Completion of Landlord’s Work On or before the Target Commencement Date (subject to Tenant Delays and Force Majeure delays), Landlord shall substantially complete or cause to be substantially completed Landlord’s Work in a good and workmanlike manner, with the Building Shell in a water tight condition, in accordance with the TI Permit subject, in each case, to Minor Variations and normal “punch list” items of a non-material nature that do not interfere with the use of the Premises and with a certificate or temporary certificate of occupancy (or an equivalent approval having been issued) for the Premises permitting lawful occupancy of the Premises (but specifically excluding any permits, licenses or other governmental approvals required to be obtained in connection with Tenant’s operations in the Premises)(“Substantial Completion” or “Substantially Complete”). Upon Substantial Completion of Landlord’s Work, Landlord shall require the TI Architect and the general contractor to execute and deliver, for the benefit of Tenant and Landlord, a Certificate of Substantial Completion in the form of the American Institute of Architects (“AIA”) document G704, and Landlord will require the vendors installing the major mechanical equipment to perform operational testing/commissioning of their respective equipment to confirm that the same are in good working order and functioning as designed. Upon Tenant’s request, Landlord will deliver “as built” drawings of the Tenant Improvements to Tenant and will provide copies of all warranties and manuals relating to any components of the Tenant Improvements for which such items are provided. For purposes of this Work Letter, “Minor Variations” shall mean any modifications reasonably required: (i) to comply with all applicable Legal Requirements and/or to obtain or to comply with any required permit (including the TI Permit); (ii) to comply with any request by Tenant for modifications to the Tenant Improvements; (iii) to comport with good design, engineering, and construction practices that are not material; or (iv) to make reasonable adjustments for field deviations or conditions encountered during the construction of Landlord’s Work.
Tenant's Responsibility Landlord shall not be liable to Tenant or to any other person for (i) damage to property or injury or death to persons due to the condition of the Leased Premises, the Building or the common areas, or (ii) the occurrence of any accident in or about the Leased Premises or the common areas, or (iii) any act or neglect of Tenant or any other tenant or occupant of the Building or of any other person, unless such damage, injury or death is directly and solely the result of Landlord's negligence; and Tenant hereby releases Landlord from any and all liability for the same. Tenant shall be liable for, and shall indemnify and defend Landlord from, any and all liability for (i) any act or neglect of Tenant and any person coming on the Leased Premises or common areas by the license of Tenant, express or implied, (ii) any damage to the Leased Premises, and (iii) any loss of or damage or injury to any person (including death resulting therefrom) or property occurring in, on or about the Leased Premises, regardless of cause, except for any loss or damage covered by Landlord's all risk coverage insurance as provided in Section 8.02 and except for that caused solely and directly by Landlord's negligence. This provision shall survive the expiration or earlier termination of this Lease.
Landlord’s Rights Regarding Use In addition to the rights specified elsewhere in this Lease, Landlord shall have the following rights regarding the use of the Leased Premises or the Common Areas, each of which may be exercised without notice or liability to Tenant except as herein provided to the contrary: (a) if Tenant or a Permitted Transferee does not lease one hundred percent (100%) of the Building, Landlord may install such signs, advertisements or notices or tenant identification information on the directory board or tenant access doors as it shall deem necessary or proper; provided the same does not materially interfere with access to the Leased Premises; (b) if Tenant or a Permitted Transferee does not lease one hundred percent (100%) of the Building, Landlord shall have the right at any time to control, change but not materially diminish or otherwise alter the Common Areas in such manner as it reasonably deems necessary; (c) Landlord, its employees and agents and any mortgagee of the Building shall have the right to enter any part of the Leased Premises at reasonable times and upon reasonable notice and with the presence of a Tenant representative (except in the case of an emergency) for the purposes of examining or inspecting the same, showing the same to prospective purchasers, mortgagees or tenants and making such repairs, alterations or improvements to the Leased Premises or the Building as Landlord may deem necessary or desirable. Landlord shall incur no liability to Tenant for such entry, nor shall such entry constitute an eviction of Tenant or a termination of this Lease, or entitle Tenant to any abatement of rent therefor; providing Landlord shall use commercially reasonable efforts to minimize interference with Tenant's use of the Leased Premises in the exercise of its rights hereunder. Notwithstanding anything contained herein to the contrary, Landlord hereby acknowledges that Tenant maintains sensitive material within the Leased Premises and in the event Landlord, its employees and/or agents enter the Leased Premises (subject to the notice and presence of a Tenant representative to the extent required in the prior sentence), such individuals shall endeavor to exercise due care in maintaining the security of the Leased Premises and, if such entry is after normal working hours, shall secure the Leased Premises following such entry.
Landlord's Responsibility LANDLORD is not responsible for any loss, expense, injury or damage to any person or property caused by items including but not limited to:
Construction of Tenant Improvements After the Landlord and Ground Lessor (in accordance with Paragraph 12 hereof) approve Tenant’s Plans and Tenant receives any necessary building permits, Tenant shall administer and diligently prosecute the construction of Tenant Improvements in accordance with Tenant’s Plans, in compliance with applicable Laws, and using building standard material, subject to Landlord’s right, at its election, to itself construct the Restroom Improvements. All Tenant Improvements (other than, if applicable, the Restroom Improvements) shall be constructed by Tenant’s Contractor (and/or its subcontractors), and Tenant shall be responsible for project management with respect to construction of the Tenant Improvements. During construction of the Tenant Improvements, Tenant and its contractors and subcontractors (i) shall not interfere with the access to, use of, or business conducted within any other portions of the Project by other tenants or occupants, (ii) shall use diligent efforts to coordinate the timing of work, deliveries and other construction matters with tenants or occupants of the Project that could be adversely impacted by such work, deliveries and construction matters, including, without limitation, by scheduling work CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. that would create noise, vibrations, dust or other similar annoyances to other tenants or occupants of the Project outside normal business hours, notwithstanding any additional cost (for overtime or otherwise) that Tenant may incur, (iii) shall clean and secure construction and staging areas daily, (iv) shall stage all construction and store all construction materials and equipment in a location designated by Landlord (in Landlord’s sole discretion) on the Project, and (v) shall otherwise abide by all rules and requirements established or imposed by Landlord relating to the performance of the Tenant Improvements, including rules relating to any required shutdown of utilities (including life-safety systems), storage of materials, and coordination of work with other tenant’s or occupant’s contractors. Tenant shall not be charged any construction management fee for Landlord’s review of Tenant’s Plans or any oversight of the construction of the Tenant Improvements.
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.
