Third Party Claims Coverage Sample Clauses

Third Party Claims Coverage. With respect to third party liability for death or bodily injury or for the loss of or damage to property that may be sustained, and any consequences thereof, resulting from, or arising in connection with the performance of the Launch Services for the Satellite, Purchaser shall use reasonable efforts to require the Launch Agency to include Contractor (and any other party or entity as Contractor may request) as an additional named insured under all policies of third party claims coverage (or any other program of third party claims coverage, including coverage provided by agencies of any government) that are provided or required to be provided by or through the Launch Agency.
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
Third Party Claims Coverage. Contractor or Purchaser, depending on which is party to the Launch Services Agreement, shall use reasonable commercial efforts to require the Launch Agency to include the other Party (and any other party or entity as such Party may request) as an additional named insured under the third party liability insurance (or any other program of third party claims coverage, including coverage provided by agencies of any government) that is provided or required to be provided by or through the Launch Agency.
Sample 1Sample 2
Third Party Claims Coverage. With respect to third party liability for death or bodily injury of for the loss or damage to property that may be sustained, and any consequences thereof, resulting from, or arising in connection with the performance of the Launch Services for any Satellite, Purchaser shall cause the Launch Services Provider(s) to include Contractor and its Subcontractors as an additional insured under all policies of third party claims coverage (or any other program of third party claims coverage, including coverage provided by agencies of any government) that are provided or required to be provided by or through any Launch Services Provider. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED FOR PORTIONS OF THIS EXHIBIT. THE COPY FILED HEREWITH OMITS THE INFORMATION SUBJECT TO A CONFIDENTIALITY REQUEST. OMISSIONS ARE DESIGNATED [***...***]. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
Sample 1
Third Party Claims Coverage. With respect to third party liability for death or bodily injury or for the loss of or damage to property that may be sustained, and any consequences thereof, resulting from, or arising in connection with the performance of the Launch Services for the Satellite, ***. *** Certain confidential portions of this exhibit were omitted by means of redacting a portion of the text.
Sample 1

Related to Third Party Claims Coverage

  • Third Party Claims Each Notice of Claim given by Acquiror, which involves a third party (a “Third Party Claim”), shall be resolved as follows: (a) If, within thirty (30) days after a Notice of Claim is delivered to the Seller Representative, (x) the Seller Representative produces a notice of election and (y) such notice of election includes a written acknowledgment from the Seller Representative on behalf of the Seller Guarantors and the Sellers (the “Indemnifying Persons”) that the Indemnifying Persons would be required to indemnify the Acquiror Indemnified Persons for all Damages in connection with such Third Party Claim Notice, the Indemnifying Persons shall have the right, but not the obligation to (i) take control of the defense and investigation of such Third Party Claim, (ii) employ and engage attorneys of their own choice (subject to the approval of Acquiror, such approval not to be unreasonably withheld, conditioned or delayed) to handle and defend the same, at the Indemnifying Persons’ sole cost and expense, and (iii) compromise or settle such Third Party Claim, which compromise or settlement shall be made only with the written consent of Acquiror; provided, that such consent will not be required if such settlement includes an unconditional release of the Acquiror Indemnified Persons and provides solely for payment of monetary damages for which the Acquiror Indemnified Persons will be indemnified in full. Notwithstanding the foregoing, the Indemnifying Persons shall not have the right to assume the defense of a Third Party Claim if (1) the Indemnifying Persons fail to actively and diligently conduct the defense of the Third Party Claim (after notice and reasonable opportunity to cure), (2) the Acquiror Indemnified Persons have received advice from counsel that an actual or potential conflict exists between the Acquiror Indemnified Persons and the Indemnifying Persons in connection with the defense of such Third Party Claim, (3) such Third Party Claim seeks a finding or admission of a violation of any criminal Law by an Acquiror Indemnified Person, (4) such Third Party Claim seeks an injunction or other equitable remedies in respect of an Acquiror Indemnified Person or its business, (5) such Third Party Claim relates to a Material Customer or Material Supplier, or (6) such Third Party Claim is reasonably likely to result in Damages that, taken with any other then existing claims under this Article 12, would not be not be fully indemnified hereunder. (b) In the event that the Indemnifying Persons defend the Acquiror Indemnified Persons against a Third Party Claim, the Acquiror Indemnified Persons shall cooperate in all reasonable respects, at the Indemnifying Persons’ request, with the Indemnifying Persons and their attorneys in the investigation, trial and defense of such Third Party Claim and any appeal arising therefrom, including, if appropriate and related to such Third Party Claim, in making any counterclaim against the third party claimant, or any cross complaint against any Person, in each case, at the expense of the Indemnifying Persons. The Acquiror Indemnified Persons may, at their own sole cost and expense, monitor and further participate in (but not control) the investigation, trial and defense of such Third Party Claim and any appeal arising therefrom. (c) Notwithstanding anything to the contrary herein, if the Indemnifying Persons do not assume such defense and investigation or does not acknowledge in writing within thirty (30) days after receipt of the Third Party Claim Notice its obligation to indemnify the Acquiror Indemnified Persons against any Damages arising from such Third Party Claim, then the Acquiror Indemnified Persons shall have the right to retain separate counsel of their choosing, defend such Third Party Claim and have the sole power to direct and control such defense (all at the cost and expense of the Indemnifying Persons if it is ultimately determined that the Acquiror Indemnified Persons are entitled to indemnification hereunder); it being understood that the Acquiror Indemnified Persons’ right to indemnification for a Third Party Claim shall not be adversely affected by assuming the defense of such Third Party Claim. Notwithstanding anything herein to the contrary, whether or not the Indemnifying Persons shall have assumed the defense of such Third Party Claim, the Acquiror Indemnified Persons shall not settle, compromise or pay such Third Party Claim for which they seeks indemnification hereunder without the prior written consent of the Indemnifying Persons, which consent shall not be unreasonably withheld, conditioned or delayed. (d) The Acquiror Indemnified Persons and the Indemnifying Persons shall use commercially reasonable efforts to avoid production of confidential information (consistent with Law), and to cause all communications among employees, counsel and others representing any party to a Third Party Claim to be made so as to preserve any applicable attorney-client or work-product privileges. (e) Notwithstanding anything to the contrary in this Agreement, Section 8.1(d) shall exclusively govern S Corporation Tax Proceedings.

