Independent Nature of Holders’ Obligations and Rights The obligations of each Holder hereunder are several and not joint with the obligations of any other Holder hereunder, and no Holder shall be responsible in any way for the performance of the obligations of any other Holder hereunder. Nothing contained herein or in any other agreement or document delivered at any closing, and no action taken by any Holder pursuant hereto or thereto, shall be deemed to constitute the Holders as a partnership, an association, a joint venture or any other kind of group or entity, or create a presumption that the Holders are in any way acting in concert or as a group or entity with respect to such obligations or the transactions contemplated by this Agreement or any other matters, and the Company acknowledges that the Holders are not acting in concert or as a group, and the Company shall not assert any such claim, with respect to such obligations or transactions. Each Holder shall be entitled to protect and enforce its rights, including without limitation the rights arising out of this Agreement, and it shall not be necessary for any other Holder to be joined as an additional party in any proceeding for such purpose. The use of a single agreement with respect to the obligations of the Company contained was solely in the control of the Company, not the action or decision of any Holder, and was done solely for the convenience of the Company and not because it was required or requested to do so by any Holder. It is expressly understood and agreed that each provision contained in this Agreement is between the Company and a Holder, solely, and not between the Company and the Holders collectively and not between and among Holders.
Sub-Adviser's Duties Subject to the general supervision of the Trust's Board of Trustees (the "Board") and the Adviser, the Sub-Adviser shall, employing its discretion, manage the investment operations of each Fund and the composition of the portfolio of securities and investments (including cash) belonging to each Fund, including the purchase, retention and disposition thereof and the execution of agreements relating thereto, in accordance with the Fund's investment objective, policies and restrictions as stated in the Trust's then-current Prospectus and Statement of Additional Information (together, the "Prospectus") and subject to the following understandings: (a) The Sub-Adviser shall furnish a continuous investment program for each Fund and determine from time to time what investments or securities will be purchased, retained or sold by each Fund and what portion of the assets belonging to each Fund will be invested or held uninvested as cash; (b) The Sub-Adviser shall use its best judgment in the performance of its duties under this Agreement; (c) The Sub-Adviser, in the performance of its duties and obligations under this Agreement, shall act in conformity with the Trust's Declaration of Trust, its By-Laws and its Prospectus and with the instructions and directions of the Trust's Board of Trustees and the Adviser and will conform to and comply with the requirements of the 1940 Act and all other applicable federal and state laws and regulations; (d) The Sub-Adviser shall determine the securities to be purchased or sold by each Fund and as agent for the Trust will effect portfolio transactions pursuant to its determinations either directly with the issuer or with any broker and/or dealer in such securities, subject to Section 3 below; (e) The Sub-Adviser shall maintain books and records with respect to the securities transactions of each Fund and shall render to the Adviser and the Trust's Board of Trustees such periodic and special reports as the Adviser or the Board may request; and (f) The Sub-Adviser shall provide the Trust's custodian with such information relating to the Trust as may be required under the terms of the then-current custody agreement between the Trust and the custodian.
Independent Nature of Buyers’ Obligations and Rights The obligations of each Buyer under the Transaction Documents are several and not joint with the obligations of any other Buyer, and no Buyer shall be responsible in any way for the performance of the obligations of any other Buyer under any Transaction Document. Nothing contained herein or in any other Transaction Document, and no action taken by any Buyer pursuant hereto or thereto, shall be deemed to constitute the Buyers as, and the Company acknowledges that the Buyers do not so constitute, a partnership, an association, a joint venture or any other kind of group or entity, or create a presumption that the Buyers are in any way acting in concert or as a group or entity, and the Company shall not assert any such claim with respect to such obligations or the transactions contemplated by the Transaction Documents or any matters, and the Company acknowledges that the Buyers are not acting in concert or as a group, and the Company shall not assert any such claim, with respect to such obligations or the transactions contemplated by the Transaction Documents. The decision of each Buyer to purchase Securities pursuant to the Transaction Documents has been made by such Buyer independently of any other Buyer. Each Buyer acknowledges that no other Buyer has acted as agent for such Buyer in connection with such Buyer making its investment hereunder and that no other Buyer will be acting as agent of such Buyer in connection with monitoring such Buyer’s investment in the Securities or enforcing its rights under the Transaction Documents. The Company and each Buyer confirms that each Buyer has independently participated with the Company and its Subsidiaries in the negotiation of the transaction contemplated hereby with the advice of its own counsel and advisors. Each Buyer shall be entitled to independently protect and enforce its rights, including, without limitation, the rights arising out of this Agreement or out of any other Transaction Documents, and it shall not be necessary for any other Buyer to be joined as an additional party in any proceeding for such purpose. The use of a single agreement to effectuate the purchase and sale of the Securities contemplated hereby was solely in the control of the Company, not the action or decision of any Buyer, and was done solely for the convenience of the Company and its Subsidiaries and not because it was required or requested to do so by any Buyer. It is expressly understood and agreed that each provision contained in this Agreement and in each other Transaction Document is between the Company, each Subsidiary and a Buyer, solely, and not between the Company, its Subsidiaries and the Buyers collectively and not between and among the Buyers.
