We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.
For more information visit our privacy policy.LANDLORD'S SERVICES Provided Tenant is not in default hereunder and is occupying a substantial portion of the Premises, Landlord, at Xxxxxxxx's expense (but subject to the reimbursement provisions of Article 5 and except as otherwise provided in this Lease) shall furnish to Tenant the following services: (a) Air-conditioning and central heat at such temperatures and in such amounts as are reasonably considered by Landlord to be standard for the Building, during normal business hours for the Building as set forth in the Rules and Regulations attached as Exhibit "E" hereto. (b) Janitorial cleaning services in the Premises and public and exterior portions of the Building for all days, except Saturdays, Sundays and holidays; provided, however, if Tenant's floor covering or other improvements are other than Building Standard, Tenant shall pay the additional cleaning cost attributable thereto as additional Rent upon presentation of a statement therefor by Landlord. (c) Hot and cold water at those points of supply provided for general use of other tenants in the Building. (d) Normal and customary routine maintenance for all public, structural, and exterior portions of the Project according to Landlord's standards. (e) Electric lighting service for all public portions of the Project in the manner and to the extent reasonably deemed by Landlord to be standard for comparable buildings in the market area. (f) Automatic passenger elevator service for access to and egress from the Premises. Freight elevator service, in common with other tenants, shall be provided during reasonable business hours as prescribed by Landlord, exclusive of Saturdays, Sundays, and holidays. Landlord may reduce the number of elevators operating outside of business hours. (g) All Building Standard fluorescent bulb replacement in all common and public areas, toilet and restroom areas and stairwells. (h) Electrical facilities to furnish sufficient power for typewriters, calculating machines and other machines of similar low electrical consumption (total electrical power requirement not to exceed one watt per square foot of rentable area); but not including electricity required for electronic data processing equipment, special lighting in excess of Building Standard, and any other item of electrical equipment, the electrical power equipment of which (singly) is more than 0.5 kilowatts per hour at rated capacity or requires a voltage other than 120 volts single phase; and provided that Landlord shall not be obligated to provide (unless otherwise specifically agreed upon in writing) dedicated circuits or electrical power in excess of Building Standard and provided that if the installation of said electrical equipment requires additional air conditioning capacity above that provided by the Building Standard system, then the additional air conditioning installation and operating costs will be the obligation of Tenant. Landlord, at its option, may cause a water meter, electric current meter or such similar device to be installed on the Premises so as to measure the amount of water and electric current consumed by Tenant. The cost of any such meters and of the installation, maintenance and repair thereof shall be paid for by Xxxxxx and Xxxxxx agrees to pay to Landlord, promptly upon demand by Landlord, for all such excess water and electric expense incurred. If a separate meter is not installed or Landlord is prevented from installing a separate meter by operation of law or other cause beyond Landlord's control, such excess costs for such water and electric current will be established by an estimate made by the utility company, electrical engineer, or an independent consultant, which estimate shall be binding on Tenant. (i) Security services as Landlord may from time to time reasonably deem to be standard for comparable buildings in the market area. NOTWITHSTANDING ANYTHING HEREIN TO THE CONTRARY, TENANT EXPRESSLY ACKNOWLEDGES AND AGREES THAT LANDLORD IS NOT WARRANTING THE EFFICACY OF ANY SUCH SECURITY PERSONNEL, SERVICE, PROCEDURES OR EQUIPMENT AND THAT TENANT IS NOT RELYING AND SHALL NOT HEREAFTER RELY ON ANY SUCH PERSONNEL, SERVICE, PROCEDURES OR EQUIPMENT. LANDLORD SHALL NOT BE RESPONSIBLE OR LIABLE IN ANY MANNER FOR FAILURE OF ANY SUCH SECURITY PERSONNEL, SERVICES, PROCEDURES OR EQUIPMENT TO PREVENT OR CONTROL, OR APPREHEND ANYONE SUSPECTED OF, PERSONAL INJURY OR DAMAGE IN, ON OR AROUND THE PROJECT.
