Temporary Condemnation In the event of any temporary Condemnation of any Property or Tenant’s interest therein, this Agreement shall continue in full force and effect and Tenant shall continue to pay (or cause to be paid), in the manner and on the terms herein specified, the full amount of the Rent. Tenant shall continue to perform and observe (or cause to be performed and observed) all of the other terms and conditions of this Agreement on the part of the Tenant to be performed and observed. Provided no Event of Default has occurred and is continuing, the entire amount of any Award made for such temporary Condemnation allocable to the Term, whether paid by way of damages, rent or otherwise, shall be paid to Tenant. Tenant shall, promptly upon the termination of any such period of temporary Condemnation, at its sole cost and expense, restore the affected Property to the condition that existed immediately prior to such Condemnation, in material compliance with all applicable Legal Requirements, unless such period of temporary Condemnation shall extend beyond the expiration of the Term, in which event Tenant shall not be required to make such restoration.
Lease Termination Notwithstanding any other provisions in this Lease, this Lease will terminate and the Tenant must immediately vacate the Leased Premises upon:
(i) The date on which the Tenant is no longer enrolled as a student in a course of full-time study at the University of Toronto Mississauga, provided that the Tenant shall be deemed to be enrolled as a student in a course of full-time study to the last day of the summer recess immediately following the completion by the Tenant of a scholastic year of full-time study.
(ii) The Landlord and the Tenant agree that, once the Tenant ceases to be enrolled as a student in a course of full-time study at the University of Toronto Mississauga, the Tenant’s continued occupation of the Leased Premises constitutes a substantial interference with the Landlord’s lawful rights, privileges, and interests, and this is grounds for the Landlord to terminate the Lease.
(iii) The provisions of this subparagraph 7(k) are strictly for the benefit of the Landlord. The Landlord may, in its sole discretion, elect to waive any or all provision(s) of this subparagraph 7(k) and require the Tenant to remain in occupation of the Leased Premises to the end of the term of the Lease. Alternatively, if the Landlord (at its sole discretion) elects to waive any or all provision(s) of this subparagraph 7(k), the Landlord and the Tenant may mutually agree to change the term of the Lease to require or allow the Tenant to remain in occupation of the Leased Premises until a mutually agreed upon date prior to the end of the term of the Lease.
(iv) If either party has given notice to terminate this Lease pursuant to any provision herein, the Leased Premises may be shown to prospective Tenants between the hours of 8:00 am and 8:00 pm by the Landlord. Should the Tenant effectively deny the Landlord reasonable viewing rights.
(v) In the event that the Tenant is obliged to vacate the Leased Premises on or before a certain date, and the Landlord enters into a tenancy agreement with a third party to lease the Premises herein described for any period thereafter, and the Tenant fails to vacate the Leased Premises on or before the due date, thereby causing the Landlord to be liable to such third party, then the Tenant will indemnify the Landlord for all losses suffered thereby, including, without limiting the generality of the foregoing, all legal costs incurred by the Landlord, such legal costs to be computed on a full indemnity basis.
Damage or Destruction Condemnation (a) In the event of partial damage or destruction of the Property of a type which can, under the circumstances, be expected in the reasonable judgment of Seller and Buyer to be restored or repaired at a cost of $500,000 or less, then, this Contract shall be consummated on the Closing Date at the Purchase Price, and unless such damage has been repaired by Seller prior to Closing, Seller shall assign to Buyer the casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts expended by Seller for partial restoration and with a credit to Buyer for the amount of any deductible and/or uninsured damage.
