Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).
Project Completion Within five (5) days after the delivery by Supplier to Purchaser of a Commissioning Certificate for the Project’s final Turbine, Supplier shall also deliver to Purchaser a completion certificate for all Turbines in the Project (the “Project Completion Certificate”), in the form attached hereto as Exhibit N, together with a list of any remaining Punch List Work on any Turbine, a schedule for completing the Punch List Work and an estimate of the cost of each item of Punch List Work. Supplier shall thereafter promptly complete all Punch List Work.
Final Closing Statement During the thirty (30) days following the date upon which Seller received the Notice of Disagreement, Seller and Buyer shall attempt in good faith to resolve in writing any differences that they may have with respect to all matters specified in the Notice of Disagreement. If at the end of such thirty (30) day period (or earlier by mutual agreement to arbitrate), Buyer and Seller have not reached agreement on such matters, the matters that remain in dispute may be submitted to an arbitrator (the "Closing Statement Arbitrator") by either Party for review and resolution. The Closing Statement Arbitrator shall be a nationally recognized independent public accounting firm as shall be agreed upon by Buyer and Seller in writing. The hearing date will be scheduled by the Closing Statement Arbitrator as soon as reasonably practicable, and shall be conducted on a confidential basis. Each Party shall, not later than seven days prior to the hearing date set by the Closing Statement Arbitrator, submit a brief with dollar figures for settlement of the disputes as to the amount of the Adjusted Purchase Price (together with a proposed Closing Statement that reflects such figures). The figures submitted need not be the figures discussed during prior conversations. The Closing Statement Arbitrator shall render a decision resolving the matters in dispute (which decision shall include a written statement of findings and conclusions) within three Business Days after the conclusion of the hearing, unless the Parties reach agreement prior thereto and withdraw the dispute from arbitration. The Closing Statement Arbitrator shall provide to the Parties explanations in writing of the reasons for its decisions regarding the Adjusted Purchase Price and shall issue the Final Closing Statement reflecting such decisions. The decision of the Closing Statement Arbitrator shall be final and binding on the Parties. The cost of any arbitration (including the fees and expenses of the Closing Statement Arbitrator) pursuant to this Section 3.4(b) shall be borne equally by Buyer and Seller. The fees and disbursements of Seller's independent auditors incurred in connection with the procedures performed with respect to the Closing Statement shall be borne by Seller and the fees and disbursements of Buyer's independent auditors incurred in connection with their preparation of the Notice of Disagreement shall be borne by Buyer. As used in this Agreement, the term "Final Closing Statement" shall mean the revised Closing Statement described in Section 3.4(a), as prepared by Seller and as may be subsequently adjusted to reflect any subsequent written agreement between the Parties with respect thereto, or if submitted to the Closing Statement Arbitrator, the Closing Statement issued by the Closing Statement Arbitrator.
Preliminary Closing Statement At least three (3) Business Days prior to the Closing Date, Escrow Agent shall prepare and submit to each of Buyer and the Seller Parties preliminary Closing statements, showing the Parties’ respective amounts of Closing costs, the Deposit, the net credit due to the Seller Parties or Buyer under Section 2.5 and the net amount of funds required to be deposited by Buyer in order to effect Closing hereunder.
Estimated Closing Statement Not less than two (2) Business Days prior to the Closing Date, the Seller shall prepare and deliver to the Buyer a statement (the “Estimated Closing Statement”), certified in writing by an executive officer of the Seller, setting forth, in reasonable detail, (i) the Seller’s good faith calculation, together with reasonably detailed supporting documentation, of the estimated Closing Date Net Working Capital (the “Estimated Closing Date Net Working Capital”) and the components thereof; (ii) the Estimated Working Capital Increase or Estimated Working Capital Decrease, as the case may be; and (iii) the resulting calculation of the Purchase Price (the resulting amount, the “Estimated Purchase Price”), in each case calculated pursuant to the Accounting Principles. The Seller and the Owner, during the period from the delivery of the Estimated Closing Statement through the Closing Date, shall, and shall cause their respective managers, officers, employees, accountants, and other relevant advisors to, provide the Buyer (and its auditors, advisors, counsel, and other representatives) reasonable access to the books and records, outside accounting firm, working papers (subject to the execution of customary access letters), personnel, and facilities of the Seller in order to complete their review of the Estimated Closing Statement and the calculations set forth therein, and the Seller shall consider in good faith any comments made by the Buyer to the Estimated Closing Statement. The Buyer’s failure to make any comment regarding, or to dispute any amount included in, the Estimated Closing Statement shall not limit, or have any effect on, the Buyer’s rights pursuant to Section 2.05(b) to conduct a review of the Estimated Closing Date Net Working Capital, the Estimated Working Capital Increase or Estimated Working Capital Decrease, as the case may be, and the resulting calculation of the Purchase Price. The Seller and the Owner shall cooperate with the Buyer’s review of the Estimated Closing Statement and the Buyer and the Seller shall negotiate in good faith prior to the Closing to resolve any reasonable objection the Buyer may have to the estimates or calculations contained therein.
