Shortages, Overshipments, Non-Conformance in Orders Sample Clauses

Shortages, Overshipments, Non-Conformance in Orders. 4.5.1 The Buyer shall immediately and not later than thirty (30) days after receipt of Material delivered pursuant to a purchase order advise the Seller: a) of any alleged shortages or overshipments with respect to such order, b) of all non-conformance to specification of parts in such order subjected to inspections by the Buyer. In the event of the Buyer not having advised the Seller of any such alleged shortages, overshipments or non-conformance within the above defined period, the Buyer shall be deemed to have accepted the deliveries. 4.5.2 In the event of the Buyer reporting overshipments or non-conformance to the specifications within the period defined in sub-Clause 4.5.1 of this Exhibit “E” the Seller shall, if accepted, either replace the concerned Material or credit the Buyer for the returned Material. In such case, transportation costs shall be borne by the Seller. The Buyer shall endeavour to minimize such costs, particularly through the use of its own airfreight system for transportation at no charge to the Seller.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to Shortages, Overshipments, Non-Conformance in Orders

  • Mail Order Catalog Warnings In the event that, the Settling Entity prints new catalogs and sells units of the Products via mail order through such catalogs to California consumers or through its customers, the Settling Entity shall provide a warning for each unit of such Product both on the label in accordance with subsection 2.4 above, and in the catalog in a manner that clearly associates the warning with the specific Product being purchased. Any warning provided in a mail order catalog shall be in the same type size or larger than other consumer information conveyed for such Product within the catalog and shall be located on the same display page of the item. The catalog warning may use the Short-Form Warning content described in subsection 2.3(b) if the language provided on the Product label also uses the Short-Form Warning.

  • Order Rejections 53.11.1 CenturyLink shall reject and return to CLEC any order that CenturyLink cannot provision, due to technical reasons, missing information, or jeopardy conditions resulting from CLEC ordering service at less than the standard order interval. 53.11.2 When an order is rejected, CenturyLink will, in its reject notification, describe the existing reasons for which the order was rejected.

  • Purchase Order Duration Purchase orders issued pursuant to this State Term Contract must be received by the Contractor no later than close of business on the last day of the Contract’s term to be considered timely. The Contractor is obliged to fill those orders in accordance with the Contract’s terms and conditions. Purchase orders received by the Contractor after close of business on the last day of the State Term Contract’s term shall be considered void. Purchase orders for a one-time performance of contractual services shall be valid through the performance by the Contractor, and all terms and conditions of the State Term Contract shall apply to the single delivery/performance, and shall survive the termination of the Contract. Contractors are required to accept purchase orders specifying delivery schedules exceeding the contracted schedule even when such extended delivery will occur after expiration of the State Term Contract. For example, if a state term contract calls for delivery 30 days after receipt of order (ARO), and an order specifies delivery will occur both in excess of 30 days ARO and after expiration of the state term contract, the Contractor will accept the order. However, if the Contractor expressly and in writing notifies the ordering office within ten (10) calendar days of receipt of the purchase order that Contractor will not accept the extended delivery terms beyond the expiration of the state term contract, then the purchase order will either be amended in writing by the ordering entity within ten (10) calendar days of receipt of the contractor’s notice to reflect the state term contract delivery schedule, or it shall be considered withdrawn. The duration of purchase orders for recurring deliveries of commodities or performance of services shall not exceed the expiration of the State Term Contract by more than twelve months. However, if an extended pricing plan offered in the State Term Contract is selected by the Customer, the Contract terms on pricing plans shall govern the maximum duration of purchase orders reflecting such pricing plans. Timely purchase orders shall be valid through their specified term and performance by the Contractor, and all terms and conditions of the State Term Contract shall apply to the recurring delivery/performance as provided herein, and shall survive the termination of the Contract. Ordering offices shall not renew a purchase order issued pursuant to a State Term Contract if the underlying contract expires prior to the effective date of the renewal.

  • Order to Stop Work The Chief Procurement Officer, may, by written order to Contractor at any time, and without notice to any surety, require Contractor to stop all or any part of the work called for by this contract. This order shall be for a specified period not exceeding 90 days after the order is delivered to Contractor, unless the parties agree to any further period. Any such order shall be identified specifically as a stop work order issued pursuant to this clause. Upon receipt of such an order, Contractor shall forthwith comply with its terms and take all reasonable steps to minimize the occurrence of costs allocable to the work covered by the order during the period of work stoppage. Before the stop work order expires, or within any further period to which the parties shall have agreed, the Chief Procurement Officer shall either: i. cancel the stop work order; or, ii. terminate the work covered by such order as provided in the Termination for Default clause or the Termination for Convenience clause of this contract.

  • Grievance Processing Union stewards or Union officials shall be permitted to have time off without loss of pay for the investigation and processing of grievances and arbitrations. Requests for such time off shall be made in advance and shall not be unreasonably denied. The Union will furnish the Employer with a list of Union stewards and their jurisdictions. The Union shall delineate the jurisdiction of Union stewards so that no xxxxxxx need travel between work locations or sub-divisions thereof while investigating grievances. Grievants shall be permitted to have time off without loss of pay for processing their grievances through the contractual grievance procedure, except that for class action grievances no more than three (3) grievants shall be granted such leave.

  • Shipments The Vendor shall ship, deliver or provide ordered products or services within a commercially reasonable time after the receipt of the order from the TIPS Member. If a delay in said delivery is anticipated, the Vendor shall notify TIPS Member as to why delivery is delayed and shall provide an estimated time for completion of the order. TIPS or the requesting entity may cancel the order if estimated delivery time is not acceptable or not as agreed by the parties.

  • Accuracy of Orders; Customer Signatures You shall be responsible for the accuracy, timeliness and completeness of any orders transmitted by you on behalf of your customers by any means, including wire or telephone. In addition, you agree to guarantee the signatures of your customers when such guarantee is required by the Company and you agree to indemnify and hold harmless all persons, including us and the Funds’ transfer agent, from and against any and all loss, cost, damage or expense suffered or incurred in reliance upon such signature guarantee.

  • Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.

  • ODUF Packing Specifications 6.3.1 A pack will contain a minimum of one message record or a maximum of 99,999 message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of 99 packs and a minimum of one pack.

  • Shipment Dell will ship the APEX System to the Site when included as part of the APEX Service. The terms and process for shipment and delivery of the APEX System will be stated in the applicable Service Offering Description.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!