The Supplier's Obligations The Supplier will in writing, by the time and date specified by the Contracting Body in accordance with paragraph 3.1.3(b) provide the Contracting Body with either: 3.2.1 a statement to the effect that it does not wish to tender in relation to the relevant Service Requirements; or 3.2.2 the Statement of Work and full details of its tender made in respect of the relevant Statement of Requirements. In the event that the Supplier submits a Statement of Work, it should include, as a minimum: a) an email response subject line to comprise unique reference number and Supplier name, so as to clearly identify the Supplier; b) a brief summary, in the email (followed by a confirmation letter), stating whether or not the Supplier is bidding for the Statement of Requirements; c) a proposal covering the Services Requirements; and d) confirmation of discounts applicable to the work, as referenced in Framework Agreement Schedule 3 (Charging Structure). 3.2.3 The Supplier shall ensure that any prices submitted in relation to a further competition held pursuant to this paragraph 3 shall be based on the Charging Structure and take into account any discount to which the Contracting Body may be entitled as set out in Framework Agreement Schedule 3 (Charging Structure). 3.2.4 The Supplier agrees that: a) all tenders submitted by the Supplier in relation to a further competition held pursuant to this paragraph 3 shall remain open for acceptance by the Contracting Body for ninety (90) Working Days (or such other period specified in the invitation to tender issued by the relevant Contracting Body in accordance with the Ordering Procedure); and b) all tenders submitted by the Supplier are made and will be made in good faith and that the Supplier has not and will not fix(ed) or adjust(ed) the amount of the offer by or in accordance with any agreement or arrangement with any other person. The Supplier certifies that it has not and undertakes that it will not: (a) communicate to any person other than the person inviting these offers the amount or approximate amount of the offer, except where the disclosure, in confidence, of the approximate amount of the offer was necessary to obtain quotations required for the preparation of the offer; and (b) enter into any arrangement or agreement with any other person that he or the other person(s) shall refrain from making an offer or as to the amount of any offer to be submitted.
Managers’ Obligations 4.1 The Managers undertake to use their best endeavours to provide the agreed Management Services as agents for and on behalf of the Owners in accordance with sound ship management practice and to protect and promote the interests of the Owners in all matters relating to the provision of services hereunder. Provided, however, that the Managers in the performance of their management responsibilities under this Agreement shall be entitled to have regard to their overall responsibility in relation to all vessels as may from time to time be entrusted to their management and in particular, but without prejudice to the generality of the foregoing, the Managers shall be entitled to allocate available supplies, manpower and services in such manner as in the prevailing circumstances the Managers in their absolute discretion consider to be fair and reasonable. 4.2 Where the Managers are providing Technical Management in accordance with sub-clause 3.2, they shall procure that the requirements of the law of the flag of the Vessel are satisfied and they shall in particular be deemed to be the “Company” as defined by the ISM Code, assuming the responsibility for the operation of the Vessel and taking over the duties and responsibilities imposed by the ISM Code when applicable.