Use of the Leased Premises (a) Lessor, in consideration of the rents to be paid and covenants herein contained, hereby leases to Lessee the Leased Premises. (b) Lessee may use the Leased Premises for the operation of the station, and, in connection therewith, for the installation, repair, maintenance, operation, housing and removal of its Improvements and other related broadcasting equipment (together comprising the “Installations”). Lessee is fully familiar with the physical condition of the Land and has received the same in good order and condition, and agrees that the Land complies in all respects with all requirements of this Agreement. Lessee shall use the Land exclusively for purposes associated with the operation of the station. (c) Lessee shall have the right from time to time to substitute Installations of similar kind and character for those hereinabove specified, including without limitation, the rebuilding and reconfiguring of the towers on the Real Property, provided such changes shall be approved in advance by Lessor, and Lessor shall not unreasonably delay or withhold its approval. In the event Lessee submits any such changes for Lessor’s approval and Lessor does not respond within thirty (30) days after Lessor’s receipt thereof, then such changes shall be deemed approved by Lessor, so long as such changes otherwise comply with this Agreement. (d) Lessee shall have access to the Leased Premises twenty-four (24) hours per day, seven (7) days per week, for the purpose of installing, maintaining and repairing its Installations, provided that the contractors performing such work are reasonably acceptable to Lessor. (e) Lessor shall not be responsible for repairs or maintenance to the Installations, except for repairs occasioned by the negligence of Lessor, its agents, employees or contractors. (f) Lessee shall not use or permit the Leased Premises to be used by any dangerous, toxic, noxious or offensive trade or business, or for any unlawful purpose. (g) Lessee shall not directly or indirectly create or permit to be created or to remain, and will discharge any mortgage, lien, security interest, encumbrance or charge on, pledge of or conditional sale or other title retention agreement with respect to the Real Property or any part thereof or Lessee’s interest therein other than (i) this Agreement, (ii) any lien, including a mortgage on the leasehold interest of Lessee, which may be approved by the Lessor in writing, which approval shall not be unreasonably withheld, (iii) liens for impositions not yet payable, or payable without the addition of any fine, penalty, interest or cost for non-payment, or being contested as permitted by Paragraph 3(d), below, and (iv) liens of mechanics, materialmen, suppliers or vendors, or rights thereto, incurred in the ordinary course of business for sums which under the terms of the related contracts are not at the time due, provided that adequate provision for the payment thereof shall have been made.
LANDLORD'S MAINTENANCE Subject to the provisions of Articles 4 and 14, Landlord shall, as an Operating Expense, maintain and make necessary repairs to the foundations, roofs, exterior walls, and the structural elements of the Building, the electrical, plumbing, heating, ventilating, air-conditioning, mechanical, communication, security and the fire and life safety systems of the Building and those corridors, washrooms and lobbies which are Common Areas of the Building, except that: (a) Landlord shall not be responsible for the maintenance or repair of any floor or wall coverings in the Premises or any of such systems which are located within the Premises and are supplemental or special to the Building’s standard systems; and (b) the cost of performing any of said maintenance or repairs whether to the Premises or to the Building caused by the negligence of Tenant, its employees, agents, servants, licensees, subtenants, contractors or invitees, shall be paid by Tenant, subject to the waivers set forth in Section 16.4. Landlord shall not be liable to Tenant for any expense, injury, loss or damage resulting from work done in or upon, or in connection with the use of, any adjacent or nearby building, land, street or alley.