(b) In the event that the Property shall have been damaged by fire or casualty, the cost of repair or restoration of which would, in the reasonable judgment of Seller and Buyer, exceed the sum of $500,000, then unless Seller has previously repaired or restored the Property to its former condition, at Buyer’s election, Seller shall either (i) pay over or assign to Buyer, on delivery of the Deed all casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts reasonably expended by Seller for partial restoration, with a credit to Buyer for the amount of any deductible and/or uninsured damage, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case, except for the Surviving Obligation, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto. Notwithstanding the foregoing, if Buyer elects to proceed with the transaction under clause (i) of this paragraph (b), in no event shall Seller be obligated to incur any out of pocket cost above $500,000 (whether attributable to a casualty being uninsured, underinsured or to any deductible).
(c) If all or part of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit and accrued interest thereon, if any, and, except for the Surviving Obligations, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto) or close title to the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's rights to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to close title to the Property, Seller shall credit the amount of said payment against the Purchase Price at the Closing.
Casualty; Condemnation (a) If any condemnation or conveyance in lieu thereof of all or any portion of the Real Property occurs or is threatened prior to Closing (written notice of which shall be given to Purchaser by Seller promptly upon its receipt), Purchaser may at its option, either (i) terminate this Agreement by written notice to Seller given within twenty (20) days after Purchaser is notified of such actual or possible proceedings (but before the Closing), in which case all of the Escrow Funds shall be returned to Purchaser and all further rights and obligations of the parties under this Agreement shall terminate, except those expressly stated to survive termination, or (ii) proceed to Closing without abatement of the Purchase Price, in which case all proceeds or award (less any expenses incurred by Seller) shall be assigned to Purchaser. If any condemnation or conveyance in lieu thereof is presently pending or occurs after the date hereof, Seller shall not settle or agree to accept any compensation for same without Purchaser’s prior written consent, not to be unreasonably withheld.
(b) In the event of loss or damage to the Property or any portion thereof which is not “major” (as hereinafter defined), this Agreement shall remain in full force and effect, and neither Purchaser nor Seller shall have the right to terminate this Agreement and the parties shall nonetheless consummate this transaction in accordance with this Agreement, without any abatement of the Purchase Price or any liability or obligation on the part of Seller by reason of said damage except as set forth in the next sentence. In such event, the transaction shall proceed as contemplated herein, Seller shall provide a credit against the Purchase Price equal to Seller’s interest in insurance proceeds that have been collected by Seller and assign to Purchaser all of Seller’s right, title and interest in the proceeds to be paid on the claim of loss, less any sums expended by Seller prior to Closing in connection with its insurance claim (including any deductibles paid) or for the restoration or repair of the damaged Property.
(c) In the event of a “major” loss or damage to the Property or any portion thereof, Purchaser may terminate this Agreement by written notice to Seller, in which event the Escrow Funds shall be returned to Purchaser. If Purchaser does not give written notice of termination of this Agreement within twenty (20) days after Seller sends Purchaser written notice of the occurrence of major loss or damage, then Purchaser shall be deemed to have elected to proceed with Closing, in which event, the transaction shall proceed as contemplated herein, Seller shall provide a credit against the Purchase Price equal to Seller’s interest in insurance proceeds that have been collected by Seller and assign to Purchaser all of Seller’s right, title and interest in the proceeds to be paid on the claim of loss, less any sums expended by Seller prior to Closing in connection with its insurance claim (including any deductibles paid) or for the restoration or repair of the damaged Property.
(d) For purposes of this Section 12, “major” loss or damage refers to loss or damage to the Property or any portion thereof: (i) such that the cost of repair or restoration of the damage to a condition substantially identical to that prior to the event of damage would be, either be equal to or greater than $500,000 or require more than 120 days after the loss or damage to repair and restore, as determined by an independent appraiser chosen by Purchaser and reasonably acceptable to Seller, or (ii) having a material adverse impact upon the ability or feasibility of operating a nursing home facility on the Property, in substantially the same manner as the Property is being operated by Seller on the date hereof. Within ten (10) days after its occurrence, Seller shall give Purchaser written notice of any casualty and, if then available, an estimate of the restoration costs and time for restoration.
