Special Provisions Related to Operation of the Premises Sample Clauses

Open Split View

Download

Share

Cite

Special Provisions Related to Operation of the Premises 

Sample 1

Save

Copy

Related to Special Provisions Related to Operation of the Premises

• Certification of Funds; Budget and Fiscal Provisions; Termination in the Event of Non-Appropriation This Agreement is subject to the budget and fiscal provisions of the City’s Charter. Charges will accrue only after prior written authorization certified by the Controller, and the amount of City’s obligation hereunder shall not at any time exceed the amount certified for the purpose and period stated in such advance authorization. This Agreement will terminate without penalty, liability or expense of any kind to City at the end of any fiscal year if funds are not appropriated for the next succeeding fiscal year. If funds are appropriated for a portion of the fiscal year, this Agreement will terminate, without penalty, liability or expense of any kind at the end of the term for which funds are appropriated. City has no obligation to make appropriations for this Agreement in lieu of appropriations for new or other agreements. City budget decisions are subject to the discretion of the Mayor and the Board of Supervisors. Contractor’s assumption of risk of possible non-appropriation is part of the consideration for this Agreement. THIS SECTION CONTROLS AGAINST ANY AND ALL OTHER PROVISIONS OF THIS AGREEMENT.

• LOCATION AND DESCRIPTION OF THE PROPERTY The subject property is a single-storey terraced house bearing the postal address of Xx. 00, Xxxxxx 00/XX0, Xxxxxx Xxxxx Xxxxxxx, 00000 Xxxxxxx Xxxxx, Xxxxxx. The subject property will be sold on an “as is where is basis” and subject to a reserve price of RM310,000.00 (RINGGIT MALAYSIA THREE HUNDRED TEN THOUSAND ONLY) and subject to the Conditions of Sale and by way of an Assignment from the above Assignee/Bank subject to the consent being obtained by the Purchaser from the Developer and other relevant authorities if any, including all terms, conditions, stipulations and covenants which were and may be imposed by the Developer and the relevant authorities. Any arrears of quit rent, assessments and service or maintenance charges which may be lawfully due to any relevant authority or the Developer up to the date of auction sale of the property shall be paid out of the purchase money upon receipt of full purchase price. All other fees, costs and charges relating to the transfer and assignment of the property shall be borne by the successful Purchaser. Online bidders are further subject to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. All intending bidders are required to deposit 10% of the fixed reserve price for the said property by Bank Draft or Cashier’s Order in favour of UOBM for KRISHNAMAL A/P MURLIGIAH & XXXXXXXXXXX A/L XXXXXXX or remit the same through online banking transfer, one (1) working day before auction date. The balance of the purchase money shall be paid by the Purchaser within one hundred and twenty (120) days from the date of auction sale to UNITED OVERSEAS BANK (MALAYSIA) BHD via Real Time Electronics Transfer of Funds and Securities (XXXXXX). For online bidders please refer to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx on the manner of payment of the deposit. FOR FURTHER PARTICULARS, please contact M/S HOE & MOIRA, of Xxxxx 000X (Xxxxx), 0xx Xxxxx, Xxxxx Xxxxxx Xxxxxx, Xxxxxxxxxx Xxxx, 00000 Xxxxxx, Xxxxxxxx. (Ref:H&M/MT/Z4P/CB23/16) Tel.: 00-000 0000, Fax: 00-000 0000) the Assignee herein or the undermentioned Auctioneer. Suite C-20-3A, Level 20, Block C, Megan Avenue II, / XXXXX XXXXX BIN XXXXXX 00, Xxxxx Xxx Xxxx Xxxx, 50450 Kuala Lumpur (Licensed Auctioneers) Tel No.: 00-0000 0000 Fax No.: 00-0000 0000 Our Ref: LIAN/UOB1035HM Website: xxx.xxxxxxxxxxxxxxxx.xxx E-mail: xxxx@xxxxxxxxxxxxxxxx.xxx [berkuatkuasa dari 1.11.2022, perniagaan perbankan pengguna (consumer banking business) CITIBANK BERHAD (No. Syarikat: 199401011410 (297089-M) telah dipindahmilik kepada xxx diletakhakkan kepada UOB di bawah Perintah Letakhak bertarikh 12.10.2022 melalui Mahkamah Tinggi Kuala Lumpur Saman Pemula No. WA-24NCC-903-09/2022] Dalam menjalankan xxx xxx kuasa xxxx telah diberikan kepada Pihak Pemegang Serahhak/Bank dibawah Perjanjian Kemudahan, Penyerahanhak xxx Surat Kuasa Wakil kesemuanya Bertarikh 09hb Julai, 2001 diantara Pihak Penyerahhak, Pihak Pelanggan xxx Pihak Pemegang Serahhak/Bank yang diperbuat dalam perkara diatas, adalah dengan ini diisytiharkan bahawa Pihak Pemegang Serahhak/Bank tersebut dengan bantuan Pelelong yang tersebut dibawah.

• Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

• Operation of the Business Except as set forth on Section 10.1 of the Sentech Disclosure Schedule, as contemplated by this Agreement or as expressly agreed to in writing by Sensec and Ensec, during the period from the date of this Agreement to the Effective Time, Sentech and its Subsidiaries will conduct their operations only in the ordinary course of business consistent with sound financial, operational and regulatory practice, and will take no action which would materially adversely affect their ability to consummate the Transactions. Without limiting the generality of the foregoing, except as otherwise expressly provided in this Agreement or except as disclosed in the Sentech Disclosure Schedule, prior to the Effective Time, neither Sentech nor any of its Subsidiaries will, without the prior written consent of Sensec and Ensec: (a) amend its Charter Documents or bylaws (or similar organizational documents); (b) authorize for issuance, issue, sell, deliver, grant any options for, or otherwise agree or commit to issue, sell or deliver any shares of its capital stock or any other securities, other than pursuant to and in accordance with the terms of any Existing Options or Sentech Warrants listed on the Sentech Disclosure Schedule; (c) recapitalize, split, combine or reclassify any shares of its capital stock; declare, set aside or pay any dividend or other distribution (whether in cash, stock or property or any combination thereof) in respect of its capital stock; or purchase, redeem or otherwise acquire any of its or its Subsidiaries' securities or modify any of the terms of any such securities; (d) (i) create, incur, assume or permit to exist any long-term debt or any short-term debt for borrowed money other than under existing notes payable, lines of credit or other credit facilities or in the ordinary course of business, or with respect to its Wholly-Owned Subsidiaries in the ordinary course of business; (ii) assume, guarantee, endorse or otherwise become liable or responsible (whether directly, contingently or otherwise) for the obligations of any other Person except its Wholly-Owned Subsidiaries in the ordinary course of business or as otherwise may be contractually required and disclosed in the Sentech Disclosure Schedule; or (iii) make any loans, advances or capital contributions to, or investments in, any other Person except its Wholly-Owned Subsidiaries; (i) amend any Sentech Benefit Plan or (ii) except in the ordinary course of business consistent with usual practice or established policy (a) increase in any manner the rate of compensation of any of its directors, officers or other employees everywhere, except for increases in the ordinary course of business; (b) pay or agree to pay any bonus, pension, retirement allowance, severance or other employee benefit except as required under currently existing Sentech Benefit Plans disclosed in the Sentech Disclosure Schedule or in the ordinary course of business; or (c) amend, terminate or enter into any employment, consulting, severance, change in control or similar agreements or arrangements with any of its directors, officers or other employees; (f) enter into any material agreement, commitment or contract, except agreements, commitments or contracts for the purchase, sale or lease of goods or services in the ordinary course of business; (g) other than in the ordinary course of business, authorize, recommend, propose or announce an intention to authorize, recommend or propose, or enter into any Contract with respect to, any (i) plan of liquidation or dissolution, (ii) acquisition of a material amount of assets or securities, (iii) disposition or Encumbrance of a material amount of assets or securities, (iv) merger or consolidation or (v) material change in its capitalization; (h) change any material accounting or Tax procedure or practice; (i) take any action the taking of which, or knowingly omit to take any action the omission of which, would cause any of the representations and warranties herein to fail to be true and correct in all material respects as of the date of such action or omission as though made at and as of the date of such action or omission; (j) compromise, settle or otherwise modify any material claim or litigation not identified in the Sentech Disclosure Schedule; or (k) commit or agree to do any of the foregoing.

