Data Breaches Contractor shall notify the School District in writing as soon as commercially practicable, however no later than forty-eight (48) hours, after Contractor has either actual or constructive knowledge of a breach which affects the School District’s Data (an “Incident”) unless it is determined by law enforcement that such notification would impede or delay their investigation. Contractor shall have actual or constructive knowledge of an Incident if Contractor actually knows there has been an Incident or if Contractor has reasonable basis in facts or circumstances, whether acts or omissions, for its belief that an Incident has occurred. The notification required by this section shall be made as soon as commercially practicable after the law enforcement agency determines that notification will not impede or compromise the investigation. Contractor shall cooperate with law enforcement in accordance with applicable law provided however, that such cooperation shall not result in or cause an undue delay to remediation of the Incident. Contractor shall promptly take appropriate action to mitigate such risk or potential problem at Contractor’s or OPERATOR’s expense. In the event of an Incident, Contractor shall, at its sole cost and expense, restore the Confidential Information, to as close its original state as practical, including, without limitation any and all Data, and institute appropriate measures to prevent any recurrence of the problem as soon as is commercially practicable. Contractor will conduct periodic risk assessments and remediate any identified security vulnerabilities in a timely manner. Contractor will also have a written incident response plan, to include prompt notification of the District in the event of a security or privacy incident, as well as best practices for responding to a breach of PII.
Data Breach In the event of an unauthorized release, disclosure or acquisition of Student Data that compromises the security, confidentiality or integrity of the Student Data maintained by the Provider the Provider shall provide notification to LEA within seventy-two (72) hours of confirmation of the incident, unless notification within this time limit would disrupt investigation of the incident by law enforcement. In such an event, notification shall be made within a reasonable time after the incident. Provider shall follow the following process: (1) The security breach notification described above shall include, at a minimum, the following information to the extent known by the Provider and as it becomes available: i. The name and contact information of the reporting LEA subject to this section. ii. A list of the types of personal information that were or are reasonably believed to have been the subject of a breach. iii. If the information is possible to determine at the time the notice is provided, then either (1) the date of the breach, (2) the estimated date of the breach, or (3) the date range within which the breach occurred. The notification shall also include the date of the notice. iv. Whether the notification was delayed as a result of a law enforcement investigation, if that information is possible to determine at the time the notice is provided; and v. A general description of the breach incident, if that information is possible to determine at the time the notice is provided. (2) Provider agrees to adhere to all federal and state requirements with respect to a data breach related to the Student Data, including, when appropriate or required, the required responsibilities and procedures for notification and mitigation of any such data breach. (3) Provider further acknowledges and agrees to have a written incident response plan that reflects best practices and is consistent with industry standards and federal and state law for responding to a data breach, breach of security, privacy incident or unauthorized acquisition or use of Student Data or any portion thereof, including personally identifiable information and agrees to provide XXX, upon request, with a summary of said written incident response plan. (4) LEA shall provide notice and facts surrounding the breach to the affected students, parents or guardians. (5) In the event of a breach originating from XXX’s use of the Service, Provider shall cooperate with XXX to the extent necessary to expeditiously secure Student Data.
Default; Breach A “Default” is defined as a failure by the Lessee to comply with or perform any of the terms, covenants, conditions or Rules and Regulations under this Lease. A “Breach” is defined as the occurrence of one or more of the following Defaults, and the failure of Lessee to cure such Default within any applicable grace period:
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Notification of Anticipatory Breach Vendor agrees that should it, for any reason, not be able to provide or maintain appropriate safeguards to fulfill its obligations under this Section, it will immediately inform Citizens in writing of such inability and such inability on Vendor’s part will serve as justification for Citizens’ termination of this Agreement, at Citizens’ sole election, at any time after the inability becomes known to Citizens.
Breach A breach of the contract clauses above may be grounds for termination of the contract, and for debarment as a contractor and subcontractor as provided in 29 C.F.R. § 5.12.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Covenant Breaches The Borrower, any Guarantor or any of their respective Subsidiaries shall fail to (i) perform or observe any covenant contained in Section 5.02(a), Section 5.03, Section 5.06(e), Section 5.09, Section 5.12, or Article VI of this Agreement or (ii) fail to perform or observe any other term or covenant set forth in this Agreement or in any other Loan Document which is not covered by clause (i) above or any other provision of this Section 7.01 if such failure shall remain unremedied for 30 days after the occurrence of such breach or failure;
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
BREACH; TERMINATION In the event that (1) the Implementing Party is not able or fails to provide a Project(s) as required by the Agreement; or (2) GoTriangle is not able or fails to provide funding for a Project(s) as required by the Agreement; or (3) GoTriangle fails to fulfill its responsibilities and duties as set out in the Governance XXX; or (4) any Party fails to fulfill a responsibility or duty of this Agreement; or (5) any Party withdraws from the Master Participation Agreement (separately each a “breach”), any Party to this Agreement shall notify the Clerk to the TPAC Committee and the other Parties to this Agreement. The Non-Breaching party may place the item on a TPAC agenda for discussion and a non-binding recommendation to the Parties. The Non-breaching Party may provide the Breaching Party with a period of time to cure the breach to the reasonable satisfaction of the Non-breaching Party. If the breach is not timely cured, or cannot be cured, the Non-breaching Party may (1) elect to terminate this Agreement in full; or (2) elect to terminate this Agreement only as to one or more Projects listed in Exhibit A. In the event of breach of this Agreement, the Parties shall be entitled to such legal or equitable remedy as may be available, including specific performance. In the event the Agreement is terminated for any reason other than by the end of the Term of the Agreement: (a) The Implementing Party shall not be required to continue implementing the Projects, but may elect to continue implementing the Projects using funds from sources other than the Wake Transit Tax. (b) GoTriangle shall reimburse the Implementing Party for any expenses for the Projects that have been approved in the annual work plan and made in reliance on this Agreement, whether or not a Reimbursement Request has been made by Implementing Party at the time of termination. The Implementing Party shall have sixty (60) days after the date of termination to submit all Reimbursement Requests. (c) The Implementing Party shall report the final status for its deliverable and GoTriangle shall do a final quarterly report and shall issue the annual report required by this Agreement.