Developer’s Obligations 7.1.1 In consideration of the Rights hereby granted, the Developer shall pay to the Authority an annual fee of Rs. /- (Rupees only) (“Fee”) commencing from the 1st (first) anniversary of Appointed Date. The Fee is exclusive of GST and all other applicable taxes and shall be payable by the Developer at actual over and above the Fee. The Fee is payable to the Authority on or before 30 (thirty) days prior to the start of every year in advance as set out in Schedule 1 throughout the Agreement Period. During the Agreement Period the Fee shall be increased by 5% (five percent) every year over the previous year’s Fee on compounded basis. 7.1.2 The Developer should pay the Fee to the Authority notwithstanding the fact that, the development of Project Facilities is not completed within the specified period or Developer does not start the commercial operation of the Project. In other words, the Developer shall not be entitled to seek any reduction of Fee, claim, damages, compensation or any other consideration from the Authority on account of any reason. 7.1.3 Any delay in payment of the Fee shall attract an interest for the delayed period at the rate of SBI PLR plus 5% per annum on the outstanding amount, which shall be due from the date of such payment till the amount is realized by the Authority. In addition to the foregoing, any delay in payment of Fee beyond a period of 60 (sixty) days from the due date of such payment will be construed to be Material Breach under this Agreement.
THE CUSTOMER’S OBLIGATIONS (1) The Customer must maintain procedures relating to a withdrawal of the goods, recall and tampering and records necessary to support a recall of the goods, and allow the Supplier to inspect such procedures and records at any time on reasonable notice. (2) The Customer must provide any services, resources or facilities to the Supplier as may be reasonably required in respect of a recall of the goods. (3) The Supplier agrees to refund or provide credit to the Customer for any units of the goods that are recalled under this clause unless the conduct of the Customer or its employees, contractors or other persons it has engaged has given rise to the recall of the goods.
Independent Nature of Investors’ Obligations and Rights The obligations of each Investor under any Transaction Document are several and not joint with the obligations of any other Investor, and no Investor shall be responsible in any way for the performance of the obligations of any other Investor under any Transaction Document. The decision of each Investor to purchase Securities pursuant to the Transaction Documents has been made by such Investor independently of any other Investor. Nothing contained herein or in any Transaction Document, and no action taken by any Investor pursuant thereto, shall be deemed to constitute the Investors as a partnership, an association, a joint venture or any other kind of entity, or create a presumption that the Investors are in any way acting in concert or as a group with respect to such obligations or the transactions contemplated by the Transaction Documents. Each Investor acknowledges that no other Investor has acted as agent for such Investor in connection with making its investment hereunder and that no Investor will be acting as agent of such Investor in connection with monitoring its investment in the Securities or enforcing its rights under the Transaction Documents. Each Investor shall be entitled to independently protect and enforce its rights, including, without limitation, the rights arising out of this Agreement or out of the other Transaction Documents, and it shall not be necessary for any other Investor to be joined as an additional party in any proceeding for such purpose. The Company acknowledges that each of the Investors has been provided with the same Transaction Documents for the purpose of closing a transaction with multiple Investors and not because it was required or requested to do so by any Investor.
Powers Duties and Rights of Preferred Guarantee Trustee SECTION 1 Powers and Duties of the Preferred Guarantee Trustee (a) This Preferred Securities Guarantee shall be held by the Preferred Guarantee Trustee for the benefit of the Holders of the Preferred Securities, and the Preferred Guarantee Trustee shall not transfer this Preferred Securities Guarantee to any Person except a Holder of Preferred Securities exercising his or her rights pursuant to Section 5.4(b) or to a Successor Preferred Guarantee Trustee on acceptance by such Successor Preferred Guarantee Trustee of its appointment to act as Successor Preferred Guarantee Trustee. The right, title and interest of the Preferred Guarantee Trustee shall automatically vest in any Successor Preferred Guarantee Trustee, and such vesting and cessation of title shall be effective whether or not conveyancing documents have been executed and delivered pursuant to the appointment of such Successor Preferred Guarantee Trustee. (b) If an Event of Default actually known to a Responsible Officer of the Preferred Guarantee Trustee has occurred and is continuing, the Preferred Guarantee Trustee shall enforce this Preferred Securities Guarantee for the benefit of the Holders of the Preferred Securities. (c) The Preferred Guarantee Trustee, before the occurrence of any Event of Default and after the curing of all Events of Default that may have occurred, shall