SUBCONTRACTOR’S INDEMNITY 2.08.1 CONTRACTOR SHALL REQUIRE ALL OF ITS SUBCONTRACTORS (AND THEIR SUBCONTRACTORS) TO RELEASE AND INDEMNIFY THE CITY TO THE SAME EXTENT AND IN SUBSTANTIALLY THE SAME FORM AS ITS RELEASE AND INDEMNITY TO THE CITY.
Indemnification by Subcontractors To the fullest extent permitted by law, an Interconnection Party that uses a subcontractor to carry out any of the Interconnection Party’s obligations under this Appendix 2 shall require each of its subcontractors to indemnify, hold harmless and defend each other Interconnection Party, its representatives and assigns from and against any and all claims and/or liability for damage to property, injury to or death of any person, including the employees of any Interconnection Party or of any Affiliate of any Interconnection Party, or any other liability incurred by the other Interconnection Party or any of its Affiliates, including all expenses, legal or otherwise, to the extent caused by any act or omission, negligent or otherwise, by such subcontractor and/or its officers, directors, employees, agents and assigns, that arises out of or is connected with the operation of the facilities of either Interconnected Entity described in this Appendix 2; provided, however, that no Interconnection Party or Affiliate thereof shall be entitled to indemnity under this Section 18.3 in respect of any injury, loss, or damage to the extent that such loss, injury, or damage results from the negligence or willful misconduct of the Interconnection Party or Affiliate seeking indemnity.
Indemnification by Contractor (a) Contractor shall defend, indemnify and hold harmless District, its officers, directors, employees, agents, volunteers, and Affiliates and District’s Board of Education from any and all damages, costs and expenses, including attorneys’ fees, arising out of any third party claims for damages for bodily injury (including death) or for damage to real property or tangible personal property resulting from, arising out of or otherwise related to Contractor’s performance of this Agreement.
Waiver and Indemnification Tenant waives all claims against Landlord, its Security Holders (defined in Section 17), Landlord’s managing agent(s), their (direct or indirect) owners, and the beneficiaries, trustees, officers, directors, employees and agents of each of the foregoing (including Landlord, the “Landlord Parties”) for (i) any damage to person or property (or resulting from the loss of use thereof), except to the extent such damage is caused by any negligence, willful misconduct or breach of this Lease of or by any Landlord Party, or (ii) any failure to prevent or control any criminal or otherwise wrongful conduct by any third party or to apprehend any third party who has engaged in such conduct. Tenant shall indemnify, defend, protect, and hold the Landlord Parties harmless from any obligation, loss, claim, action, liability, penalty, damage, cost or expense (including reasonable attorneys’ and consultants’ fees and expenses) (each, a “Claim”) that is imposed or asserted by any third party and arises from (a) any cause in, on or about the Premises, or (b) any negligence, willful misconduct or breach of this Lease of or by Tenant, any party claiming by, through or under Tenant, their (direct or indirect) owners, or any of their respective beneficiaries, trustees, officers, directors, employees, agents, contractors, licensees or invitees (each, an “Act of Tenant”), except to the extent such Claim arises from any negligence, willful misconduct or breach of this Lease of or by any Landlord Party. Landlord shall indemnify, defend, protect, and hold Tenant, its (direct or indirect) owners, and their respective beneficiaries, trustees, officers, directors, employees and agents (including Tenant, the “Tenant Parties”) harmless from any Claim that is imposed or asserted by any third party and arises from any negligence, willful misconduct or breach of this Lease of or by any Landlord Party, except to the extent such Claim arises from any negligence, willful misconduct or breach of this Lease of or by any Tenant Party.
Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR.
