Capital Improvements From and after Final Completion, Tenant shall not replace or materially alter the Project, or any part thereof (except as provided to the contrary with respect to Fixtures in Article 13), or make any addition thereto, whether voluntarily or in connection with repairs required by this Lease (collectively, “Capital Improvements”), unless Tenant shall comply with the following requirements and, if applicable, with the additional requirements set forth in Section 11.10:
(a) No Capital Improvements shall be undertaken, as applicable, until Tenant shall have procured from all Governmental Authorities and paid for all permits, consents, certificates and approvals for the proposed Capital Improvements which are required to be obtained prior to the commencement of the proposed Capital Improvements (collectively, “Improvement Approvals”). The FCRHA shall not unreasonably refuse to join or otherwise unreasonably refuse to cooperate in the application for any such Improvement Approvals, provided such application is made without cost, expense or liability (contingent or otherwise) to the FCRHA. True copies of all such Improvement Approvals shall be delivered by Tenant to the FCRHA prior to commencement of the proposed Capital Improvements.
(b) The Premises after completion of such Capital Improvements, shall have a value at least equal to the value of the Premises immediately before construction of such Capital Improvements. In addition, the Project shall at all times remain in substantial conformity with the original Plans and Specifications therefor (except to the extent specifically consented to by the FCRHA, in its sole but reasonable discretion).
(c) All Capital Improvements shall be made with reasonable diligence and continuity (subject to Unavoidable Delays) and in a good and workmanlike manner and in compliance with (i) all Improvement Approvals, (ii) if required pursuant to Section 11.10(a) or (b), in substantial accordance with the plans and specifications for such Capital Improvements as approved by the FCRHA, and (iii) all Applicable Laws.
(d) No construction of any Capital Improvement shall be commenced until Tenant shall have delivered to the FCRHA certificates of insurance and copies of the declaration page(s) for the insurance required by Exhibit D. Such insurance policies shall comply with the terms of Section 7.02 above.
CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.
Maintenance, Alteration and Repair (a) Resident is responsible for and agrees to take good care of the premises, fixtures and all common areas. Resident may not remove any of Owner’s property and will not perform any repairs, upgrades, painting, wallpapering, electric changes or other alterations of the premises without prior written consent from Owner. Resident will be responsible for damage from waste stoppages caused by foreign or improper objects or improper use in lines serving bathrooms, damage to fixtures, appliances, doors, windows, screens, damage from water faucets left on or from doors left open, and repairs or replacements to alarm devices necessitated by misuse or damage by Resident and/or guests. Extraordinary appliances or furnishings such as satellite dishes, hot tubs, pool tables, water beds or high utility-consuming devices may not be installed or placed on the premises or anywhere at the Property without Owner’s prior written consent, in its sole discretion. SAMPLE
(b) In the case of a malfunction of any utilities or damage by fire, water or similar cause, or any water leak, suspected mold or microbial growth, electrical problem, broken glass, broken lock or any other condition that Resident reasonably believes poses a hazard to health and safety, Resident must promptly notify Owner in writing. Owner will act with reasonable time and diligence in making repairs and reconnections; Resident may not withhold or reduce payment of rent or other charges during such time. Maintenance and repair requested by Resident will generally be performed between 8am and 8pm, unless the work is considered an emergency, in which case work may take place at any time. Owner may temporarily disconnect equipment or utilities to avoid property damage and/or to perform repairs requiring such interruption, in Owner’s sole discretion. Owner will not be liable for any inconvenience, discomfort, disruption or interference with Resident use of the premises because of ongoing repairs, alterations or improvements to the Property or any apartment.
(c) Following move-in, Resident is responsible for providing and changing all light bulbs and batteries (for smoke detectors and remote controls) in the assigned apartment. A written maintenance report requesting assistance in changing these items may be submitted for maintenance staff assistance, with extra charges payable by Resident as applicable per Owner’s published rates. From time to time, maintenance staff may enter the assigned apartment with or without notice to inspect and change furnace filters and to provide pest control.
Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.
Supervisors Working (a) The Employer agrees that the function of supervisors is the supervision of Employees and not the performance of the work of the employees they supervise. Accordingly, the Employer agrees that supervisors or other employees of the Employer who are not members of the bargaining unit shall not perform any bargaining unit work, except to train employees or demonstrate safety, or as otherwise provided in the applicable Supplement, Rider or Addendum. However, in the case of Acts of God, supervisors shall comply with the procedures in subsections (b) and (c) and may only perform bargaining unit work until bargaining unit employees are available. The Employer shall make every reasonable effort to maintain a sufficient workforce to staff its operations with bargaining unit employees. The Employer also agrees that supervisors or other employees of the Employer who are not members of the bargaining unit shall not perform bargaining unit work in preparing the work areas before the start of the Employer’s hub, preload or reload operation, nor shall the Employer send any bargaining unit employee home and then have such employee’s work performed by a supervisor or other employees of the Employer who are not a member of the bargaining unit.
