Significant Defects Sample Clauses

Significant Defects. ‌ (a) Seller warrants and guarantees to Buyer that there will be no Significant Defects.
Sample 1Sample 2Sample 3See All (6)
Significant Defects. Developer warrants and guarantees to PacifiCorp that there will be no Significant Defects. In the event that a Significant Defect occurs, Developer shall cure or otherwise make good the Significant Defect.
Sample 1Sample 2Sample 3
Significant Defects. (a) Contractor warrants and guarantees to Company that there will be no Significant Defects.
Sample 1

Related to Significant Defects

  • Latent Defects Notwithstanding anything to the contrary set forth herein, no acceptance, or deemed acceptance, by City pursuant to this Section shall be applicable with respect to any Latent Defects. An acceptance, or deemed acceptance, by City pursuant to this Section shall not mean that City has accepted, or the other party has been relieved of, responsibility for: (i) compliance with the Laws; (ii) the proper application of construction means or methods; or (iii) correcting any portion of the Project if it later is determined that any portion of the Project is inconsistent with the Final Documents and Drawings.

  • Environmental Defects If Buyer determines that with respect to the Asset there exists an Environmental Condition (other than with respect to asbestos, asbestos containing materials, or NORM, and excluding any matter set forth on Schedule 6.10) (in each case, an “Environmental Defect”), then on or prior to the Defect Claim Date, Buyer may give Seller a written notice of such Environmental Defect that sets forth the information required by this Section 3.17 (an “Environmental Defect Notice”). For all purposes of this Agreement and notwithstanding anything herein to the contrary, Buyer shall be deemed to have waived any Environmental Defect that Buyer fails to timely and properly assert as an Environmental Defect by an Environmental Defect Notice received by Seller on or before the Defect Claim Date. To be effective, an Environmental Defect Notice must set forth (a) a clear description of the matter constituting the alleged Environmental Defect, (b) a description of each Asset (or portion thereof) affected by the alleged Environmental Defect, (c) the estimated proportionate share attributable to the Assets of the estimated Lowest Cost Response to eliminate the alleged Environmental Defect (the “Environmental Defect Amount”), and (d) supporting documents and reasonably necessary for Seller to verify the existence of the alleged Environmental Defect and the Environmental Defect Amount. Buyer shall furnish Seller, on or before the end of each calendar week prior to the Defect Claim Date, Environmental Defect Notices with respect to any Environmental Defects that any of Buyer’s or any of its Affiliate’s employees, representatives, attorneys, or other environmental personnel or contractors discover or become aware of during the preceding calendar week, which notice may be preliminary in nature and supplemented prior to the Defect Claim Date; provided that notwithstanding this sentence, any Environmental Defect Notice shall be deemed timely if received by Seller prior to the Defect Claim Date.

  • Defects If either party become aware of 5.4.1 any possible, actual or potential defect, containment, fault or other condition in Milk supplied under this Agreement; 5.4.2 any matter that may impact upon compliance with any health standard, public policy or code; 5.4.3 any matter which may affect compliance with any law or regulatory health standard; that party must, as soon as possible, advise the other party of the particulars of any such issue. The parties must cooperate, to the fullest extent possible, to diminish any risk to the public arising from a defect in Milk.

  • Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected. 35.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the length of time specified by the Engineer’s notice.

  • Cost of remedying Defects Any repair or rectification undertaken in accordance with the provisions of Clause 17.2, including any additional testing, shall be carried out by the Contractor at its own risk and cost, to the extent that such rectification or repair is attributable to: (a) the design of the Project; (b) Plant, Materials or workmanship not being in accordance with this Agreement and the Specifications and Standards; (c) improper maintenance during construction of the Project Highway by the Contractor; and/ or (d) failure by the Contractor to comply with any other obligation under this Agreement.

  • REMEDY OF DEFECTS (a) The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow. In such case, the VESSEL shall be taken at the BUYER's cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER's getting and keeping the VESSEL ready for such repairing or replacing. (b) However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice by email or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by email or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER's acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD. (c) In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the C.I.F terms to the BUYER's nominated port. The BUILDER reserves the option to retrieve, at the BUILDER's cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article. (d) Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.

  • Casualty Loss If in Owner’s reasonable judgment the premises or the Property is materially damaged by fire or other casualty, Owner may terminate this Agreement within a reasonable time after such determination, by written notice to Resident, in which case Owner will refund prorated, pre-paid rent and all deposits less lawful deductions unless Resident and/or Resident’s guest(s) caused the casualty, in which case all funds on account will be applied to all applicable charges related to the damages and Resident will be responsible for the balance of all charges for repairs. If following a fire or other casualty Owner has not elected to terminate this Agreement, Owner will rebuild the damaged areas within a reasonable time, and during such reconstruction, Resident will be provided a reasonable rent reduction for the unusable portion of the premises unless Resident and/or Resident’s guest(s) caused the casualty.

