Casualty or Condemnation If, prior to the Closing, the Improvements or any material portion thereof (having a replacement cost equal to or in excess of $100,000 are damaged or destroyed by fire or casualty, or are taken by eminent domain by any governmental entity, and Seller is unable to restore such damage or destruction prior to the Closing Date in the case of a casualty, then Buyer shall have the option, exercisable by written notice given to Seller at or prior to the Closing, to terminate this Agreement, whereupon all obligations of all parties hereto shall cease, the Deposit shall be returned to Buyer, and this Agreement shall be void and without recourse to the parties hereto except for provisions which are expressly stated to survive such termination. If Buyer does not elect to terminate this Agreement as aforesaid or if such damage or destruction or taking has a replacement cost or is in an amount of less than $100,000, Buyer shall proceed with the consummation of the Closing (to the extent then otherwise obligated to do so) without reduction or offset of the Purchase Price, and in such case, unless the Seller shall have previously restored the Real Property to its condition prior to the occurrence of any such damage or destruction, Seller shall pay over or assign to Buyer all amounts received or due from, and all claims against, any insurance company or governmental entity as a result of such destruction or taking, and Seller shall pay the applicable deductible amount under the insurance maintained by Seller. In the event of any such casualty or condemnation, Seller agrees to (a) provide Buyer with copies of all written communications between Seller or the Partnership and their insurance carriers or the applicable governmental authorities, as applicable, the subject matter of which is the adjustment of insurance proceeds or condemnation awards, and (b) allow Buyer to review and make comments to any proposed settlement arrangement proposed to be entered into by Seller or the Partnership with any such third party; provided, that after the Inspection Period, if Buyer has not terminated this Agreement, Seller shall not enter into any settlement arrangement concerning casualty or condemnation in excess of $50,000 without obtaining the prior written consent of Buyer, which consent may be granted or withheld in Buyer’s sole discretion.
Damage or Destruction Condemnation (a) In the event of partial damage or destruction of the Property of a type which can, under the circumstances, be expected in the reasonable judgment of Seller and Buyer to be restored or repaired at a cost of $500,000 or less, then, this Contract shall be consummated on the Closing Date at the Purchase Price, and unless such damage has been repaired by Seller prior to Closing, Seller shall assign to Buyer the casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts expended by Seller for partial restoration and with a credit to Buyer for the amount of any deductible and/or uninsured damage.
(b) In the event that the Property shall have been damaged by fire or casualty, the cost of repair or restoration of which would, in the reasonable judgment of Seller and Buyer, exceed the sum of $500,000, then unless Seller has previously repaired or restored the Property to its former condition, at Buyer’s election, Seller shall either (i) pay over or assign to Buyer, on delivery of the Deed all casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts reasonably expended by Seller for partial restoration, with a credit to Buyer for the amount of any deductible and/or uninsured damage, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case, except for the Surviving Obligation, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto. Notwithstanding the foregoing, if Buyer elects to proceed with the transaction under clause (i) of this paragraph (b), in no event shall Seller be obligated to incur any out of pocket cost above $500,000 (whether attributable to a casualty being uninsured, underinsured or to any deductible).
(c) If all or part of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit and accrued interest thereon, if any, and, except for the Surviving Obligations, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto) or close title to the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's rights to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to close title to the Property, Seller shall credit the amount of said payment against the Purchase Price at the Closing.
Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow").
(b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement.
(d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
Damage, Destruction and Condemnation (a) Seller will bear the risk of loss for any damage, destruction, or condemnation that may occur prior to Closing. If any portion of the Property is damaged or destroyed prior to Closing, Purchaser may elect to terminate this Agreement, unless prior to Closing all that damage has been repaired and the Improvements restored or replaced to their condition prior to the damage. If any material portion of the Property is condemned or taken prior to Closing, Purchaser may elect to terminate this Agreement.
(b) Purchaser's election under this Section with respect to any condemnation or taking will be exercised by written notice to Seller within twenty (20) days after written notice from Seller of the condemnation or taking. Purchaser's election under this Section with respect to any damage or destruction not repaired prior to Closing will be exercised by written notice to seller within twenty (20) days of the later to occur of:
(i) written notice from Seller of the damage or destruction and Seller's inability to repair and restore prior to Closing; or
(ii) written notice from Seller's insurance carrier regarding the estimated cost of repair, replacement, or reconstruction and the portion of the repair, replacement, or reconstruction for which insurance proceeds will be made available. The Closing Date will be extended as necessary to give Purchaser time to make the election.
