Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
END USER AGREEMENTS (“EUA GAC acknowledges that the END USER may choose to enter into an End User Agreement (“EUA) with the Contractor through this Agreement, and that the term of the EUA may exceed the term of the current H-GAC Agreement. H-GAC’s acknowledgement is not an endorsement or approval of the End User Agreement’s terms and conditions. Contractor agrees not to offer, agree to or accept from the END USER, any terms or conditions that conflict with those in Contractor’s Agreement with H-GAC. Contractor affirms that termination of its Agreement with H-GAC for any reason shall not result in the termination of any underlying EUA, which shall in each instance, continue pursuant to the EUA’s stated terms and duration. Pursuant to the terms of this Agreement, termination of this Agreement will disallow the Contractor from entering into any new EUA with END USERS. Applicable H-GAC order processing charges will be due and payable to H-GAC
Documents Required to be Delivered on each Issuance Notice Date The Agent’s obligation to use its commercially reasonable efforts to place Shares hereunder shall additionally be conditioned upon the delivery to the Agent on or before the Issuance Notice Date of a certificate in form and substance reasonably satisfactory to the Agent, executed by the Chief Executive Officer, President or Chief Financial Officer of the Company, to the effect that all conditions to the delivery of such Issuance Notice shall have been satisfied as at the date of such certificate (which certificate shall not be required if the foregoing representations shall be set forth in the Issuance Notice).
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
MFMP Transaction Fee Reports The Contractor shall submit complete monthly MFMP Transaction Fee Reports to the Department. Reports are due 15 calendar days after the end of each month. Information on how to submit MFMP Transaction Fee Reports online can be located at xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/state_/myfloridamarketplace/mf mp_vendors/transaction_fee_and_reporting. Assistance with transaction fee reporting is also available by email at xxxxxxxxxxxxx@xxxxxxxxxxxxxxxxxxxx.xxx or telephone at 866-FLA-EPRO (866-352-3776) from 8:00 a.m. to 6:00 p.m. Eastern Time.
CONTRACT EXHIBIT I PREFERRED PRICING AFFIDAVIT This preferred-pricing affidavit is entered into in accordance with section 216.0113, F.S., and as required by Contract No. 80101507-21-STC-ITSA (“Contract”) between (“Contractor”) and the Department of Management Services. As the person authorized by Contractor to sign this affidavit, I attest that the Contractor is in full compliance with the preferred-pricing clause of the Contract. Contractor’s Name: By: Signature Printed Name/Title Date: STATE OF COUNTY OF Sworn to (or affirmed) and subscribed before me this day of , by Vendor Name: FEIN# Vendor’s Authorized Representative Name and Title: Address: City, State, and Zip code: Phone Number: ( ) - E-mail: CORPORATE SEAL (IF APPLICABLE) (Print, Type, or Stamp Commissioned Name of Notary Public) [Check One] Personally Known OR Produced the following I.D.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
DISTRIBUTION OF CONTRACTOR PRICE LIST AND CONTRACT APPENDICES Contractor shall provide Authorized Users with electronic copies of the Contract, including price lists and Appendices, upon request. Contract Updates will be handled as provided in Appendix C – Contract Modification Procedures.
MONITORING FOR MATERIAL IRRECONCILABLE CONFLICTS AVIF agrees that its Board of Directors will monitor for the existence of any material irreconcilable conflict between the interests of the Participants in all separate accounts of life insurance companies utilizing AVIF ("Participating Insurance Companies"), including each Account, and participants in all qualified retirement and pension plans investing in AVIF ("Participating Plans"). LIFE COMPANY agrees to inform the Board of Directors of AVIF of the existence of or any potential for any such material irreconcilable conflict of which it is aware. The concept of a "material irreconcilable conflict" is not defined by the 1940 Act or the rules thereunder, but the Parties recognize that such a conflict may arise for a variety of reasons, including, without limitation:
(a) an action by any state insurance or other regulatory authority;
(b) a change in applicable federal or state insurance, tax or securities laws or regulations, or a public ruling, private letter ruling, no-action or interpretative letter, or any similar action by insurance, tax or securities regulatory authorities;
(c) an administrative or judicial decision in any relevant proceeding;
(d) the manner in which the investments of any Fund are being managed;
(e) a difference in voting instructions given by variable annuity contract and variable life insurance contract Participants or by Participants of different Participating Insurance Companies;
(f) a decision by a Participating Insurance Company to disregard the voting instructions of Participants; or
(g) a decision by a Participating Plan to disregard the voting instructions of Plan participants. Consistent with the SEC's requirements in connection with exemptive orders of the type referred to in Section 5.1 hereof, LIFE COMPANY will assist the Board of Directors in carrying out its responsibilities by providing the Board of Directors with all information reasonably necessary for the Board of Directors to consider any issue raised, including information as to a decision by LIFE COMPANY to disregard voting instructions of Participants. LIFE COMPANY's responsibilities in connection with the foregoing shall be carried out with a view only to the interests of Participants.