  • Risk of Loss/Condemnation Upon an occurrence of a casualty, condemnation or taking with respect to any Property, Seller shall notify Buyer in writing of same. Until Closing, the risk of loss or damage to the Property, except as otherwise expressly provided herein, shall be borne by Seller. In the event all or any portion of any Property is damaged in any casualty or condemned or taken (or notice of any condemnation or taking is issued) so that: (a) Tenant has a right of termination or abatement of rent under the Lease for such Property, or (b) with respect to any casualty, if the cost to repair such casualty would exceed $50,000, or (c) with respect to any condemnation, any Improvements or access to the Property or more than five percent (5%) of the Property is (or will be) condemned or taken, then, Buyer may elect to terminate this Agreement with respect to each such Property by providing written notice of such termination to Seller within ten (10) business days after Buyer’s receipt of notice of such condemnation, taking or damage, upon which termination a proportionate part of the Xxxxxxx Money shall be returned to the Buyer in accordance with the Purchase Price as set forth on Exhibit A1 and neither party hereto shall have any further rights, obligations or liabilities under this Agreement with respect to such Property, except as otherwise expressly set forth herein. With respect to any condemnation or taking (of any notice thereof), if Buyer does not elect to cancel this Agreement as aforesaid, there shall be no abatement of the Purchase Price and Seller shall assign to Buyer at the Closing the rights of Seller to the awards, if any, for the condemnation or taking, and Buyer shall be entitled to receive and keep all such awards. With respect to a casualty, if Buyer does not elect to terminate this Agreement with respect to any such Property or does not have the right to terminate this Agreement as aforesaid, there shall be no abatement of the Purchase Price and Seller shall assign to Buyer at the Closing the rights of Seller to the proceeds under Seller’s insurance policies covering such Property with respect to such damage or destruction (or pay to Buyer any such proceeds received prior to Closing) and pay to Buyer the amount of any deductible with respect thereto, and Buyer shall be entitled to receive and keep any monies received from such insurance policies.

  • Damage or Destruction If the Premises are partially damaged or destroyed by any casualty insured against under any insurance policy maintained by Landlord, Landlord shall repair the Premises to substantially the condition in which the Premises were immediately prior to such damage or destruction and collect insurance proceeds when dispensed. Lxxxxxxx’s obligation under the preceding sentence shall not exceed the lesser of the cost of the standard improvements installed by Landlord in the Premises, or the proceeds received by Landlord from any insurance policy maintained by Landlord. Until such repair is complete, the Basic Monthly Rent shall be abated proportionately commencing on the date of such damage or destruction as to that portion of the Premises rendered untenable, if any. If (a) by reason of such occurrence the Premises are rendered wholly untenable, (b) the Premises are damaged as a result of a risk not covered by insurance, (c) the Premises are damaged in whole or in part during the last twelve (12) months of the Term, (d) the Premises or the Building (whether or not the Premises are damaged) is damaged to the extent of twenty-five percent (25%) or more of the then-replacement value of either or to the extent that it would take, in Landlord’s opinion, in excess of ninety (90) days to complete the requisite repairs, or (e) insurance proceeds adequate to repair the Property are not available to Landlord for any reason, Landlord may either elect to repair the damage or cancel this Lease by notice of cancellation within thirty (30) days after such event, and on such notice Tenant shall vacate and surrender the Premises to Landlord. If Landlord elects to repair any such damage, any abatement of Basic Monthly Rent shall end on notice given by Landlord to Tenant that the Premises have been repaired. If the damage is caused by the negligence of Tenant or Tenant’s Occupants, Basic Monthly Rent shall not axxxx. Except for abatement of Basic Monthly Rent, if any, Tenant shall have no claim against Landlord for any loss suffered by reason of any such damage, destruction, repair or restoration, nor may Tenant terminate this Lease as the result of any statutory provision in effect on or after the date of this Lease pertaining to the damage and destruction of the Premises or the Building. The proceeds of all insurance carried by Tenant on Tenant’s furnishings, trade fixtures, leasehold improvements, equipment and other personal property shall be held in trust by Tenant for the purpose of the repair and replacement of the same. Landlord shall not be required to repair any damage to, or to make any restoration or replacement of, any furnishings, trade fixtures, leasehold improvements, equipment and other personal property installed in the Premises by Tenant or at the direct or indirect expense of Tenant. Unless this Lease is terminated by Landlord pursuant to this Paragraph, Tenant shall be required to restore or replace such furnishings, trade fixtures, leasehold improvements, equipment and other personal property on damage or destruction in at least a condition equal to that existing prior to such event.