(c) If Purchaser elects to terminate this Agreement under this Section, neither party will have any further rights, duties, or obligations. If Purchaser does not elect to terminate this Agreement, this Agreement will remain in full force and the purchase contemplated in this Agreement, less any interest taken by condemnation, will be effected, and at the Closing, Seller will pay the Purchaser the amount of any deductible under Seller's insurance policy and will assign, transfer, and set over to Purchaser all of Seller's right, title, and interest to any condemnation awards or insurance proceeds that have been or that may later be made for the taking or destruction.
DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion.
b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination.
c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease.
d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.
Insurance Casualty Condemnation Restoration SECTION 8.1. INSURANCE SECTION 8.2. CASUALTY SECTION 8.3. CONDEMNATION SECTION 8.4. RESTORATION
Condition of Property; Condemnation In the case of each Mortgage Loan, except as set forth in an engineering report prepared by an independent engineering consultant in connection with the origination of such Mortgage Loan, the related Mortgaged Property is, to the Seller's knowledge, in good repair and free and clear of any damage that would materially and adversely affect its value as security for such Mortgage Loan (except in any such case where an escrow of funds, letter of credit or insurance coverage exists sufficient to effect the necessary repairs and maintenance). As of the date of origination of the Mortgage Loan, there was no proceeding pending for the condemnation of all or any material part of the related Mortgaged Property. As of the Closing Date, the Seller has not received notice and has no knowledge of any proceeding pending for the condemnation of all or any material portion of the Mortgaged Property securing any Mortgage Loan. As of the date of origination of each Mortgage Loan and, to the Seller's knowledge, as of the date hereof, (a) none of the material improvements on the related Mortgaged Property encroach upon the boundaries and, to the extent in effect at the time of construction, do not encroach upon the building restriction lines of such property, and none of the material improvements on the related Mortgaged Property encroached over any easements, except, in each case, for encroachments that are insured against by the lender's title insurance policy referred to in representation 8 below or that do not materially and adversely affect the Value or current use of such Mortgaged Property and (b) no improvements on adjoining properties encroached upon such Mortgaged Property so as to materially and adversely affect the Value of such Mortgaged Property, except those encroachments that are insured against by the lender's title insurance policy referred to in representation 8 below.
Condemnation/Eminent Domain In the event that the Premises or any part thereof, or the whole or any part of the Building, shall be taken or appropriated by eminent domain or shall be condemned for any public or quasi-public use, or (by virtue of any such taking, appropriation or condemnation) shall suffer any damage (direct, indirect or consequential) for which Landlord or Tenant shall be entitled to compensation, then (and in any such event) this Lease and the Term hereof may be terminated at the election of Landlord by a notice in writing of its election so to terminate which shall be given by Landlord to Tenant within sixty (60) days following the date on which Landlord shall have received notice of such taking, appropriation or condemnation. In the event that a material part of the Premises or the means of access thereto shall be so taken, appropriated or condemned, and in either case, the remainder of the Premises or the mode of access thereto is, in Tenant’s reasonable judgment, unsuitable for the operation of Tenant’s business in the Premises, then (and in any such event) this Lease and the Term hereof may be terminated at the election of Tenant by a notice in writing of its election so to terminate which shall be given by Tenant to Landlord within sixty (60) days following the date on which Tenant shall have received notice of such taking, appropriation or condemnation. Upon the giving of any such notice of termination (either by Landlord or Tenant) this Lease and the Term hereof shall terminate on or retroactively as of the date on which Tenant shall be required to vacate any part of the Premises or shall be deprived of a substantial part of the means of access thereto, provided, however, that Landlord may in Landlord’s notice elect to terminate this Lease and the Term hereof retroactively as of the date on which such taking, appropriation or condemnation became legally effective. In the event of any such termination, this Lease and the Term hereof shall expire as of such effective termination date as though that were the Expiration Date as stated in Exhibit 1, and the Yearly Rent (together with Operating Costs Excess and Tax Excess) shall be apportioned as of such date. If neither party (having the right so to do) elects to terminate Landlord will, with reasonable diligence and at Landlord’s expense, restore the remainder of the Premises, or the remainder of the means of access, as nearly as practicably may be to the same condition as obtained prior to such taking, appropriation or condemnation in which event (i) the Total Rentable Area shall be equitably adjusted, (ii) a just proportion of the Yearly Rent, according to the nature and extent of the