Substantial Taking If the whole of the Premises, or such part thereof as shall substantially interfere with Tenant's use and occupancy of the Premises, as contemplated by this Lease, is taken for any public or quasi-public purpose by any lawful power or authority by exercise of the right of appropriation, condemnation or eminent domain, or sold to prevent such taking, either party will have the right to terminate this Lease effective as of the date possession is required to be surrendered to such authority.
Partial Taking If any part of the Premises is taken and the remaining part after Landlord makes repairs and alterations is reasonably suitable, as reasonably determined by Landlord and Tenant, for Tenant’s continued occupancy for the purposes and uses permitted by this Lease, this Lease shall, as to the part so taken terminate as of the date that possession of such part of the Premises is taken and the Base Monthly Rental shall be reduced in the same proportion that the floor area of the portion of the Building so taken (less any addition thereto by reason of any reconstruction) bears to the original floor area of the Building. Tenant shall, at its sole cost and expense, make all necessary repairs or alterations to the Building so as to make the portion of the Building not taken a complete architectural unit in accordance with the terms and provisions of Section 19.4, Landlord shall make available to Tenant any condemnation proceeds it receives which are allocable to such portion of the Building in accordance with the terms and provisions of Section 19.4. Base Monthly Rental due and payable hereunder shall be temporarily abated during such restoration period in proportion to the degree to which Tenant’s use of Premises is impaired. Notwithstanding the foregoing, if more than twenty-five percent (25%) of the square footage of the Building is taken or sold under such threat, Landlord may terminate this Lease as of the date that the condemning authority takes possession by delivery of written notice of such election within twenty (20) days after Landlord has been notified of the taking or, in the absence thereof, within twenty (20) days after the condemning authority shall have taken possession.
Total Taking If the entire Building or Premises are taken by right of eminent domain or conveyed in lieu thereof (a “Taking”), this Lease shall terminate as of the date of the Taking.
Permanent Taking If the whole or any part of the Premises, Building or Project shall be taken by power of eminent domain or condemned by any competent authority for any public or quasi-public use or purpose, or if any adjacent property or street shall be so taken or condemned, or reconfigured or vacated by such authority in such manner as to require the use, reconstruction or remodeling of any part of the Premises, Building or Project, or if Landlord shall grant a deed or other instrument in lieu of such taking by eminent domain or condemnation, Landlord shall have the option to terminate this Lease upon ninety (90) days’ notice, provided such notice is given no later than one hundred eighty (180) days after the date of such taking, condemnation, deed or other instrument. If more than twenty-five percent (25%) of the rentable square feet of the Premises is taken, or if access to the Premises is substantially impaired, Tenant shall have the option to terminate this Lease upon ninety (90) days’ notice, provided such notice is given no later than one hundred eighty (180) days after the date of such taking. Landlord shall be entitled to receive the entire award or payment in connection therewith, except that Tenant shall have the right to file any separate claim available to Tenant for any taking of Tenant’s personal property and fixtures belonging to Tenant and removable by Tenant upon expiration of the Lease Term pursuant to the terms of this Lease, and for moving expenses, so long as such claim does not diminish the award available to Landlord, or its ground lessor or mortgagee with respect to the Project, and such claim is payable separately to Tenant. All Rent shall be apportioned as of the date of such termination, or the date of such taking, whichever shall first occur. If any part of the Premises shall be taken, and this Lease shall not be so terminated, the Base Rent and Tenant’s Share of Operating Expenses, Tax Expenses and Utilities Costs shall be proportionately abated. Tenant hereby waives any and all rights it might otherwise have pursuant to Section 1265.130 of The California Code of Civil Procedure.
Complete Taking 22 (b) Partial Taking..................................................... 22 (c) Award.............................................................. 22 (d) Notices............................................................ 22 24.
Delay of the Substantial Completion of the Premises Except as provided in this Section 5.2, the Lease Commencement Date shall occur as set forth in the Lease and Section 5.1, above. If there shall be a delay or there are delays in the Substantial Completion of the Premises or in the occurrence of any of the other conditions precedent to the Lease Commencement Date, as set forth in the Lease, as a direct, indirect, partial, or total result of:
Temporary Taking If the whole or any part of the Leased Property (other than the fee) or of Lessee’s interest under this Lease is condemned by any Condemnor for its temporary use or occupancy (which shall mean a period not to exceed two years), this Lease shall not terminate by reason thereof, and Lessee shall continue to pay, in the manner and at the terms herein specified, the full amounts of Base Rent and Additional Charges. In addition, Lessee shall pay Percentage Rent at a rate equal to the average Percentage Rent during the last three (3) preceding Fiscal Years (or if three (3) Fiscal Years shall not have elapsed, the average during the preceding Fiscal Years). Except only to the extent that Lessee may be prevented from so doing pursuant to the terms of the order of the Condemnor, Lessee shall continue to perform and observe all of the other terms, covenants, conditions and obligations hereof on the part of Lessee to be performed and observed, as though such Condemnation had not occurred. In the event of any Condemnation as in this Section 15.6 described, the entire amount of any Award made for such Condemnation allocable to the Term of this Lease, whether paid by way of damages, rent or otherwise, shall be paid to Lessee. Lessee covenants that upon the termination of any such period of temporary use or occupancy it will, at its sole cost and expense (subject to Lessor’s contribution as set forth below), restore the Leased Property as nearly as may be reasonably possible to the condition in which the same was immediately prior to such Condemnation, unless such period of temporary use or occupancy extends beyond the expiration of the Term, in which case Lessee shall not be required to make such restoration. If restoration is required hereunder, Lessor shall contribute to the cost of such restoration that portion of its entire Award that is specifically allocated to such restoration in the judgment or order of the court, if any, and Lessee shall fund the balance of such costs in a manner reasonably satisfactory to Lessor.
