T itle and Risks Sample Clauses
Related to T itle and Risks
Title and Risk 6.1 The risk in the Goods shall pass to the Customer on completion of delivery.
Title and Risk of Loss Notwithstanding the form of shipment, title or other property interest, risk of loss shall not pass from the Contractor to the Authorized User until the Products have been received, inspected and accepted by the receiving entity. Acceptance shall occur within a reasonable time or in accordance with such other defined acceptance period as may be specified in the Bid Specifications or Purchase Order. Mere acknowledgment by Authorized User personnel of the delivery or receipt of goods (e.g., signed xxxx of lading) shall not be deemed or construed as acceptance of the Products received. Any delivery of Product that is substandard or does not comply with the Bid Specifications or Contract terms and conditions, may be rejected or accepted on an adjusted price basis, as determined by the Commissioner.
DELIVERY, TITLE AND RISK OF LOSS Unless otherwise specified on the EDDYFI quotation, delivery is FCA (Manufacturing Site). In any case, delivery and risk of loss is in accordance with INCOTERMS 2010. Title to products shall pass to the Customer upon full payment of the invoice(s). In the absence of specific instructions, goods will be shipped via the carrier EDDYFI deems most practical. No claim for error in shipment will be considered unless made within ten (10) days of Customer’s receipt of goods.
Title and Characteristics of Property Seller, as of the date of execution of this Agreement, owns the Property in fee simple and has marketable and good title of public record and, in fact, the Property at Closing shall have the title status as described in Section VIII of this Agreement.
Risks This notification is missioned to reveal to the Customer the information regarding risks connected with conducting trading operations on the financial markets and to warn the Customer about possibility of financial losses related to these risks. In the present Agreement it is impossible to disclose all information about all potential risks due to sheer number of possible situations. The interpretation of the notions and terms used in this notification fully coincides with interpretation of those in the Agreement on processing and executing the Customer orders.
Title and Ownership Contractor warrants and represents that it has (i) full ownership, clear title free of all liens, or (ii) the right to transfer or deliver specified license rights to any Products acquired by Authorized User under this Contract. Contractor shall be solely liable for any costs of acquisition associated therewith. Contractor shall indemnify Authorized Users and hold Authorized Users harmless from any damages and liabilities (including reasonable attorneys’ fees and costs) awarded by a court of competent jurisdiction arising from any breach of Contractor’s warranties as set forth herein.
Delivery and Risk of Loss Unless otherwise provided for in advance, all shipments will be made F.O.B. Seller's facility, and upon Seller's delivery of a shipment to the carrier, Buyer shall assume the risk of any loss or damage to the shipment thereafter. Delivery and/or completion dates furnished by Seller represent the best estimates of the time required to make shipment or complete services, and Seller does not guarantee delivery or completion by a particular date unless otherwise stated herein or in any schedule or addendum attached hereto. If a delivery date for products is guaranteed herein, (a) Seller’s unexcused delay in delivering one installment to the carrier at Seller’s facility shall permit Buyer to cancel only that installment, and acceptance by Buyer or the act of taking possession of products by the carrier shall constitute a bar to any claim of late delivery with respect to such products and (b) Buyer shall not be excused from performance if for any reason, the carrier does not pick up products on the date specified for shipping, and Seller may dispose of any products which the carrier does not pick-up within five (5) days of the date agreed for delivery to the carrier at Seller’s facility if Buyer refuses acceptance based on such delay, in which case Seller may cancel the order without notice to Buyer and Buyer shall be responsible for a 25% restocking fee as to the products ordered. In any such event, Seller shall have no duty to mitigate its damages. Seller may deliver any products subject to an order to the carrier at its facility in part and in such event, Buyer shall be responsible for payment for that part of the order received by the carrier, and Seller shall only be responsible for that portion of an order which Seller is required to but does not deliver. Unless otherwise required by a contract of Buyer with a customer of Buyer with respect only to products ordered by such customer, Title shall not pass with respect to any products ordered until Buyer makes payment in full thereof. In the alternative, Seller reserves a purchase money security interest in the products sold as well as any other products or property forwarded to Seller by Buyer for servicing or evaluation until full payment has been received. Buyer agrees to execute any document appropriate or necessary to perfect Seller's security interest or to acknowledge that title remains with Seller. In the alternative, Seller may file this order as a financing statement and/or chattel mortgage. Buyer agrees that, upon its failure to pay any invoice when due, Seller may immediately foreclose upon and sell, in a manner determined by Seller, any products or property owned by or provided by Buyer to Seller, regardless of whether such products or property are the subject of the unpaid invoice, in order to allow Seller to recover all amounts, including but not limited to interest and penalties, owed by Buyer to Seller.
Delivery and Risk 7.1 Unless otherwise stated in the Order, the price quoted includes delivery to the address specified in the Order.
Title and Ownership Warranty Contractor warrants, represents and conveys (i) full ownership, clear title free of all liens, or (ii) the right to transfer or deliver perpetual license rights to any Products transferred to Authorized User under this Contract. Contractor shall be solely liable for any costs of acquisition associated therewith. Contractor fully indemnifies the Authorized User for any loss, damages or actions arising from a breach of said warranty without limitation.
RISK AND TITLE (a) Risk of damage to or loss of Products will pass to Customer (i) upon delivery by Signify to Customer in accordance with the applicable INCOTERM; or (ii) in the event that Signify Installs Products on-site, unless agreed otherwise, upon delivery on-site.