undertake to perform only such duties as are specifically set forth in this Preferred Securities Guarantee, and no implied covenants shall be read into this Preferred Securities Guarantee against the Preferred Guarantee Trustee. In case an Event of Default has occurred (that has not been cured or waived pursuant to Section 2.6) and is actually known to a Responsible Officer of the Preferred Guarantee Trustee, the Preferred Guarantee Trustee shall exercise such of the rights and powers vested in it by this Preferred Securities Guarantee, and use the same degree of care and skill in its exercise thereof, as a prudent person would exercise or use under the circumstances in the conduct of his or her own affairs. (d) No provision of this Preferred Securities Guarantee shall be construed to relieve the Preferred Guarantee Trustee from liability for its own negligent action, its own negligent failure to act, or its own willful misconduct, except that: (i) prior to the occurrence of any Event of Default and after the curing or waiving of all such Events of Default that may have occurred: (A) the duties and obligations of the Preferred Guarantee Trustee shall be determined solely by the express provisions of this Preferred Securities Guarantee, and the Preferred Guarantee Trustee shall not be liable except for the performance of such duties and obligations as are specifically set forth in this Preferred Securities Guarantee, and no implied covenants or obligations shall be read into this Preferred Securities Guarantee against the Preferred Guarantee Trustee; and (B) in the absence of bad faith on the part of the Preferred Guarantee Trustee, the Preferred Guarantee Trustee may conclusively rely, as to the truth of the statements and the correctness of the opinions expressed therein, upon any certificates or opinions furnished to the Preferred Guarantee Trustee and conforming to the requirements of this Preferred Securities Guarantee; but in the case of any such certificates or opinions that by any provision hereof are specifically required to be furnished to the Preferred Guarantee Trustee, the Preferred Guarantee Trustee shall be under a duty to examine the same to determine whether or not they conform to the requirements of this Preferred Securities Guarantee; (ii) the Preferred Guarantee Trustee shall not be liable for any error of judgment made in good faith by a Responsible Officer of the Preferred Guarantee Trustee, unless it shall be proved that the Preferred Guarantee Trustee was negligent in ascertaining the pertinent facts upon which such judgment was made; (iii) the Preferred Guarantee Trustee shall not be liable with respect to any action taken or omitted to be taken by it in good faith in accordance with the direction of the Holders of not less than a Majority in liquidation amount of the Preferred Securities relating to the time, method and place of conducting any proceeding for any remedy available to the Preferred Guarantee Trustee, or exercising any trust or power conferred upon the Preferred Guarantee Trustee under this Preferred Securities Guarantee; and (iv) no provision of this Preferred Securities Guarantee shall require the Preferred Guarantee Trustee to expend or risk its own funds or otherwise incur personal financial liability in the performance of any of its duties or in the exercise of any of its rights or powers, if the Preferred Guarantee Trustee shall have reasonable grounds for believing that the repayment of such funds or liability is not reasonably assured to it under the terms of this Preferred Securities Guarantee or indemnity, reasonably satisfactory to the Preferred Guarantee Trustee, against such risk or liability is not reasonably assured to it.
Customer’s Obligations The Customer shall: (a) provide the Supplier with: (i) all necessary co-operation in relation to this agreement; and (ii) all necessary access to such information as may be required by the Supplier; in order to render the Services, including but not limited to Customer Data, security access information and configuration services; (b) comply with all applicable laws and regulations with respect to its activities under this agreement; (c) carry out all other Customer responsibilities set out in this agreement in a timely and efficient manner. In the event of any delays in the Customer's provision of such assistance as agreed by the parties, the Supplier may adjust any agreed timetable or delivery schedule as reasonably necessary; (d) ensure that the Authorised Users use the Services and the Documentation in accordance with the terms and conditions of this agreement and shall be responsible for any Authorised User’s breach of this agreement; (e) obtain and shall maintain all necessary licences, consents, and permissions necessary for the Supplier, its contractors and agents to perform their obligations under this agreement, including without limitation the Services; (f) ensure that its network and systems comply with the relevant specifications provided by the Supplier from time to time; and (g) be solely responsible for procuring and maintaining its network connections and telecommunications links from its systems to the Supplier’s data centres, and all problems, conditions, delays, delivery failures and all other loss or damage arising from or relating to the Customer's network connections or telecommunications links or caused by the internet.