WAIVER OF LIABILITY, ASSUMPTION OF RISK, AND INDEMNITY AGREEMENT I, , IN CONSIDERATION of being permitted to participate in any way in the Rocky Mountain Cycling Club 200 km brevet calendared for October 8, 2022 (“Activity”), I hereby acknowledge, agree, attest and represent the following:
Defense and Indemnification a. The Contractor hereby agrees to defend, indemnify, reimburse and hold harmless the City, its appointed and elected officials, agents and employees for, from and against all liabilities, claims, judgments, suits or demands for damages to persons or property arising out of, resulting from, or relating to the work performed under this Agreement (“Claims”), unless such Claims have been specifically determined by the trier of fact to be the sole negligence or willful misconduct of the City. This indemnity shall be interpreted in the broadest possible manner to indemnify the City for any acts or omissions of the Contractor or its subcontractors either passive or active, irrespective of fault, including the City’s concurrent negligence whether active or passive, except for the sole negligence or willful misconduct of the City.
Indemnification/Hold Harmless The Exhibitor who signs this contract and each person associated therewith (i.e. employees, spouses, guests, survivors, heirs, executors and representatives) herein agrees to indemnify, defend, hold harmless, and to release and forever discharge from any and all known and unknown damages, injuries, death, loss, liabilities, claims, costs, penalties, demands, actions, causes of action, judgments, and liabilities of every kind and description (including court costs and attorney’s fees), occasioned by, resulting from, and/or related to conduct, actions, and/or omissions of anyone connected with this event, including: Xxxx Xxxx Xxxxxxxxxxx, Inc. d.b.a. Rod Shows, Fairplex, all other Exhibitors/Vendors at the event; and each of their respective owners, shareholders, officers, their directors, employees, agents, staff, volunteers, independent contractors, representatives and servants. Exhibitor covenants and agrees that in case Rod Shows shall be made party to any litigation commenced by or against exhibitor or relating to this agreement or to the booth space hereunder, then exhibitor shall and will pay all costs and expenses, including reasonable attorney fees and court costs, incurred by or imposed upon Rod Shows by virtue of any such litigation. SECURITY & PROPERTY DAMAGE Rod Shows will provide limited facility security and will exercise reasonable precaution for the protection of the exhibitors property. Rod Shows assumes no responsibility for loss or damage incurred during the rental period, or for any loss of items left onsite overnight. Neither Rod Shows or the vendor/exhibitor shall be responsible for any loss or damage to property of other party hereto including, but not limited to loss or damage occasioned by theft, fire, smoke, acts of God, public enemy, riot, civil commotion or other insurable hereto with respect to any loss or damage. It shall be the responsibility of Rod Shows and the Vendor/Exhibitor, respectively, to secure their own property insurance or otherwise protect themselves and their property against any such loss or damage. UNAVAILABILITY OF BOOTH SPACE
HOLD HARMLESS AND INDEMNIFICATION A. The Consultant shall defend, indemnify, and hold the City, its officers, officials, employees, and volunteers harmless from any and all claims, injuries, damages, losses, or suits including attorney fees, arising out of or resulting from the acts, errors, or omissions of the Consultant in performance of this Agreement, except for injuries and damages caused by the sole negligence of the City.
Indemnification Obligations Subject to the limitations set forth in this Agreement, each Fund severally and not jointly agrees to indemnify and hold harmless the Custodian and its nominees from all loss, damage and expense (including reasonable attorneys' fees) suffered or incurred by the Custodian or its nominee caused by or arising from actions taken by the Custodian on behalf of such Fund in the performance of its duties and obligations under this Agreement; provided however, that such indemnity shall not apply to loss, damage and expense occasioned by or resulting from the negligence, misfeasance or misconduct of the Custodian or its nominee. In addition, each Fund agrees severally and not jointly to indemnify any Person against any liability incurred by reason of taxes assessed to such Person, or other loss, damage or expenses incurred by such Person, resulting from the fact that securities and other property of such Fund's Portfolios are registered in the name of such Person; provided however, that in no event shall such indemnification be applicable to income, franchise or similar taxes which may be imposed or assessed against any Person.
