Supply of Product 4.1 DAEWOONG shall manufacture and supply Product to AEON in a primary packaged and labeled form. Product packaging shall display the logo of DAEWOONG (to the extent required by applicable law) and AEON and the outer label shall be marked using English language in accordance with applicable laws and Product’s Regulatory Approvals.
4.2 AEON’s estimate sales forecast of the Product during the Term of Agreement in the Territory in the Field is set forth in Annex D. Within ninety (90) days after the Effective Date, AEON shall provide DAEWOONG with a non-binding twelve (12) month rolling forecast of its requirements of Product, which the Parties agree is not a commitment to buy any stated quantity. Thereafter, on at least a quarterly basis, AEON shall provide DAEWOONG with an updated twelve (12) month rolling forecast, together with a binding six (6) month forecast to the extent AEON has requested Safety Stock as described in Article 4.10 below. Each such forecast shah be referred to herein as a “Forecast.”
4.3 AEON may from time to time submit Purchase Orders to DAEWOONG for Product in accordance with the forecasting requirements in Article 4.2. Orders will be shipped on CIF Los Angeles port.
4.4 Once a Purchase Order for Product and Product Samples has been received by DAEWOONG, it shall be considered as irrevocable.
4.5 AEON agrees herein to place an Order for Product not later than [***] from receipt of Regulatory Approval.
4.6 Individual Purchase Orders of Product shall be placed at least [***] in advance of the required delivery date.
4.7 For the purpose of Commercialization, AEON will store and maintain the full quantity of Product in a clean, secured area in accordance with the reasonable directions and specifications provided by DAEWOONG in writing in connection thereof in the Territory. AEON will advise DAEWOONG on the applicable requirements specifically deriving from the laws and regulations in the Territory.
4.8 AEON agrees that DAEWOONG and its collaborators and agents, in DAEWOONG’s sole discretion, which collaborators and Agents will be subject to appropriate obligations of confidentiality, will have the right upon reasonable prior notice, to observe and to inspect and to audit AEON’s facility to ascertain compliance by AEON with the terms of this Agreement, including without limitation (a) the holding facilities for Product, and (b) AEON’s compliance with applicable law, including cGMP (if applicable). Following any such audit, DAEWOONG will discuss its observations and conclusions with AEON and corrective actions, if any, will be agreed upon by the Parties, and executed by AEON using Commercially Reasonable Efforts.
4.9 In addition to any other rights and remedies available to AEON, AEON shall have the right to recover lost profits in the event that DAEWOONG fails to deliver at least [***] in any [***] (a “Supply Default Event”). For purposes of this provision, lost profits would be equal to [***] of AEON operating profit (sales less direct expenses and the puce paid by AEON for such Products) on Products that have not been shipped against firm Purchase Orders during the period leading up to the Supply Default Event and bona fide Purchase Orders submitted by AEON that are consistent with the Forecast during the Supply Default Period (as defined below). Such payment shall be made with respect to all Product not shipped in the period giving rise to the Supply Default and for the period until DAEWOONG is again timely shipping Product to meet AEON’s needs (the “Supply Default Period”). The first such payment shall be made within [***] of the Supply Default Event, and every [***] thereafter. AEON agrees to permit full disclosure to DAEWOONG of AEON’s accounting records, solely related to the calculation of lost profits, for the [***] ending on the first day of the month in which the Supply Event Default occurred. In the event that DAEWOONG is unable to supply both AEON’s requirements of Product and its own and third parties’ requirements for Product, DAEWOONG shall allocate Product that DAEWOONG has in inventory and that DAEWOONG is able to Product, so that AEON receives its requirements of Product in priority to DAEWOONG and third parties.
4.10 At the request of AEON, DAEWOONG shall at its own cost and expense during the Term, maintain an amount of inventory of Product equal to AEON’s requirements for Product for [***] based on AEON’s most recent forecast (“Safety Stock”). The Safety Stock shall be (i) maintained for the sole benefit of AEON and its Affiliates, (ii) shall be stored at a secure facility in compliance with GMP, and (iii) shall not be used for the benefit of any other customer of DAEWOONG. DAEWOONG shall rotate the Safety Stock on a “First Expiry-First Out” basis for routine fulfillment of firm orders, subject to Article 7.
