Acknowledgement of Existing Physical Conditions In undertaking the work under this Contract, the Contractor acknowledges that he has visited the premises and has taken into consideration all open and apparent conditions that might affect his work. No claim based on lack of knowledge of existing conditions shall be allowed unless the existing physical conditions cannot be discovered by a reasonably observant person. Any claims relating to conditions that are materially different from the Contract Documents that were not open and apparent may be adjusted as provided in this Part.
First Right of Refusal If any Partner shall enter into an agreement to sell their ownership interest in the Partnership with an individual or entity that is not a current Partner, the following parties must be given a first right of refusal before such a transaction can take place:
Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.
Proceeding Affecting Xxxxxx’s Interest in the Property Borrower will be in Default if any action or proceeding begins, whether civil or criminal, that, in Xxxxxx’s judgment, could result in forfeiture of the Property or other material impairment of Xxxxxx’s interest in the Property or rights under this Security Instrument. Borrower can cure such a Default and, if acceleration has occurred, reinstate as provided in Section 20, by causing the action or proceeding to be dismissed with a ruling that, in Xxxxxx’s judgment, precludes forfeiture of the Property or other material impairment of Xxxxxx’s interest in the Property or rights under this Security Instrument. Borrower is unconditionally assigning to Lender the proceeds of any award or claim for damages that are attributable to the impairment of Xxxxxx’s interest in the Property, which proceeds will be paid to Lender. All Miscellaneous Proceeds that are not applied to restoration or repair of the Property will be applied in the order that Partial Payments are applied in Section 2(b).
Site to be free from Encumbrances Subject to the provisions of Clause 10.3, the Site shall be made available by the Authority to the Concessionaire pursuant hereto free from all Encumbrances and occupations and without the Concessionaire being required to make any payment to the Authority on account of any costs, compensation, expenses and charges for the acquisition and use of such Site for the duration of the Concession Period, except insofar as otherwise expressly provided in this Agreement. For the avoidance of doubt, it is agreed that existing rights of way, easements, privileges, liberties and appurtenances to the Licensed Premises shall not be deemed to be Encumbrances. It is further agreed that the Concessionaire accepts and undertakes to bear any and all risks arising out of the inadequacy or physical condition of the Site.
REMOVAL OF RECORDS FROM PREMISES Where performance of the Contract involves use by the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) of Authorized User owned or licensed papers, files, computer disks or other electronic storage devices, data or records at Authorized User facilities or offices, or via remote access, the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) shall not remotely access, modify, delete, copy or remove such Records without the prior written approval of the Authorized User. In no case, with or without the written approval of the Authorized User, can the Authorized User data be accessed, moved or sent outside the continental United States.
Right of Entry The Landlord shall have the right to enter the Premises during normal working hours by providing at least twenty-four (24) hours notice in order for inspection, make necessary repairs, alterations or improvements, to supply services as agreed or for any reasonable purpose. The Landlord may exhibit the Premises to prospective purchasers, mortgagees, or lessees upon reasonable notice.
RIGHT OF RE-ENTRY Upon the occurrence of a Default, Landlord may elect to terminate this Lease or, without terminating this Lease, terminate Tenant's right to possession of the Premises. Upon any such termination, Tenant shall immediately surrender and vacate the Premises and deliver possession thereof to Landlord. Tenant grants to Landlord the right to enter and repossess the Premises and to expel Tenant and any others who may be occupying the Premises and to remove any and all property therefrom, without being deemed in any manner guilty of trespass and without relinquishing Landlord's rights to Rent or any other right given to Landlord hereunder or by operation of law.
How Do I Get More Information? For more information, including the full Notice, Claim Forms and Settlement Agreement go to xxx.xxxxxxxxxxxxxxxxxxxx.xxx, contact the settlement administrator at 0-000-000-0000, or call Class Counsel at 1-866-354-3015. Exhibit E UNITED STATES DISTRICT COURT FOR THE SOUTHERN DISTRICT OF FLORIDA Xxxxx v. AvMed, Inc., Case No. 10-cv-24513 If You Paid for or Received Insurance from AvMed, Inc. at Any Time Through December of 2009, You May Be Part of a Class Action Settlement. IMPORTANT: PLEASE READ THIS NOTICE CAREFULLY. THIS NOTICE RELATES TO THE PENDENCY OF A CLASS ACTION LAWSUIT AND, IF YOU ARE A MEMBER OF THE SETTLEMENT CLASSES, CONTAINS IMPORTANT INFORMATION ABOUT YOUR RIGHTS TO MAKE A CLAIM UNDER THE SETTLEMENT OR TO OBJECT TO THE SETTLEMENT (A federal court authorized this notice. It is not a solicitation from a lawyer.) Your legal rights are affected whether or not you act. Please read this notice carefully. YOUR LEGAL RIGHTS AND OPTIONS IN THIS SETTLEMENT SUBMIT A CLAIM FORM This is the only way to receive a payment. EXCLUDE YOURSELF You will receive no benefits, but you will retain any rights you currently have to xxx the Defendant about the claims in this case. OBJECT Write to the Court explaining why you don’t like the Settlement. GO TO THE HEARING Ask to speak in Court about your opinion of the Settlement. DO NOTHING You won’t get a share of the Settlement benefits and will give up your rights to xxx the Defendant about the claims in this case. These rights and options – and the deadlines to exercise them – are explained in this Notice. QUESTIONS? CALL 0-000-000-0000 TOLL FREE, OR VISIT XXX.XXXXXXXXXXXXXXXXXXXX.XXX PARA UNA NOTIFICACIÓN EN ESPAÑOL, LLAMAR O VISITAR NUESTRO WEBSITE BASIC INFORMATION
SCHOOL DISTRICT RIGHTS Section 1. Inherent Managerial Rights 2 Section 2. Management Responsibilities 2 Section 3. Effect of Laws, Rules and Regulations 2 Section 4. Reservation of Managerial Rights 2