Tenant’s Entry Into the Premises Prior to Substantial Completion Subject to the terms hereof and provided that Tenant and its agents do not interfere with, or delay, Contractor’s work in the Building and the Premises, at Landlord’s reasonable discretion, Contractor shall allow Tenant access to the Premises prior to the Substantial Completion of the Premises for the purpose of Tenant installing any necessary furniture, equipment or fixtures (including Tenant’s data and telephone equipment) in the Premises. Prior to Tenant’s entry into the Premises as permitted by the terms of this Section 6.01, Tenant shall submit a schedule to Landlord and Contractor, for their approval, which schedule shall detail the timing and purpose of Tenant’s entry, and Landlord will reasonably cooperate with Tenant to coordinate Landlord’s Contractor’s work of constructing the Tenant Improvements with such access by Tenant for the installation of Tenant’s furniture, equipment and fixtures. In connection with any such entry, Tenant acknowledges and agrees that Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees shall fully cooperate, work in harmony and not, in any manner, interfere with Landlord or Landlord’s Contractor, agents or representatives in performing work in the Building and the Premises, or interfere with the general operation of the Building and/or the Project; and such entry shall be subject to the site management rules of Landlord and Landlord’s Contractor. If at any time any such person representing Tenant shall not be cooperative or shall otherwise cause or threaten to cause any such disharmony or interference, including, without limitation, labor disharmony, and Tenant fails to immediately institute and maintain corrective actions as directed by Landlord, then Landlord may revoke Tenant’s entry rights upon twenty-four (24) hours’ prior written notice to Tenant. Tenant acknowledges and agrees that any such entry into and occupancy of the Premises or any portion thereof by Tenant or any person or entity working for or on behalf of Tenant shall be deemed to be subject to all of the terms, covenants, conditions and provisions of the Lease, excluding only the covenant to pay Rent (until the occurrence of the Lease Commencement Date). Tenant further acknowledges and agrees that Landlord shall not be liable for any injury, loss or damage which may occur to any of Tenant’s work made in or about the Premises in connection with such entry or to any property placed therein prior to the Lease Commencement Date, the same being at Tenant’s sole risk and liability. Tenant shall be liable to Landlord for any damage to any portion of the Premises, including the Tenant Improvement work, caused by Tenant or any of Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees. If the performance of Tenant’s work in connection with such entry causes extra costs to be incurred by Landlord or requires the use of any Building services, Tenant shall promptly reimburse Landlord for such extra costs and/or shall pay Landlord for such Building services at Landlord’s standard rates then in effect. In addition, Tenant shall hold Landlord harmless from and indemnify, protect and defend Landlord against any loss or damage to the Building or Premises and against injury to any persons caused by Tenant’s actions pursuant to this Section 6.01.
TOTAL OR PARTIAL TAKING If all or a material portion of the Premises is taken by any lawful authority by exercise of the right of eminent domain, or sold to prevent a taking, either Tenant or Landlord may terminate this Lease effective as of the date possession is required to be surrendered to the authority. In the event title to a portion of the Building or Project, other than the Premises, is taken or sold in lieu of taking, and if Landlord elects to restore the Building in such a way as to alter the Premises materially, either party may terminate this Lease, by written notice to the other party, effective on the date of vesting of title. In the event neither party has elected to terminate this Lease as provided above, then Landlord shall promptly, after receipt of a sufficient condemnation award, proceed to restore the Premises to substantially their condition prior to the taking, and a proportionate allowance shall be made to Tenant for the rent corresponding to the time during which, and to the part of the Premises of which, Tenant is deprived on account of the taking and restoration. In the event of a taking, Landlord shall be entitled to the entire amount of the condemnation award without deduction for any estate or interest of Tenant; provided that nothing in this Section shall be deemed to give Landlord any interest in, or prevent Tenant from seeking any award against the taking authority for, the taking of personal property and fixtures belonging to Tenant or for relocation or business interruption expenses recoverable from the taking authority.
Taking If the entire Premises or so much of the Premises as to render the balance unusable by Tenant shall be taken by condemnation, sale in lieu of condemnation or in any other manner for any public or quasi-public purpose (collectively “Condemnation”), and if Landlord, at its option, is unable or unwilling to provide substitute premises containing at least as much rentable area as described in Section 1.02 above, then this Lease shall terminate on the date that title or possession to the Premises is taken by the condemning authority, whichever is earlier.
