Attorneys’ Fees and Costs of Collection Guarantor shall pay on demand all attorneys' fees and all other costs and expenses incurred by Lender in the enforcement of or preservation of Lender's rights under this Guaranty including, without limitation, all reasonable attorneys' fees and expenses, investigation costs, and all court costs, whether or not suit is filed herein, or whether at maturity or by acceleration, or whether before or after maturity, or whether in connection with bankruptcy, insolvency or appeal, or whether in connection with the collection and enforcement of this Guaranty against any other Guarantor, if there be more than one. Guarantor agrees to pay interest on any expenses or other sums due to Lender under this Section 10 that are not paid when due, at a rate per annum equal to the interest rate provided for in the Note. Guarantor's obligations and liabilities under this Section 10 shall survive any payment or discharge in full of the Guaranteed Obligations.
Allocation of Costs and Expenses The Company shall bear all costs and expenses for the administration of its business and shall reimburse the Advisor for any such costs and expenses that have been paid by the Advisor, or by any affiliate thereof, on behalf of the Company on the terms and conditions set forth in Section 6. These costs and expenses shall include, but not be limited to:
Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.
Construction Costs Tenant shall pay for all construction costs, including, but not limited to permits, costs of materials and labor, sales tax, construction management fees and the like except to the extent of the Tenant Improvement Allowance which shall be paid by Landlord. The term “Tenant Improvement Allowance” shall mean the sum of $316,020.00 (or $15.00 per square foot of rentable area times 21,068 square feet of rentable area) which Landlord agrees to pay towards the construction costs. Landlord agrees to pay architectural fees and design services up to $1.25 per rentable square foot. Any services performed by the architect above the $1.25 per rentable square foot shall be the responsibility of the Tenant and may be paid out of the Tenant Improvement Allowance to the extent funds are available. Notwithstanding anything to the contrary, provided there is any unused portion of the Tenant Improvement Allowance, up to 20% of the allowance can be used by the Tenant as a moving allowance or for communications costs for cabling and data. Tenant must submit invoices for such allowances for Landlord to pay. Xxxxxx Development will act as General Contractor for the construction of tenant improvements, competitively bidding each trade to at least three subcontractors, the typical five percent (5%) construction management fee will not be charged to Tenant or deducted from the Tenant Improvement Allowance. Landlord shall obtain bids based on the Approved Pricing Plans and construct the Work as described in the Approved Pricing Plans. If after finalizing the Approved Working Drawings, it is determined that the construction costs will exceed the amount of the Tenant Improvement Allowance (an “Excess”), then Tenant shall pay to Landlord the amount of such Excess within ten (10) days of written request from Landlord. Notwithstanding anything to the contrary, if Tenant fails to pay any Excess timely, Landlord shall not be obligated to commence construction of the Work and such delay shall constitute a Tenant Delay for each day beyond the ten (10) day period until the Excess is paid to Landlord. If Tenant elects not to use Xxxxxx Development as the General Contractor, Tenant understands that Landlord, or its designated agent, shall serve as construction manager for all of Tenant’s refurbishment and renovations in the refurbishment and renovations in the Premises and the fee for such service is 5% of the total cost of all work performed in connection with such refurbishment and renovations. Tenant agrees to cooperate with Landlord in completing any such improvements on a timely basis and Tenant has approved the preliminary space plan and pricing documentation. Additional space on the 3rd floor which Tenant elects to lease pursuant [****] = CERTAIN CONFIDENTIAL INFORMATION CONTAINED IN THIS DOCUMENT, MARKED BY BRACKETS, HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO RULE 406 OF THE SECURITIES ACT OF 1933, AS AMENDED. to a right hereunder shall be finished out by Landlord pursuant to mutually agreed upon plans and Tenant shall receive an allowance of $15.00 per square foot of rentable area provided, however, Tenant acknowledges that Landlord is improving the entire third (3rd) floor prior to commencement of the Lease and Tenant shall not be entitled to any additional tenant finish when Tenant leases the remainder of the third floor.
Payment of Costs and Fees The Borrower shall pay to the Administrative Agent all reasonable costs, out-of-pocket expenses, and fees and charges of every kind in connection with the preparation, negotiation, execution and delivery of this Amendment and any documents and instruments relating hereto (which costs include, without limitation, the reasonable fees and expenses of any attorneys retained by the Administrative Agent) to the extent provided in Section 10.5 of the Credit Agreement.
Allocation of Costs The Fund shall pay the cost of composition and printing of sufficient copies of its Prospectus and SAI as shall be required for periodic distribution to its shareholders and the expense of registering Shares for sale under federal securities laws. You shall pay the expenses normally attributable to the sale of Shares, other than as paid under the Fund's Distribution Plan under Rule 12b-1 of the 1940 Act, including the cost of printing and mailing of the Prospectus (other than those furnished to existing shareholders) and any sales literature used by you in the public sale of the Shares and for registering such shares under state blue sky laws pursuant to paragraph 8.
Attorneys’ Fees and Cost of Collection In the event any suit, action or arbitration is filed by either party against the other to interpret or enforce any of the Transaction Documents, the unsuccessful party to such action agrees to pay to the prevailing party all costs and expenses, including attorneys’ fees incurred therein, including the same with respect to an appeal. The “prevailing party” shall be the party in whose favor a judgment is entered, regardless of whether judgment is entered on all claims asserted by such party and regardless of the amount of the judgment; or where, due to the assertion of counterclaims, judgments are entered in favor of and against both parties, then the arbitrator shall determine the “prevailing party” by taking into account the relative dollar amounts of the judgments or, if the judgments involve nonmonetary relief, the relative importance and value of such relief. Nothing herein shall restrict or impair an arbitrator’s or a court’s power to award fees and expenses for frivolous or bad faith pleading. If (i) the Note is placed in the hands of an attorney for collection or enforcement prior to commencing arbitration or legal proceedings, or is collected or enforced through any arbitration or legal proceeding, or Investor otherwise takes action to collect amounts due under the Note or to enforce the provisions of the Note, or (ii) there occurs any bankruptcy, reorganization, receivership of Company or other proceedings affecting Company’s creditors’ rights and involving a claim under the Note; then Company shall pay the costs incurred by Investor for such collection, enforcement or action or in connection with such bankruptcy, reorganization, receivership or other proceeding, including, without limitation, attorneys’ fees, expenses, deposition costs, and disbursements.
Allocation of Overhead To the extent that Borrower, on the one hand, and the Servicer, the Parent, the Performance Guarantor, any Originator or any Affiliate thereof, on the other hand, have offices in the same location, there shall be a fair and appropriate allocation of overhead costs between them, and the Borrower shall bear its fair share of such expenses, which may be paid through the Servicing Fee or otherwise.
Maintenance and Repair; Return (a) Lessee, at its sole cost and expense, shall maintain each Property in good condition, repair and working order (ordinary wear and tear excepted) and in the repair and condition as when originally delivered to Lessor and make all necessary repairs thereto and replacements thereof, of every kind and nature whatsoever, whether interior or exterior, ordinary or extraordinary, structural or nonstructural or foreseen or unforeseen, in each case as required by Section 9.1 and on a basis consistent with the operation and maintenance of properties or equipment comparable in type and function to the applicable Property, such that such Property is capable of being immediately utilized by a third party and in compliance with standard industry practice subject, however, to the provisions of Article XV with respect to Casualty and Condemnation.
Commencement of Construction Construction of the Project will start within thirty (30) days after notification to the Developer by the Owner, or as soon thereafter as weather and ground conditions permit.