Casualty or Condemnation If, prior to the Closing, the Improvements or any material portion thereof (having a replacement cost equal to or in excess of $100,000 are damaged or destroyed by fire or casualty, or are taken by eminent domain by any governmental entity, and Seller is unable to restore such damage or destruction prior to the Closing Date in the case of a casualty, then Buyer shall have the option, exercisable by written notice given to Seller at or prior to the Closing, to terminate this Agreement, whereupon all obligations of all parties hereto shall cease, the Deposit shall be returned to Buyer, and this Agreement shall be void and without recourse to the parties hereto except for provisions which are expressly stated to survive such termination. If Buyer does not elect to terminate this Agreement as aforesaid or if such damage or destruction or taking has a replacement cost or is in an amount of less than $100,000, Buyer shall proceed with the consummation of the Closing (to the extent then otherwise obligated to do so) without reduction or offset of the Purchase Price, and in such case, unless the Seller shall have previously restored the Real Property to its condition prior to the occurrence of any such damage or destruction, Seller shall pay over or assign to Buyer all amounts received or due from, and all claims against, any insurance company or governmental entity as a result of such destruction or taking, and Seller shall pay the applicable deductible amount under the insurance maintained by Seller. In the event of any such casualty or condemnation, Seller agrees to (a) provide Buyer with copies of all written communications between Seller or the Partnership and their insurance carriers or the applicable governmental authorities, as applicable, the subject matter of which is the adjustment of insurance proceeds or condemnation awards, and (b) allow Buyer to review and make comments to any proposed settlement arrangement proposed to be entered into by Seller or the Partnership with any such third party; provided, that after the Inspection Period, if Buyer has not terminated this Agreement, Seller shall not enter into any settlement arrangement concerning casualty or condemnation in excess of $50,000 without obtaining the prior written consent of Buyer, which consent may be granted or withheld in Buyer’s sole discretion.
Total Condemnation If all of the Premises is condemned by eminent domain, inversely condemned or sold under threat of condemnation for any public or quasi-public use or purpose ("Condemned"), this Lease shall terminate as of the earlier of the date the condemning authority takes title to or possession of the Premises, and Rent shall be adjusted to the date of termination.
Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow").
(b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement.
(d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant of this Tenant Work Letter or the Lease has occurred at any time on or before the Substantial Completion of the Premises and remains after the expiration of applicable notice and cure periods, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to cause the Contractor to suspend the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 4.2 above), and (ii) all other obligations of Landlord under the terms of this Tenant Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to a default by Tenant as described in Section 19.1 of the Lease or under this Tenant Work Letter, in addition to any other remedies available to Landlord under the Lease, at law and/or in equity, Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) business days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.
Condition of Property; Condemnation In the case of each Mortgage Loan, except as set forth in an engineering report prepared by an independent engineering consultant in connection with the origination of such Mortgage Loan, the related Mortgaged Property is, to the Seller's knowledge, in good repair and free and clear of any damage that would materially and adversely affect its value as security for such Mortgage Loan (except in any such case where an escrow of funds, letter of credit or insurance coverage exists sufficient to effect the necessary repairs and maintenance). As of the date of origination of the Mortgage Loan, there was no proceeding pending for the condemnation of all or any material part of the related Mortgaged Property. As of the Closing Date, the Seller has not received notice and has no knowledge of any proceeding pending for the condemnation of all or any material portion of the Mortgaged Property securing any Mortgage Loan. As of the date of origination of each Mortgage Loan and, to the Seller's knowledge, as of the date hereof, (a) none of the material improvements on the related Mortgaged Property encroach upon the boundaries and, to the extent in effect at the time of construction, do not encroach upon the building restriction lines of such property, and none of the material improvements on the related Mortgaged Property encroached over any easements, except, in each case, for encroachments that are insured against by the lender's title insurance policy referred to in representation 8 below or that do not materially and adversely affect the Value or current use of such Mortgaged Property and (b) no improvements on adjoining properties encroached upon such Mortgaged Property so as to materially and adversely affect the Value of such Mortgaged Property, except those encroachments that are insured against by the lender's title insurance policy referred to in representation 8 below.