Landlord Work Prior to the execution of this First Amendment, Landlord and Tenant have approved (i) a detailed space plan for the construction of Landlord’s Work in the Premises, which space plan has been prepared by Studio O + A (“Final Approved Plan”) and (ii) a bid proposal for the construction of Landlord’s Work in the Premises, which bid proposal has been prepared by XX Xxxx Construction and is dated June 2, 2011 (Rev-2) (“Bid Proposal”). The Final Approved Plan and Bid Proposal are approved by the parties as of the Effective Date, are attached hereto collectively, as Exhibit “D-1” and hereby replaces the original Approved Plan attached to the Lease as Exhibit “D-1”. Consequently, all references in the Work Letter to the “Approved Plan” shall mean and refer to the Final Approved Plan and Bid Proposal attached hereto as Exhibit “D-1”. Landlord agrees to construct the Landlord Work, pursuant to the terms and conditions set forth in the Work Letter and as depicted on the Approved Plan (as amended hereby). Landlord shall pay for the cost (including, the cost of obtaining all applicable building permits) of the design and construction of Landlord’s Work in an amount up to, but not exceeding, Two Hundred Twenty Two Thousand One Hundred Fifty and 00/100 Dollars ($222,150.00) plus any additional costs actually incurred by Landlord in excess of such $222,150.00 amount as a direct result of Landlord’s or Landlord’s contractor’s active negligence or willful misconduct or resulting from change order to the Approved Plans (as amended hereby) if such change order is initiated and executed by Landlord (the “Landlord’s Contribution”). Tenant shall pay for all costs in excess of the Landlord’s Contribution (“Over Allowance Amount”) which payment shall be made to Landlord in cash within thirty (30) days after Tenant’s receipt of invoice therefor from Landlord. Payment of the Over-Allowance Amount shall be in addition to Tenant’s obligation to pay to Landlord the cost of any Aggregate Extras as provided in Section 4 of the Work Letter.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Landlord’s Work The Landlord will provide and carry out, in accordance with the provisions of the Lease, including, without limitation, this Schedule, at the Tenant’s expense, all equipment and work other than Tenant’s Work required to be provided in order to render the Premises complete and suitable to open for business (the “Landlord’s Work”) including, but not limited to the following: • Connecting all utilities including, power to building and distribution panels to the Premises, including the requirement to provide via separate metering. • Connecting water, including without limitation hot water, to greenhouse area and distribution water tank(s). • Installation of a storage cooler. • All concrete work around the greenhouse and drive-way to the compost hut and floor for compost piles as designed. • Installation of necessary or required ventilation fans. • Installation or replacement of lighting, including without limitation any required high upper grow lights. • Installation of hand wash stations in the Premises. • Gas heaters and controls. • Any repairs or refurbishing of outer panels, germination room walls. The Tenant’s consent (not to be unreasonably withheld, conditioned or delayed), shall be required prior to the commencement of the Landlord’s Work. The Landlord shall provide, in such detail as the Tenant may reasonably request, all material documentation relating to the Landlord’s Work, including without limitation, any proposed plans and drawings, proposed agreements with any contractors or subcontractors and estimated costs to complete the Landlord’s Work. Subject to receiving the Tenant’s consent as contemplated herein, the Landlord shall commence the Landlord’s Work in accordance with the terms of this Lease. Upon completion of the Landlord’s Work, the Landlord shall provide the Tenant receipted invoices verifying the actual cost of completing the Landlord’s Work in the Premises. It is acknowledged and agreed that in consideration for the Tenant being responsible for all the costs associated with the Landlord’s Work as contemplated herein, the cost of the Landlord’s Work shall be included in total amount subject recoverable by the Tenant and to the Free Rent Period (as hereinafter defined) subject to the terms and conditions of this Schedule “D” and the Lease, generally.
Lessee's Improvements Since Lessor is the Insuring Party, Lessor shall not be required to insure Lessee-Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease.