  • Damage or Destruction Condemnation (a) In the event the Assigned Space or the improvements thereon are damaged by any casualty which is required to be insured against by Permittee pursuant to this Permit, then Permittee shall, in accordance with all applicable requirements of this Permit (including without limitation Section 1(2) above), repair such damage (and replace any Trade Equipment damaged by such casualty) as soon as reasonable possible, at its own cost, and this Permit shall continue in full force and effect, with no abatement in the Rent payable by Permittee to Port under Paragraph E of this Permit. (b) In the event the Assigned Space or the improvements thereon are damaged by any casualty which is not required to be insured against by Permittee pursuant to the provisions of this Permit, then Port may, at Port’s option, either (i) repair such damage as soon as reasonably possible at Port’s expense, in which event this Permit shall continue in full force and effect, and there shall be no abatement in the Rent payable by Permittee to Port under Paragraph E of this Permit, or (ii) give written notice to Permittee within sixty (60) days after the date of occurrence of such damage of Port’s intention to terminate this Permit, in which event such termination shall be effective as of the date of the occurrence of such damage; provided, however, that notwithstanding the foregoing: (x) If such damage was caused by the act or omission of Permittee or any principal, affiliate, contractor, employee, agent, licensee or invitee of Permittee, then Permittee shall, in accordance with all applicable provisions of this Permit (including without limitation Section 1(2) above), repair such damage promptly and at its sole cost and expense, this Permit shall remain in full force and effect, and there shall be no abatement in the Rent payable by Permittee to Port under Paragraph E above; and (y) If such damage is not covered by subsection (b)(ii)(x) above, and if such damage occurred during the last twelve months of the Term, then either party shall have the right, by written notice given to the other within sixty (60) days after the date of occurrence of such damage, to terminate this Permit as of the date of such damage, in which event all proceeds of the insurance against casualty that Permittee was required to maintain pursuant to this Permit shall be paid to Port. (c) If the Assigned Space is damaged or destroyed by casualty, Permittee shall have no claim against Port for any damage suffered by reason of any such damage or destruction, or for any required repair or restoration. Port and Permittee hereby waive the provisions of California Civil Code Sections 1932 and 1933, and of any other statutes which relate to the termination of a Permit when leased property is destroyed and agree that any such event shall be governed by the terms of this Permit. (a) If the whole of the Assigned Space should be taken by any public or quasi-public authority under the power or threat of eminent domain, then, in such event, on the earlier of the date title to the Assigned Space vests in such public or quasi-public authority, or the date on which said public or quasi-public agency takes possession of the Assigned Space, this Permit shall terminate with respect to Port’s and Permittee’s future obligations hereunder, but said termination shall not affect Port’s and Permittee’s rights to any compensation or damages for, on the account of, or arising out of such taking. For any period of time prior to termination during which Permittee (involuntarily on account of such taking or any proceedings related thereto) does not have full use of the Assigned Space, the monthly Rent due hereunder shall be equitably reduced. In the event of such a taking, the Port shall be entitled to receive all sums in the award of damages and compensation arising by reason of such taking except that an amount therefrom equal to the fair market value of Permittee’s leasehold interest in the Assigned Space (as of the date of valuation of the taking) shall be paid to Permittee. (b) If a substantial portion of the Assigned Space should be taken so as to impair materially the use of the Assigned Space as contemplated by the Permit, then on the earlier of the date title to such portion of the Assigned Space vests in such public or quasi-public agency, or the date on which such public or quasi-public agency takes possession of such portion of the Assigned Space and Permittee no longer has full possession of such portion, this Permit shall terminate with respect to Port’s and Permittee’s future obligations hereunder, but said termination shall not affect Port’s or Permittee’s rights to any compensation or damages for, on account of, or arising out of such taking. For any period of time prior to termination during which Permittee (involuntarily on account of such taking or any proceedings related thereto) does not have full use of the Assigned Space, the monthly Rent due hereunder shall be equitably reduced. In the event of such a substantial taking, the award of damages and compensation arising by reason of such taking shall be distributed in the same manner as the last sentence of Section 37(2)(a) above. (c) If a taking shall occur which does not result in termination of this Permit as provided in the previous subsections of this Section 37(2), but which requires the portion of the Assigned Space not so taken to be reconstructed and restored so as to be constituted an architecturally complete unit suitable for use by Permittee, all compensation and damages payable for or on account of such taking shall be payable to Permittee, and shall be