Supply of Products
3.1 The Supplier warrants that the Products shall:
(a) correspond with their description and any applicable Product Specification;
(b) conform in all respects with the Order and any relevant sample;
(c) be of satisfactory quality and fit for any purpose held out by the Supplier or made known to the Supplier by Ornua, expressly or by implication, and in this respect Ornua relies on the Supplier's skill and judgement;
(d) be manufactured by properly trained and qualified personnel using all reasonable skill, care and diligence and in a good and workmanlike manner;
(e) where they are manufactured products, be free from defects in design, materials and workmanship and remain so for the period set out in the Product Specification or, if none is specified, for at least 12 months after delivery;
(f) comply with all applicable statutory and regulatory requirements relating to the manufacture, labelling, packaging, storage, handling and delivery of the Products;
(g) comply with all relevant standards including any UK Standards, European Standards or International Standards applicable in the UK and the country or State where the Products are to be used; and
(h) in the case of Products containing food stuffs, when delivered to Ornua, comply with all applicable food and hygiene legislation and regulations and best industry practice.
3.2 The Supplier shall ensure that at all times it has and maintains all licences, permissions, authorisations, consents and permits needed to carry out its obligations under the Contract in respect of the supply of Products. Breach of this Condition shall be deemed a material breach of the Contract.
3.3 Ornua may inspect and test the Products at any time before delivery. The Supplier shall remain fully responsible for the Products despite any such inspection or testing and any such inspection or testing shall not reduce or otherwise affect the Supplier's obligations under the Contract.
3.4 If following such inspection or testing Ornua considers that the Products do not comply or are unlikely to comply with the Supplier's undertakings at clause 3.1, Ornua shall inform the Supplier and the Supplier shall immediately take such remedial action as is necessary to ensure compliance.
3.5 Ornua may conduct further inspections and tests after the Supplier has carried out its remedial actions.
SHIPPING/RECEIPT OF PRODUCT a. Packaging Tangible Product shall be securely and properly packed for shipment, storage and stocking in appropriate, clearly labeled shipping containers and according to accepted commercial practice, without any extra charges for packing materials, cases or other types of containers. The container shall become and remain the property of the Authorized User unless otherwise specified in the Contract documents.
SOURCE CODE ESCROW FOR LICENSED PRODUCT If Source Code or Source Code escrow is offered by either Contractor or Product manufacturer or developer to any other commercial customers, Contractor shall either: (i) provide Licensee with the Source Code for the Product; or (ii) place the Source Code in a third party escrow arrangement with a designated escrow agent who shall be named and identified to the State, and who shall be directed to release the deposited Source Code in accordance with a standard escrow agreement acceptable to the State; or (iii) will certify to the State that the Product manufacturer/developer has named the State, acting by and through the Authorized User, and the Licensee, as a named beneficiary of an established escrow arrangement with its designated escrow agent who shall be named and identified to the State and Licensee, and who shall be directed to release the deposited Source Code in accordance with the terms of escrow. Source Code, as well as any corrections or enhancements to such source code, shall be updated for each new release of the Product in the same manner as provided above and such updating of escrow shall be certified to the State in writing. Contractor shall identify the escrow agent upon commencement of the Contract term and shall certify annually that the escrow remains in effect in compliance with the terms of this clause. The State may release the Source Code to Licensees under this Contract who have licensed Product or obtained services, who may use such copy of the Source Code to maintain the Product.
Supply of Services 7.1 Supplier shall provide the Services to Purchaser in accordance with the Order in all material respects using reasonable care and skill.
7.2 Supplier shall use reasonable endeavours to meet any performance dates for the Services specified in the Order but any dates shall be estimates only and time shall not be of the essence for the performance of the Services.
7.3 Supplier shall have the right to make any changes to the Services which are necessary to comply with any applicable law or safety requirements or which do not materially affect the nature or quality of the Services.