• Operations Matters In the conduct its business and operations, Pledgor shall, and shall cause each of the Companies to: (i) maintain books and records, separate from those of any other Person; (ii) maintain its bank accounts and all its other assets separate from those of any other Person; (iii) hold regular member, partnership or shareholder meetings, as appropriate, to conduct its business, and observe all other limited liability company, partnership or corporate formalities, as the case may be; (iv) hold itself out to creditors and the public as a legal entity separate and distinct from any other Person; (v) prepare separate financial statements, or if part of a consolidated or combined group, then it shall be shown as a separate member of such group, including in a footnote(s) to the relevant financial statements disclosing its separate existence and identity and the existence of its own assets; (vi) allocate and charge fairly and reasonably any common employee or overhead shared with Affiliates; (vii) transact all business with Affiliates on an arm's-length basis and to enter into transactions with Affiliates on an arm's-length basis; (viii) conduct business in its own name; (ix) with regard to each Company, maintain a sufficient number of employees in light of such Company's contemplated business operations; (x) correct any misunderstanding regarding its separate identity of which Pledgor has actual knowledge; (xi) not identify itself in writing as a division of any other Person; and (xii) maintain adequate capital in light of its contemplated business operations.

• Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.

• Operation of the Property Between June 1, 1998 and the Closing Date, Seller shall (a) lease, operate, manage and enter into contracts with respect to the Property, in the same manner done by Seller prior to the date hereof (provided, however, that without the prior consent of Purchaser, which as to (i) and (ii) shall not be unreasonably delayed, conditioned or withheld, (i) Seller shall not enter into any Service Contract that cannot be terminated with thirty (30) days notice or materially modify any existing Service Contracts to be assumed by Purchaser at Closing, and (ii) after June 1, 1998, Seller shall not materially modify or terminate any existing Tenant Lease or grant any material consents under any existing Tenant Lease (except as otherwise required pursuant to the terms and conditions of such Tenant Lease), or enter into any new Tenant Lease, and (iii) Seller shall not apply any then unapplied Deposits (as reflected on the Rent Roll delivered by Seller to Purchaser pursuant to Schedule 5.3(vii) hereof) under Tenant Leases); and (b) advise Purchaser of the commencement of any litigation, condemnation or other judicial or administrative proceedings affecting the Property of which Seller has current actual knowledge. Notwithstanding anything to the contrary set forth in this Contract, Purchaser acknowledges that after June 1, 1998 and prior to Closing, Seller will enter into contracts for the completion of Tenant improvements under Tenant Leases entered into after June 1, 1998 pursuant to the terms of Section 12.1 hereof (collectively, the "Tenant Finish Contracts"). Purchaser and Seller agree that at Closing, Purchaser shall assume the obligations of Seller under all such Tenant Finish Contracts including, without limitation, the obligations to pay any costs and expenses charged with respect to construction of improvements in the space subject to such Tenant Leases. At Closing, Purchaser shall execute and deliver to the Seller an Assignment, Assumption and Indemnity Agreement in the form attached hereto as Exhibit H and made a part hereof for all purposes.

• Operation of Agreement This Agreement will be effective and binding immediately upon its execution, but, anything in this Agreement to the contrary notwithstanding, this Agreement will not be operative unless and until a Change in Control occurs. Upon the occurrence of a Change in Control at any time during the Term, without further action, this Agreement shall become immediately operative.

• Operation of the Agreement The Parties recognize that it is impractical in this Agreement to provide for every contingency which may arise during the life of the Agreement, and the Parties hereby agree that it is their intention that this Agreement shall operate fairly as between them, and without detriment to the interest of either of them, and that, if during the term of this Agreement either Party believes that this Agreement is operating unfairly, the Parties will use their best efforts to agree on such action as may be necessary to remove the cause or causes of such unfairness, but failure to agree on any action pursuant to this Clause 8.2 shall not give rise to a dispute subject to arbitration in accordance with Clause 9 hereof.

• Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.