held in a separate account approved in writing by Port in trust by Permittee to be used by Permittee in accordance with all applicable requirements of this Permit (including without limitation Section 1(2) above) solely to reconstruct and restore the portion of the Assigned Space not so taken to an architecturally complete unit suitable for use by Permittee; and the monthly Rent payable by Permittee hereunder shall be equitably reduced during the time Permittee does not have full use of the Assigned Space as a result of such taking to account for the reduced economic value to Permittee, if any, occasioned by reason of such taking. The balance of any compensation and damages remaining after the reconstruction and restoration contemplated by this subsection shall be distributed in the same manner as distribution of damages and compensation for a total taking under the last sentence of Section 37(2)(a) above. In the event of a taking covered by this subsection (c), Port shall send to Permittee an amendment to this Permit showing the deletion of that portion of the Assigned Space that was the subject of this taking, and this Permit shall be deemed amended thereby. (d) If a taking shall occur which does not result in a termination of this Permit as provided in the previous subsections of this Section 37(2), and which does not require any portion of the Assigned Space not so taken to be reconstructed and restored so as to constitute an architecturally complete unit suitable for use by Permittee, the proceeds shall be distributed in accordance with the last sentence of Section 37(2)(a) above. Permittee, however, shall be entitled to an equitable reduction in the monthly Rent. (e) No taking of Permittee’s leasehold estate in the Assigned Space or any part thereof without a taking of the fee shall terminate or give Permittee the right to surrender this Permit, nor excuse the taker of such leasehold estate, including any successor in interest thereto, from full performance of the covenants for the payment of the Rent and other charges or any other obligations hereunder capable of performance by the taker of such leasehold estate, including any successor in interest thereto, after any such taking, but in such case, all compensation and damages payable for or on account of such taking shall be payable to and be the sole property of Port. During any period of time that Permittee is not in possession of the Assigned Space, or any portion thereof, as a result of the taking of any portion of its leasehold estate hereunder, but only during such period of time, (1) Permittee shall not be obligated to pay or in any way be liable for the payment of any Rent or to perform any of the other obligations or covenants otherwise to be performed by it hereunder with respect to, but only with respect to the portion of the Assigned Space affected by such taking, (2) the Port shall look solely to the taker of such leasehold interest, including the successors in interest thereto and any party then in possession of all or such portion of the Assigned Space affected by such taking for the payment of the Rent and the performance of the other obligations and covenants hereunder with respect to such portion of the Assigned Space, and (3) as between Port and Permittee, Port shall not forfeit or terminate this Permit for breach by the taker of such leasehold interest, including its successors in interest thereto and any party then in possession, of any obligation or covenant hereunder, including the obligation to pay the Rent. Any taking that is the subject of this subsection (e) shall not extend the Term of this Permit. (f) In the event of any taking of any portion of the Assigned Space, Permittee shall be entitled to receive all compensation and damages arising from such taking and payable for or on account of the Permittee’s Trade Equipment located on the portion of the Assigned Space so taken, except for those trade fixtures and equipment that pursuant to this Permit are to remain with the Assigned Space on surrender. (g) Except as otherwise expressly provided in this Section 37(2), no taking shall reduce or xxxxx Permittee’s obligation to pay the Rent during the Term of this Permit. Where Section 37(2) expressly provides for a reduction in the Rent payable by Permittee, if the parties cannot agree on the amount of such reduction, the same shall be determined by Arbitration. Such arbitration shall be conducted in accordance with the Commercial Arbitration Rules of the American Arbitration Association. The arbitrators shall have no power to modify any of the provisions of this Permit and their jurisdiction is limited accordingly. Each party hereby consents to the entry of judgment by any court having jurisdiction in accordance with the arbitration decision. No change in the Arbitration Rules which would deprive a party of the rights to be represented by counsel, to present evidence or to cross-examine witnesses presented by the other party shall be effective in any arbitration proceeding arising out of this Permit. Any arbitration provided for herein shall be conducted in the Port’s offices in Alameda County, California. Disputes under this Permit shall be subject to Arbitration only to the extent expressly provided for in this subsection (h). (h) Permittee acknowledges the Port’s reserved power upon payment of just compensation to exercise its power of eminent domain as to the leasehold estate created hereunder; provided, however, that the foregoing acknowledgment shall not be deemed or construed to prejudice or waive any rights of Permittee to challenge or object to any attempt by the Port so to exercise such power.