The Authority Notes Sample Clauses

Open Split View

Download

Share

Cite

The Authority Notes 

Sample 1

Save

Copy

Related to The Authority Notes

• The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).

• Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works. (iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor: (a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre. (b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7 (c) all environmental clearances as required under Clause 4.3.8 (iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.

• Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment. (ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.

• Requisite Authority The Company has all necessary power and authority to enter into this Agreement and to perform the transactions contemplated hereby, except to the extent that the enforceability of the indemnity and/or contribution provisions contained in Section 7 of this Agreement may be limited under applicable securities laws and to the extent that the enforceability of this Agreement may be limited by bankruptcy, insolvency, reorganization, moratorium or other similar laws that affect creditors’ rights generally or by equitable principles relating to the availability of remedies.

• Authority Documents The Administrative Agent shall have received the following:

• Corporate Authority; No Conflicts The execution, delivery and performance by such Credit Party of this Amendment and all documents, instruments and agreements contemplated herein are within such Credit Party’s corporate or other organizational powers, have been duly authorized by all necessary action, require no action by or in respect of, or filing with, any court or agency of government and do not violate or constitute a default under any provision of any applicable law or other agreements binding upon such Credit Party or result in the creation or imposition of any Lien upon any of the assets of such Credit Party except for Liens permitted under Section 7.02 of the Credit Agreement.

• Authority; No Conflict (a) Parent and Merger Sub each have all necessary corporate power and authority to execute and deliver this Agreement and the other agreements referred to in this Agreement, to perform their respective obligations hereunder and to consummate the Contemplated Transactions. The execution and delivery of this Agreement by each of Parent and Merger Sub and the consummation by each of Parent and Merger Sub of the Contemplated Transactions have been duly and validly authorized by all necessary corporate action on its part and no other corporate proceedings on the part of Parent or Merger Sub are necessary to authorize this Agreement or to consummate the Contemplated Transactions (other than, with respect to the Merger, the filing of a certificate of merger required by the DGCL). This Agreement has been duly and validly executed and delivered by Parent and Merger Sub and constitutes the legal, valid and binding obligation of Parent and Merger Sub, enforceable against Parent and Merger Sub in accordance with its terms, subject to the Bankruptcy and Equity Exception. (b) Except as set forth in Part 3.2(b) of the Parent Disclosure Schedule, neither the execution and delivery of this Agreement nor the consummation of any of the Contemplated Transactions will, directly or indirectly (with or without notice or lapse of time or both): (i) contravene, conflict with, or result in a violation of (A) any provision of the Organizational Documents of Parent or any of its Subsidiaries, or (B) any resolution adopted by the Board of Directors or the shareholders of Parent or any of its Subsidiaries; or (ii) subject to compliance with the requirements specified in clauses (A) through (D) of Section 3.2(c), contravene, conflict with, or result in a violation of, or give any Governmental Body or other Person the right to challenge any of the Contemplated Transactions or to exercise any remedy or obtain any relief under, any Legal Requirement or any order, injunction, writ or decree to which Parent or any of its Subsidiaries, or any of the assets owned or used by Parent or any of its Subsidiaries, may be subject, except, in the case of clause (ii), for any such conflicts or violations that would not be reasonably likely to prevent or delay consummation of the Merger in any material respect, or otherwise would not prevent Parent from performing any of its material obligations under this Agreement in any material respect. (c) The execution and delivery of this Agreement by Parent do not, and the performance of this Agreement and the consummation of the Contemplated Transactions by Parent will not, require any Consent of, or filing with or notification to, any Governmental Body, except (i) for (A) applicable requirements, if any, of the Securities Act, the Exchange Act, The New York Stock Exchange or the Toronto Stock Exchange, (B) the pre-merger notification requirements of the HSR Act, (C) filing of appropriate merger documents as required by the DGCL and (D) the non-United States competition, antitrust and investment laws set forth in Part 3.2(c) of the Parent Disclosure Schedule and (ii) where failure to obtain such Consents, or to make such filings or notifications, would not prevent or delay consummation of the Merger in any material respect, or otherwise prevent Parent from performing any of its material obligations under this Agreement in any material respect, and would not reasonably be likely to, individually or in the aggregate, result in a Material Adverse Effect on Parent.

• Corporate Authority; Noncontravention Pubco has all requisite corporate and other power and authority to enter into this Agreement and to consummate the transactions contemplated by this Agreement. The execution and delivery of this Agreement by Pubco and the consummation by Pubco of the transactions contemplated hereby have been (or at Closing will have been) duly authorized by all necessary corporate action on the part of Pubco. This Agreement has been duly executed and when delivered by Pubco shall constitute a valid and binding obligation of Pubco, enforceable against Pubco in accordance with its terms, except as such enforcement may be limited by bankruptcy, insolvency or other similar laws affecting the enforcement of creditors’ rights generally or by general principles of equity. The execution and delivery of this Agreement do not, and the consummation of the transactions contemplated by this Agreement and compliance with the provisions hereof will not, conflict with, or result in any breach or violation of, or default (with or without notice or lapse of time, or both) under, or give rise to a right of termination, cancellation or acceleration of or “put” right with respect to any obligation or to loss of a material benefit under, or result in the creation of any lien upon any of the properties or assets of Pubco under, (i) its articles of incorporation, bylaws, or other charter documents of Pubco (ii) any loan or credit agreement, note, bond, mortgage, indenture, lease or other agreement, instrument, permit, concession, franchise or license applicable to Pubco, its properties or assets, or (iii) subject to the governmental filings and other matters referred to in the following sentence, any judgment, order, decree, statute, law, ordinance, rule, regulation or arbitration award applicable to Pubco, its properties or assets, other than, in the case of clauses (ii) and (iii), any such conflicts, breaches, violations, defaults, rights, losses or liens that individually or in the aggregate could not have a material adverse effect with respect to Pubco or could not prevent, hinder or materially delay the ability of Pubco to consummate the transactions contemplated by this Agreement.

• GUIDELINES FOR THE EXERCISE OF DELEGATED AUTHORITY For purposes of this Section 3.2, the Board shall be deemed to have considered and determined to accept such Country Risk as is incurred by placing and maintaining the Foreign Assets in each country for which the Custodian is serving as Foreign Custody Manager of the Portfolios.

• Authority to Execute Agreement Each of the Parties represents and warrants that its undersigned representative has been expressly authorized to execute this Agreement for and on behalf of such Party.