  • Indemnification of Third Party Claims The obligations and liabilities of any party to indemnify any other under this Article 6 with respect to Claims relating to third parties shall be subject to the following terms and conditions:

  • Indemnification; Third Party Claims The Master Servicer agrees to indemnify the Depositor, the Sponsor and the Trustee, and their respective officers, directors, agents and affiliates, and hold each of them harmless against any and all claims, losses, penalties, fines, forfeitures, reasonable legal fees and related costs, judgments, and any other costs, liability, fees and expenses that the Depositor, the Sponsor or the Trustee may sustain as a result of (a) any material breach by the Master Servicer of any if its obligations hereunder, including particularly its obligations to provide any reports under Section 9.25(a), Section 9.25(b), Section 9.26 or any information, data or materials required to be included in any Exchange Act report, (b) any material misstatement or omission in any information, data or materials provided by the Master Servicer, or (c) the negligence, bad faith or willful misconduct of the Master Servicer in connection with its performance hereunder, provided, however, that in no event shall the Master Servicer be liable for any special, consequential, indirect or punitive damages pursuant to this Section 9.31, even if advised of the possibility of such damages. The Depositor, the Sponsor and the Trustee shall immediately notify the Master Servicer if a claim is made by a third party with respect to this Agreement or the Mortgage Loans entitling the Depositor, the Sponsor or the Trustee to indemnification hereunder, whereupon the Master Servicer shall assume the defense of any such claim and pay all expenses in connection therewith, including counsel fees, and promptly pay, discharge and satisfy any judgment or decree which may be entered against it or them in respect of such claim. Notwithstanding anything to the contrary contained herein, the Master Servicer shall not settle any claim involving any of the other parties hereto without such party’s prior written consent unless such settlement involves a complete and absolute release of such party from any and all liability in connection with such claim. This indemnification shall survive the termination of this Agreement or the termination of the Master Servicer as a party to this Agreement.