Overstandard Tenant Use If Tenant uses water, electricity, heat or air conditioning in excess of that supplied by Landlord pursuant to Section 6.1 of this Lease, Tenant shall pay to Landlord, upon billing, the cost of such excess utility consumption, the cost of the installation, operation, and maintenance of equipment which is required to be installed in order to supply such excess consumption; and, to the extent no previously installed, Landlord may install devices to separately sub-meter any increased use and in such event Tenant shall pay the increased cost directly to Landlord, on demand, at the rates charged by the public utility company furnishing the same, including the cost of such additional metering (or sub-metering) devices. Tenant’s use of electricity shall never exceed the capacity of the feeders to the Property or the risers or wiring installation; provided, however, Tenant shall have the right, subject to the terms of Article 8, to increase such capacity. Notwithstanding anything to the contrary in this Lease, Tenant may operate the HVAC within the Premises at its discretion; provided, however, if Tenant desires to use heat, ventilation or air conditioning during hours other than those for which Landlord is obligated to supply such utilities pursuant to the terms of Section 6.1 of this Lease, Tenant shall reimburse Landlord for the actual cost of supplying chilled water and gas to the Premises during non-Building Hours at the actual rates charged by the utilities, which cost shall be equitably prorated among all Building occupants (other than the Bank) operating HVAC during the same non-Building Hours. For purposes of an example, Exhibit K, attached hereto, sets forth the calculation of such actual utilities costs, with the actual calculation being subject to the actual rates charged by the utilities. Landlord shall, at its sole cost, as part of the Core and Shell Work, provide a cloud-based software system (Workspeed) to allow Tenant to control Tenant’s after-hours HVAC.
Tenant’s Work Landlord and Tenant acknowledge and agree that certain work required for Tenant's occupancy of the Leased Premises, including but not limited to the procurement and installation of furniture, fixtures, equipment, artwork and interior signage are beyond the scope of the Tenant Improvements and shall be performed by Tenant or its contractors at Tenant's sole cost and expense. All such work ("Tenant's Work") shall be subject to Landlord's prior written approval. Tenant shall adopt a construction schedule for Tenant's Work in conformance with the Contractor's schedule, and shall perform Tenant's Work in such a way as not to hinder or delay the operations of Landlord or the Contractor in the Building. Any costs incurred by Landlord as a result of any interference with Landlord's operations by Tenant or its contractors shall be promptly paid by Tenant to Landlord upon demand. Landlord shall make all reasonable efforts to notify Tenant of any such interference of which Landlord has actual knowledge, but failure to provide such notice shall in no way limit Landlord's right to demand payment for such costs. Tenant's contractors shall be subject to Landlord's prior written approval, and to the administrative supervision of the Contractor. Tenant's Work shall comply with all of the following requirements: (a) Tenant's Work shall not proceed until Landlord has approved in writing: (i) Tenant's contractors, (ii) proof of the amount and coverage of public liability and property damage insurance carried by Tenant's contractors in the form of an endorsed insurance certificate naming Landlord, the Contractor, and the agents of Landlord and the Contractor as additional insureds, in an amount not less than two million dollars, and (iii) complete and detailed plans and specifications for Tenant's Work. (b) Tenant's Work shall be performed in conformity with a valid permit when required, a copy of which shall be furnished to Landlord before such work is commenced. In any event, all Tenant's Work shall comply with all applicable laws, codes and ordinances of any governmental entity having jurisdiction over the Building. Landlord shall have no responsibility for Tenant's failure to comply with such applicable laws. Any and all delay in obtaining a certificate of occupancy due to Tenant's vendors is the responsibility of Tenant and shall be a Tenant Delay. (c) In connection with Tenant's Work (e.g., delivering or installing furniture or equipment to the second floor of the Leased Premises), Tenant or its contractors shall arrange for any necessary hoisting or elevator service with Landlord and shall pay such reasonable costs for such services as may be charged by Landlord. (d) Tenant shall promptly pay Landlord upon demand for any extra expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, by reason of damage to existing work caused by Tenant or its contractors, or by reason of inadequate cleanup by Tenant or its contractors.
Subleased Premises Sublandlord hereby subleases to Subtenant and Subtenant hereby subleases from Sublandlord for the term, at the rental, and upon all of the conditions set forth herein, the Subleased Premises.