taking, appropriation or condemnation and the resulting permanent injury to the Premises and the means of access thereto, shall be permanently abated, and (iii) a just proportion of the remainder of the Yearly Rent, according to the nature and extent of the taking, appropriation or condemnation and the resultant injury sustained by the Premises and the means of access thereto, shall be abated until what remains of the Premises and the means of access thereto shall have been restored as fully as may be for permanent use and occupation by Tenant hereunder. Except for any award specifically reimbursing Tenant for moving or relocation expenses or for Tenant’s personal property, or for the unamortized value of any leasehold improvements paid for by Tenant (in excess of any Landlord contribution), there are expressly reserved to Landlord all rights to compensation and damages created, accrued or accruing by reason of any such taking, appropriation or condemnation, in implementation and in confirmation of which Tenant does hereby acknowledge that Landlord shall be entitled to receive all such compensation and damages, grant to Landlord all and whatever rights (if any) Tenant may have to such compensation and damages, and agree to execute and deliver all and whatever further instruments of assignment as Landlord may from time to time reasonably request. In the event of any taking of the Premises or any part thereof for temporary (i.e., not in excess of one (1) year) use, (i) this Lease shall be and remain unaffected thereby, and (ii) Tenant shall be entitled to receive for itself any award made to the extent allocable to the Premises in respect of such taking on account of such use, provided, that if any taking is for a period extending beyond the Term of this Lease, such award shall be apportioned between Landlord and Tenant as of the Expiration Date or earlier termination of this Lease.
Insurance Casualty Condemnation Seller agrees that it will keep the Property insured against casualty until the Closing Date under its existing insurance policies or replacement policies with the same coverage as existing at the date of execution hereof. Such policies shall be terminated by Seller at the Closing Date. In the event that, prior to the Closing Date, all or any portion of the Property shall be destroyed by fire or other casualty, or taken by condemnation or exercise of the right of eminent domain, or if proceedings therefor shall be instituted or threatened and the amount of any such damage or condemnation exceeds $100,000, then Buyer may, within ten (10) days of its receipt of notice of such event, elect to terminate this Agreement by written notice to Seller and Escrow Agent. If the damage or condemnation is equal to or less than $100,000 or if the damage or condemnation exceeds $100,000 but Buyer does not terminate this Agreement, then the parties shall proceed to close the transaction contemplated hereby, in which event any insurance or condemnation proceeds (excluding rental loss proceeds attributable to the period prior to the Closing Date) shall inure to the benefit of Buyer and shall be assigned by Seller to Buyer at close of Escrow. In the event the parties proceed to close the transaction contemplated hereby, Seller shall pay any required deductible applicable to such insurance coverage, or the Purchase Price shall be reduced by the amount of any such deductible.
Insurance Casualty and Condemnation (a) If, before the Closing, the Property is damaged by fire or other casualty, and such damage does not result in an ACBR Material Adverse Effect, the Closing shall proceed as scheduled and Seller shall, as of the Closing Date, (i) promptly pay to Buyer all insurance proceeds received by Seller, the ACBR Entities or their respective Affiliates with respect to such damage, destruction or other loss, less any proceeds applied to the physical restoration of the Property, and (ii) assign to Buyer all rights of Seller, the ACBR Entities and their respective Affiliates against third parties (other than against its insurance carriers) with respect to any causes of action, whether or not litigation has commenced as of the Closing Date, in connection with such damage, destruction or other loss, provided, that the proceeds of such insurance shall be subject to (and recovery thereon shall be reduced by the amount of) any applicable deductibles and co-payment provisions or any payment or reimbursement and shall constitute full compensation for the damage to the Property, and Seller shall have no responsibility for restoration or repair of the Property or any resultant loss, directly, by subrogation, or otherwise.
(b) In the event a condemnation proceeding or payment in lieu of condemnation occurs relative to any part of the Property prior to the Closing Date, and such proceeding does not result in an ACBR Material Adverse Effect, Seller shall assign and turn over to Buyer, and Buyer shall be entitled to receive and keep, all awards for the taking by condemnation and Buyer shall be deemed to have accepted the Property subject to the taking without reduction in the Purchase Price.
(c) In the event a casualty or condemnation occurs prior to the Closing Date that results in an ACBR Material Adverse Effect, Buyer shall have the option, by written notice to Seller and the Escrow Agent, to either (i) proceed with the Closing whereby the provisions of this Section 6.13 shall govern as if the casualty or condemnation did not result in an ACBR Material Adverse Effect, or (ii) terminate this Agreement whereby the Deposit shall be immediately refunded to Buyer and Buyer shall have no further liability or obligations hereunder.
