions, and specifications are met during the term of the contract through the completion of the closeout procedures. 2. develop, implement, and maintain financial management and control systems that meet or exceed the requirements of Uniform Statewide Accounting System (UGMS). Those requirements and procedures include, at a minimum, the following: i. Financial planning, including the development of budgets that adequately reflect all functions and resources necessary to carry out authorized activities and the adequate determination of costs; ii. Financial management systems that include accurate accounting records that are accessible and identify the source and application of funds provided under each Contract of this Contract, and original source documentation substantiating that costs are specifically and solely allocable to a Contract and its Contract and are traceable from the transaction to the general ledger; iii. Effective internal and budgetary controls; iv. Comparison of actual costs to budget; determination of reasonableness, allowableness, and allocability of costs; v. Timely and appropriate audits and resolution of any findings; vi. Billing and collection policies; and vii. Mechanism capable of billing and making reasonable efforts to collect from clients and third parties.
Records Maintenance; Access Contractor shall maintain all financial records relating to this Contract in accordance with generally accepted accounting principles. In addition, Contractor shall maintain any other records, books, documents, papers, plans, records of shipments and payments and writings of Contractor, whether in paper, electronic or other form, that are pertinent to this Contract (“Records”) in such a manner as to clearly document Contractor's performance. Contractor acknowledges and agrees that Agency and the Oregon Secretary of State's Office and the federal government and their duly authorized representatives will have access to such financial records and other Records that are pertinent to this Contract, whether in paper, electronic or other form, to perform examinations and audits and make excerpts and transcripts. Contractor shall retain and keep accessible all such financial records and other Records for a minimum of 6 years, or such longer period as may be required by applicable law, following final payment and termination of this Contract, or until the conclusion of any audit, controversy or litigation arising out of or related to this Contract, whichever date is later.
Site Access Dell requires the right to access the APEX System in a timely way and as provided in the Service Offering Description to provide the Support Services. Failure to ensure that Customer provides Dell with timely access to a Site will relieve Dell of the Support Services obligations and Dell may also, at Dell’s discretion, suspend the APEX Service.
Wastewater investments in the construction, material enhancement, or renewal of infrastructure that supports wastewater and storm water collection, treatment, and management systems. Note: Investments in health infrastructure (e.g., hospitals, long-term care facilities, convalescent centres, and senior centres) are not eligible. Eligible Expenditures will be limited to the following: 1. Infrastructure investments – expenditures associated with acquiring, planning, designing, constructing, or renovating a tangible capital asset and any related debt financing charges specifically identified with that asset. 2. Capacity-building costs – for projects eligible under the capacity-building category only, expenditures associated with the development and implementation of: • Capital investment plans, integrated community sustainability plans, integrated regional plans, housing needs assessments, or asset management plans; • Studies, strategies, systems, software, third-party assessments, plans, or training related to asset management; • Studies, strategies, systems, or plans related to housing or land use; • Studies, strategies, or plans related to the long-term management of infrastructure; and • Other initiatives that strengthen the Recipient’s ability to improve local and regional planning. 3. Joint communications and signage costs – expenditures directly associated with joint federal communication activities and with federal project signage.
Drainage Systems (1) Clear culvert inlets, outlets, and sediment catching basins. (2) Maintain waterbars, drainage dips, and other water diversion measures. (3) During active use, patrol and maintain functional drainage. (4) Repair damaged culvert ends.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Claims Handling If a credible claim is made or threatened, for which Newegg is entitled to indemnification from Seller including without limitation the filing of a lawsuit against Newegg, or the receipt of a demand or notice by Newegg or Newegg elects to defend any claim for which Newegg is entitled to indemnification: 12.2.1. Newegg shall have the right to engage counsel of its choosing that Newegg deems, in its sole discretion, to be necessary for a competent defense of the suit; 12.2.2. Newegg shall pay all legal fees and expenses incurred in defense of the claim or suit as they become due. Seller shall reimburse Newegg for such fees and expenses within thirty (30) days from date of invoice or debit memo from Newegg. After thirty (30) days, Newegg will be entitled to deduct any unpaid invoice or debit memo amount from any amounts owed by Newegg to Seller. This shall not apply to any judgment or settlement amount, which amounts Newegg shall be entitled to notify, invoice or debit Seller's account at any time. 12.2.3. In the event a claim is made or a suit is filed directly against Newegg, and Newegg is defending such claim or suit, then Newegg, in its sole discretion, may settle the claim or suit. If Seller is defending the claim or suit, Seller may not settle the claim of suit absent the written consent of Newegg unless such settlement (i) includes a release of all claims pending against Newegg; (ii) contains no admission of liability or wrongdoing by Newegg; and (iii) imposes no obligations upon Newegg other than an obligation to stop selling any infringing items. Newegg agrees to provide reasonable assistance to Seller, at Seller's expense, regarding such claim or action.
Access Toll Connecting Trunk Group Architecture 9.2.1 If CSTC chooses to subtend a Verizon access Tandem, CSTC’s NPA/NXX must be assigned by CSTC to subtend the same Verizon access Tandem that a Verizon NPA/NXX serving the same Rate Center Area subtends as identified in the LERG. 9.2.2 CSTC shall establish Access Toll Connecting Trunks pursuant to applicable access Tariffs by which it will provide Switched Exchange Access Services to Interexchange Carriers to enable such Interexchange Carriers to originate and terminate traffic to and from CSTC’s Customers. 9.2.3 The Access Toll Connecting Trunks shall be two-way trunks. Such trunks shall connect the End Office CSTC utilizes to provide Telephone Exchange Service and Switched Exchange Access to its Customers in a given LATA to the access Tandem(s) Verizon utilizes to provide Exchange Access in such LATA. 9.2.4 Access Toll Connecting Trunks shall be used solely for the transmission and routing of Exchange Access to allow CSTC’s Customers to connect to or be connected to the interexchange trunks of any Interexchange Carrier which is connected to a Verizon access Tandem.