7.4 Purchaser shall: (a) ensure that the terms of Order are complete and (if submitted by Purchaser) the service specification are complete and accurate; (b) co-operate with Supplier in all matters relating to the Services; (c) provide Supplier, its employees, agents, consultants and subcontractors with access to Purchaser’s premises, machinery and other facilities as reasonably required by Supplier to provide the Services; and (d) provide Supplier with such information and materials as Supplier may reasonably require to supply the Services, and ensure that such information is accurate in all material respects.
7.5 If Supplier’s performance of any of its obligations in respect of the Services is prevented or delayed by an any act or omission by Purchaser or failure by Purchaser to performs its obligations (“Purchaser Default”) Supplier shall without limiting its other rights or remedies have the right to suspend performance of the Services until Purchaser remedied Purchaser Default and relieves Supplier from its obligations to the extent the Customer Default prevents or delays Supplier’s performance. Purchaser shall indemnify Supplier against all liabilities costs, losses and expenses which Supplier may incur by reason of Purchaser Default.
7.6 Where the Services consist of any experimental or developmental work, the results supplied or recommendations made under the Services are given in good faith within the limitations of the data available, but no warranty, expressed or implied, is given as to the ability of Supplier to achieve a specific outcome, nor the accuracy of results obtained.
7.7 Any claims by Purchaser which is based on defect in the Services shall be notified to Supplier within twenty-one (21) days of the services being performed and promptly after discovery of defect or failure. The sole and exclusive remedy of Purchaser for such defect hereunder shall be the re-performance or re- fund, at Supplier’s option, of any defective or non-conforming Services.
Supply Agreement Seller and Buyer, or their Affiliates, shall have executed the Supply Agreement.
Development Milestone Payments (i) In addition to the Closing Date Merger Consideration (less the Remaining Option Consideration and Rights Proceeds Amount, if any) and any Net TNF Sales Payments (as defined below), upon the attainment of the development ** Portions of the Exhibit have been omitted and have been filed separately pursuant to an application for confidential treatment filed with the Securities and Exchange Commission pursuant to Rule 24b-2 under the Securities Exchange Act of 1934, as amended. milestones set forth below (each, a “Development Milestone”), Parent shall, or shall cause the Surviving Corporation to, [**] after the occurrence of each Development Milestone, deliver to the Paying Agent (for further payment to the holders of Stock Certificates and Stock Agreements outstanding immediately prior to the Effective Time), via wire transfer of immediately available funds, the respective amounts set forth below minus, in each case, the applicable Contingent Consideration Distribution Fee associated therewith and any amount designated by the Stockholders’ Representatives to be placed in the Administrative Expense Account (each, a “Development Milestone Payment” and collectively, the “Development Milestone Payments”):
(A) Upon FDA approval of Reslizumab for the treatment of eosinophilic esophagitis, a cash payment of [**];
(B) Upon marketing authorization of Reslizumab for the treatment of eosinophilic esophagitis being granted by the European Commission in accordance with Regulation (EC) No. 726/2004, a cash payment of [**];
(C) If Res 5-0010 Asthma Study Completion has not occurred on or prior to the Closing Date, then upon the occurrence of the Res 5-0010 Asthma Study Completion, a cash payment of $50,000,000 (fifty million dollars) (the “Res 5-0010 Asthma Payment”);
(D) Upon FDA approval of Reslizumab for any asthma indication, a cash payment of [**];
(E) Upon marketing authorization of Reslizumab for the treatment of any asthma indication being granted by the European Commission in accordance with Regulation (EC) No. 726/2004, a cash payment of [**]; and
(F) Upon FDA approval of an Oral Anti-TNF Product, a cash payment of [**].
Supply of Materials The following materials will be supplied by the department Name of Materials Rate. Place of delivery 1.
Sales Milestone Payments Artiva shall make the following one-time, non-refundable and non-creditable sales milestone payments to GCLC when the aggregate annual Net Sales of Products in the Territory first reach the thresholds specified below. Artiva shall notify GCLC promptly of the achievement of each such sales threshold. Each sales milestone payment shall be made by Artiva within [***] days after the end of the calendar quarter in which such sales threshold is achieved. To the extent more than one sales threshold is reached in any given calendar year, then the applicable milestone payment for each such achievement shall be due and owing with respect to such calendar year. For clarification, the total milestone payments payable hereunder if all milestone events are achieved is [***].
Net Sales The term “