(b) When additional employees are necessary to complete the Employer’s operations on any shift or within any classification, the supervisor shall exhaust all established local practices to first use bargaining unit employees including where applicable, double shifting, early call-in, and overtime.
(c) If there is no established local practice, the following shall apply with regard to inside work. Within each building, each operation will maintain appropriate list(s), by seniority, of those part-time employees requesting coverage work. It will be the employees’ responsibility to sign up on the appropriate list. The Company shall post such lists and employees who are interested in adding their names to the lists shall do so on the first working day of each month. It will be the employee’s responsibility to make sure his/her their contact information is correct. Employees who are unavailable to work on three (3) separate occasions within a calendar month shall have their names removed from the coverage list. Those employees shall be eligible to re-sign the list the following month. When coverage work is available, the Company will use the appropriate list to fill the required positions, and such employees will work as assigned. The employee must be qualified for the available work and double shift employees shall have seniority among themselves. No employee is allowed to work more than two (2) shifts in any twenty-four (24) hour period. Local call verification practices and procedures shall remain in place. Nothing contained in this Section shall change existing practices or procedures covering full-time work.
(d) If it is determined at any step of the grievance and/or arbitration procedure that this Section, or a “supervisor working” provision in a Supplement, Rider or Addendum, has been violated, the aggrieved employee will be paid as follows: (i) if the actual hours worked by the supervisor amounts to two (2) hours or less, the aggrieved employee will be paid for the actual hours worked by the supervisor at the rate of double time the employee’s rate of pay at the time of the incident; or (ii) if the supervisor works more than two (2) hours, the aggrieved employee shall be paid four (4) hours at straight time or actual hours worked at double time the employee’s rate of pay at the time of the incident, whichever is greater. If no aggrieved employee can be identified, the payment will be made to the grievant. Such remedy shall be in addition to any other remedies sought by the Union in the appropriate grievance procedure. If a Supplement, Rider, or Addendum does not have a provision requiring notice to the xxxxxxx when a supervisor works the following shall be incorporated: “In the event a supervisor does perform bargaining unit work, the Employer shall notify the appropriate shop xxxxxxx as soon as possible.” In the event that any individual supervisor is found to be in violation of the first paragraph of this Subsection three (3) times in any nine (9) month rolling period, the grievance shall be paid at triple quadruple time the employee’s rate of pay for the hours specified in the first paragraph of this subsection.
Operation of the Property Between June 1, 1998 and the Closing Date, Seller shall (a) lease, operate, manage and enter into contracts with respect to the Property, in the same manner done by Seller prior to the date hereof (provided, however, that without the prior consent of Purchaser, which as to (i) and (ii) shall not be unreasonably delayed, conditioned or withheld, (i) Seller shall not enter into any Service Contract that cannot be terminated with thirty (30) days notice or materially modify any existing Service Contracts to be assumed by Purchaser at Closing, and (ii) after June 1, 1998, Seller shall not materially modify or terminate any existing Tenant Lease or grant any material consents under any existing Tenant Lease (except as otherwise required pursuant to the terms and conditions of such Tenant Lease), or enter into any new Tenant Lease, and (iii) Seller shall not apply any then unapplied Deposits (as reflected on the Rent Roll delivered by Seller to Purchaser pursuant to Schedule 5.3(vii) hereof) under Tenant Leases); and (b) advise Purchaser of the commencement of any litigation, condemnation or other judicial or administrative proceedings affecting the Property of which Seller has current actual knowledge. Notwithstanding anything to the contrary set forth in this Contract, Purchaser acknowledges that after June 1, 1998 and prior to Closing, Seller will enter into contracts for the completion of Tenant improvements under Tenant Leases entered into after June 1, 1998 pursuant to the terms of Section 12.1 hereof (collectively, the "Tenant Finish Contracts"). Purchaser and Seller agree that at Closing, Purchaser shall assume the obligations of Seller under all such Tenant Finish Contracts including, without limitation, the obligations to pay any costs and expenses charged with respect to construction of improvements in the space subject to such Tenant Leases. At Closing, Purchaser shall execute and deliver to the Seller an Assignment, Assumption and Indemnity Agreement in the form attached hereto as Exhibit H and made a part hereof for all purposes.
Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain.
(b) Employees shall not be required to start a concrete pour in Inclement Weather.
(c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear.
(d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay.
(e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.
Construction Activities Please list all major construction activities, both planned and completed, to be performed by Seller or the EPC Contractor. Activity EPC Contractor / Subcontractor Completion Date __/__/____ (expected / actual) __/__/____ (expected / actual)