At Completion the Buyer shall:
Closing Statement (a) At least five (5) business days prior to the Closing Date, the Company shall submit to Buyer a written statement of estimated Current Assets and Current Liabilities as of the last day of the month immediately preceding the Closing Date (the "Estimated Closing Statement") containing the Company's good faith estimate of the Net Working Capital Amount (the "Estimated Net Working Capital Amount"), which shall reflect the items required to be set forth in, and be prepared in a manner consistent with the preparation of, the Closing Statement, in each case in accordance with Section 4.6(b); provided, however, that for purposes of the Estimated Net Working Capital Amount, the parties hereto agree that 50% of the amount of Fuel Sensor Damages (x) actually expended by Parent or the Company from March 1, 2011 through the last day of the month immediately preceding the Closing Date and (y) accrued as current liabilities on the Estimated Closing Statement, shall be added as a credit to the estimated Net Working Capital Amount set forth on the Estimated Closing Statement. Commencing with the Company's delivery of the Estimated Closing Statement to Buyer, Buyer shall have reasonable access to the books and records and personnel of the Company and the opportunity to consult with the Company for purposes of confirming or disputing the Estimated Net Working Capital Amount. If Buyer shall disagree, in good faith, with any item set forth in the Estimated Closing Statement or used to determine the Estimated Net Working Capital Amount, then Buyer and the Company shall work, in good faith, to reach agreement on such disputed items and the amounts as agreed to by Buyer and the Company shall constitute the Estimated Net Working Capital Amount. Notwithstanding the foregoing, Buyer's agreement with the Estimated Net Working Capital Amount (or any item set forth in the Estimated Closing Statement or used to determine the Estimated Net Working Capital Amount) shall not foreclose, prevent, limit or preclude any rights or remedy of Buyer set forth in this Agreement. If the Estimated Net Working Capital Amount is less than the Target Net Working Capital Amount, the amount of the Closing Payment to be paid by Buyer pursuant to Section 4.1(b)(i) shall be reduced by an amount equal to the difference between the Estimated Net Working Capital Amount and the Target Net Working Capital Amount. If the Estimated Net Working Capital Amount is more than the Target Net Working Capital Amount, the amount of the Closing Payment to be paid by Buyer pursuant to Section 4.1(b)(i) shall be increased by an amount equal to the difference between the Estimated Net Working Capital Amount and the Target Net Working Capital Amount.
Completion Date Completion date" shall be the date on which the improvements erected and to be erected upon the leased premises shall have been completed in accordance with the plans and specifications described in article 6.00. The completion date shall constitute the commencement of the term of this Lease for all purposes, whether or not Lessee has actually taken possession. Lessor shall use its best efforts to establish the completion date as the date set forth in section 1.03. In the event that the improvements have not in fact been completed as of that date, Lessee shall notify Lessor in writing of its objections. Lessor shall have a reasonable time after delivery of the notice in which to take such corrective action as may be necessary and shall notify Lessee in writing as soon as it deems such corrective action has been completed and the improvements are ready for occupancy. Upon completion of construction, Lessee shall deliver to Lessor a letter accepting the leased premises as suitable for the purposes for which they are let and the date of such letter shall constitute the commencement of the term of this Lease. Whether or not Lessee has executed such letter of acceptance, taking possession of the leased premises by Lessee shall be deemed to establish conclusively that the improvements have been completed in accordance with the plans and specifications, are suitable for the purposes for which the leased premises are let, and that the leased premises are in good and satisfactory condition as of the date possession was so taken by Lessee, except for latent defects, if any.
Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.
Notice of Completion Promptly after the completion of the distribution of the Securities by the Underwriters, the Representatives shall deliver to the Company a notice in writing confirming the completion of the distribution (the “Notice of Completion”).