Condemnation/Eminent Domain In the event that the Premises or any part thereof, or the whole or any part of the Building, shall be taken or appropriated by eminent domain or shall be condemned for any public or quasi-public use, or (by virtue of any such taking, appropriation or condemnation) shall suffer any damage (direct, indirect or consequential) for which Landlord or Tenant shall be entitled to compensation, then (and in any such event) this Lease and the Term hereof may be terminated at the election of Landlord by a notice in writing of its election so to terminate which shall be given by Landlord to Tenant within sixty (60) days following the date on which Landlord shall have received notice of such taking, appropriation or condemnation. In the event that a material part of the Premises or the means of access thereto shall be so taken, appropriated or condemned, and in either case, the remainder of the Premises or the mode of access thereto is, in Tenant’s reasonable judgment, unsuitable for the operation of Tenant’s business in the Premises, then (and in any such event) this Lease and the Term hereof may be terminated at the election of Tenant by a notice in writing of its election so to terminate which shall be given by Tenant to Landlord within sixty (60) days following the date on which Tenant shall have received notice of such taking, appropriation or condemnation. Upon the giving of any such notice of termination (either by Landlord or Tenant) this Lease and the Term hereof shall terminate on or retroactively as of the date on which Tenant shall be required to vacate any part of the Premises or shall be deprived of a substantial part of the means of access thereto, provided, however, that Landlord may in Landlord’s notice elect to terminate this Lease and the Term hereof retroactively as of the date on which such taking, appropriation or condemnation became legally effective. In the event of any such termination, this Lease and the Term hereof shall expire as of such effective termination date as though that were the Expiration Date as stated in Exhibit 1, and the Yearly Rent (together with Operating Costs Excess and Tax Excess) shall be apportioned as of such date. If neither party (having the right so to do) elects to terminate Landlord will, with reasonable diligence and at Landlord’s expense, restore the remainder of the Premises, or the remainder of the means of access, as nearly as practicably may be to the same condition as obtained prior to such taking, appropriation or condemnation in which event (i) the Total Rentable Area shall be equitably adjusted, (ii) a just proportion of the Yearly Rent, according to the nature and extent of the taking, appropriation or condemnation and the resulting permanent injury to the Premises and the means of access thereto, shall be permanently abated, and (iii) a just proportion of the remainder of the Yearly Rent, according to the nature and extent of the taking, appropriation or condemnation and the resultant injury sustained by the Premises and the means of access thereto, shall be abated until what remains of the Premises and the means of access thereto shall have been restored as fully as may be for permanent use and occupation by Tenant hereunder. Except for any award specifically reimbursing Tenant for moving or relocation expenses or for Tenant’s personal property, or for the unamortized value of any leasehold improvements paid for by Tenant (in excess of any Landlord contribution), there are expressly reserved to Landlord all rights to compensation and damages created, accrued or accruing by reason of any such taking, appropriation or condemnation, in implementation and in confirmation of which Tenant does hereby acknowledge that Landlord shall be entitled to receive all such compensation and damages, grant to Landlord all and whatever rights (if any) Tenant may have to such compensation and damages, and agree to execute and deliver all and whatever further instruments of assignment as Landlord may from time to time reasonably request. In the event of any taking of the Premises or any part thereof for temporary (i.e., not in excess of one (1) year) use, (i) this Lease shall be and remain unaffected thereby, and (ii) Tenant shall be entitled to receive for itself any award made to the extent allocable to the Premises in respect of such taking on account of such use, provided, that if any taking is for a period extending beyond the Term of this Lease, such award shall be apportioned between Landlord and Tenant as of the Expiration Date or earlier termination of this Lease.
