Termination of the Contract 1. The Contractor may terminate the contract if the Partner has inadequately discharged or failed to discharge any of the contractual obligations, insofar as this is not due to force majeure, after notification of the Partner by registered letter has remained without effect for one month.
2. The Partner shall immediately notify the Contractor, supplying all relevant information, of any event likely to prejudice the performance of this contract.
No Construction as Employment Agreement Nothing contained in this Agreement shall be construed as giving Indemnitee any right to be retained in the employ of the Company or any of its subsidiaries.
TERM AND TERMINATION OF THIS AGREEMENT; NO ASSIGNMENT (a) This Agreement shall go into effect as to the Fund on the date set forth above and shall, unless terminated as hereinafter provided, continue in effect for a period of two years from the date of approval by shareholders of the Fund at a meeting called for the purpose of such approval. This Agreement shall continue in effect thereafter for additional periods not exceeding one (l) year so long as such continuation is approved for the Fund at least annually by (i) the Board of Trustees of the Trust or by the vote of a majority of the outstanding voting securities of the Fund and (ii) the vote of a majority of the Trustees of the Trust who are not parties to this Agreement nor interested persons thereof, cast in person at a meeting called for the purpose of voting on such approval. The terms “majority of the outstanding voting securities” and “interested persons” shall have the meanings as set forth in the 1940 Act;
(b) This Agreement may be terminated by the Trust on behalf of the Fund at any time without payment of any penalty, by the Board of Trustees of the Trust, by the Manager, or by vote of a majority of the outstanding voting securities of a Fund without the payment of any penalties, upon sixty (60) days’ written notice to the Sub-Adviser, and by the Sub-Adviser upon sixty (60) days’ written notice to the Fund and the Manager. In the event of a termination, the Sub-Adviser shall cooperate in the orderly transfer of the Fund’s affairs and, at the request of the Board of Trustees or the Manager, transfer any and all books and records of the Fund maintained by the Sub-Adviser on behalf of the Fund; and
(c) This Agreement shall terminate automatically in the event of any transfer or assignment thereof, as defined in the 1940 Act. This Agreement will also terminate in the event that the Management Agreement is terminated.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Termination and Amendment of this Agreement This Agreement shall automatically terminate, without the payment of any penalty, in the event of its assignment. This Agreement may be amended only if such amendment is approved (i) by Underwriter, (ii) either by action of the Board of Trustees of the Trust or at a meeting of the Shareholders of the Trust by the affirmative vote of a majority of the outstanding Shares, and (iii) by a majority of the Trustees of the Trust who are not interested persons of the Trust or of Underwriter by vote cast in person at a meeting called for the purpose of voting on such approval. Either the Trust or Underwriter may at any time terminate this Agreement on sixty (60) days' written notice delivered or mailed by registered mail, postage prepaid, to the other party.
Continuance of Agreement for Certain Purposes If any Party terminates this Agreement with respect to any Fund pursuant to Sections 6.1(b), 6.1(c), 6.1(d), 6.1(f), 6.1(g), 6.1(h) or 6.1(i) hereof, this Agreement shall nevertheless continue in effect as to any Shares of that Fund that are outstanding as of the date of such termination (the "Initial Termination Date"). This continuation shall extend to the earlier of the date as of which an Account owns no Shares of the affected Fund or a date (the "Final Termination Date") six (6) months following the Initial Termination Date, except that LIFE COMPANY may, by written notice shorten said six (6) month period in the case of a termination pursuant to Sections 6.1(d), 6.1(f), 6.1(g), 6.1(h) or 6.1(i).
Termination of the Agreement In the event of failure by the participant to perform any of the obligations arising from the agreement, and regardless of the consequences provided for under the applicable law, the institution is legally entitled to terminate or cancel the agreement without any further legal formality where no action is taken by the participant within one month of receiving notification by registered letter. If the participant terminates the agreement before its agreement ends or if he/she fails to follow the agreement in accordance with the rules, he/she shall have to refund the amount of the grant already paid, except if agreed differently with the sending organisation. In case of termination by the participant due to "force majeure", i.e. an unforeseeable exceptional situation or event beyond the participant's control and not attributable to error or negligence on his/her part, the participant shall be entitled to receive at least the amount of the grant corresponding to the actual duration of the mobility period. Any remaining funds shall have to be refunded, except if agreed differently with the sending organisation.
Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.
EVENTS CONSTITUTING MATERIAL BREACH OF AGREEMENT The Applicant shall be in Material Breach of this Agreement if it commits one or more of the following acts or omissions (each a “Material Breach”):
A. The Application, any Application Supplement, or any Application Amendment on which this Agreement is approved is determined to be inaccurate as to any material representation, information, or fact or is not complete as to any material fact or representation or such application;
B. The Applicant failed to complete Qualified Investment as required by Section 2.5.A. of this Agreement during the Qualifying Time Period;
C. The Applicant failed to create and maintain the number of New Qualifying Jobs required by the Act;
D. The Applicant failed to create and maintain the number of New Qualifying Jobs specified in Schedule C of the Application;
E. The Applicant failed to pay at least the average weekly wage of all jobs in the county in which the jobs are located for all New Non-Qualifying Jobs created by the Applicant;
F. The Applicant failed to provide payments to the District sufficient to protect future District revenues through payment of revenue offsets and other mechanisms as more fully described in Article IV of this Agreement;
G. The Applicant failed to provide the payments to the District that protect the District from the payment of extraordinary education-related expenses related to the project to the extent and in the amounts that the Applicant agreed to provide such payments in Article V of this Agreement;
H. The Applicant failed to provide the Supplemental Payments to the extent and in the amounts that the Applicant agreed to provide such Supplemental Payments in Article VI of this Agreement;
I. The Applicant failed to create and Maintain Viable Presence on or with the Qualified Property as more fully specified in Article VIII of this Agreement;
J. The Applicant failed to submit the reports required to be submitted by Section 8.2 to the satisfaction of the Comptroller;
K. The Applicant failed to provide the District or the Comptroller with all information reasonably necessary for the District or the Comptroller to determine whether the Applicant is in compliance with its obligations, including, but not limited to, any employment obligations which may arise under this Agreement;
L. The Applicant failed to allow authorized employees of the District, the Comptroller, the Appraisal District, or the State Auditor’s Office to have access to the Applicant’s Qualified Property or business records in order to inspect the project to determine compliance with the terms hereof or as necessary to properly appraise the Taxable Value of the Applicant’s Qualified Property under Sections 8.5 and 8.6;
M. The Applicant failed to comply with a request by the State Auditor’s office to review and audit the Applicant’s compliance with this Agreement;
N. The Applicant has made any payments to the District or to any other person or persons in any form for the payment or transfer of money or any other thing of value in recognition of, anticipation of, or consideration for this Agreement for limitation on Appraised Value made pursuant to Chapter 313 of the TEXAS TAX CODE, in excess of the amounts set forth in Articles IV, V and VI of this Agreement;
O. The Applicant failed to comply with the conditions included in the certificate for limitation issued by the Comptroller.