  • Indemnification Claims An Indemnified Party shall give written notification to the Indemnifying Party of the commencement of any Third Party Action. Such notification shall be given within 20 days after receipt by the Indemnified Party of notice of such Third Party Action, and shall describe in reasonable detail (to the extent known by the Indemnified Party) the facts constituting the basis for such Third Party Action and the amount of the claimed damages; provided, however, that no delay or failure on the part of the Indemnified Party in so notifying the Indemnifying Party shall relieve the Indemnifying Party of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Party may, upon written notice thereof to the Indemnified Party, assume control of the defense of such Third Party Action with counsel reasonably satisfactory to the Indemnified Party; provided that the Indemnifying Party may not assume control of the defense of Third Party Action involving criminal liability or in which equitable relief is sought against the Indemnified Party. If the Indemnifying Party does not, or is not permitted under the terms hereof to, so assume control of the defense of a Third Party Action, the Indemnified Party shall control such defense. The Non-controlling Party may participate in such defense at its own expense. The Controlling Party shall keep the Non-controlling Party advised of the status of such Third Party Action and the defense thereof and shall consider in good faith recommendations made by the Non-controlling Party with respect thereto. The Non-controlling Party shall promptly furnish the Controlling Party with such information as it may have or receive with respect to such Third Party Action (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party in the defense of such Third Party Action. The fees and expenses of counsel to the Indemnified Party with respect to a Third Party Action shall be considered Damages for purposes of this Agreement if (x) the Indemnified Party controls the defense of such Third Party Action pursuant to the terms of this Section 5.3 or (y) the Indemnifying Party assumes control of such defense and the Indemnified Party reasonably concludes that the Indemnifying Party and the Indemnified Party have conflicting interests with respect to such Third Party Action. The Indemnifying Party shall not agree to any settlement of, or the entry of any judgment arising from, any Third Party Action without the prior written consent of the Indemnified Party, which shall not be unreasonably withheld, conditioned or delayed. The Indemnified Party shall not agree to any settlement of, or the entry of any judgment arising from, any such Third Party Action without the prior written consent of the Indemnifying Party, which shall not be unreasonably withheld, conditioned or delayed.

  • Indemnification for Third Party Claims ‌ (a) Seller shall defend, indemnify and hold harmless Buyer, its shareholders and Affiliates, and their respective directors, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance by any Project Party of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Seller, the Contractor, any Subcontractor, and its respective employees or agents. (b) Buyer shall defend, indemnify and hold harmless Seller and its managers, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Buyer, its employees or agents. (c) Either Party seeking indemnification under this Agreement (the “Indemnified Party”) shall give notice to the Party required to provide indemnification hereunder (the “Indemnifying Party”) promptly after the Indemnified Party has actual knowledge of any Claim as to which indemnity may be sought hereunder, and the Indemnified Party shall permit the Indemnifying Party (at the expense of the Indemnifying Party) to assume the defense of any Claim or litigation resulting therefrom; provided that: (i) counsel for the Indemnifying Party who shall conduct the defense of such Claim or litigation shall be reasonably satisfactory to the Indemnified Party; (ii) the Indemnified Party may participate in such defense at its own expense, except the Indemnifying Party shall reimburse the Indemnified Party for its participation in such defense to the extent that the Indemnifying Party requests the Indemnified Party to participate in its own defense; and (iii) the omission by the Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligations hereunder except to the extent that such omission results in a failure of actual notice to the Indemnifying Party and Indemnifying Party is damaged as a result of such failure to give notice. Notwithstanding the foregoing, the Indemnifying Party may not settle any Claim related to the indemnity being provided hereunder without the consent of the Indemnified Party, such consent not to be unreasonably withheld. (d) With regard to any Claim or Liability which is the result of the joint or concurrent fault or negligence of Seller and Buyer, the Parties agree to jointly defend any Claim with respect thereto that is based on such joint or concurrent fault or negligence of Buyer and Seller. Any Claim of contribution or indemnification between Buyer and Seller relating to such Claims shall be resolved on the basis of the percentage of fault or negligence and the Parties agree to reserve the determination of such percentage until after resolution of such Claim. Such pro rata share shall be based upon a final judicial determination of the Parties’ comparative fault or negligence or, in the absence of such determination, by mutual agreement. (e) Nothing in this Section 26.1 is intended to allow any Indemnified Party to be indemnified from and against any third party Claims and Liabilities caused by, arising out of, or in connection with the performance of this Agreement to the extent any of such Claims or Liabilities were caused by, arose out of, or were in any way incidental to or in connection with its own negligence or intentional misconduct.

  • Third Party Claim A Claim where there is (a) a claim, demand, suit or action by a person who is not a Party, (b) a settlement with, judgment by, or liability to, a person who is not a Party, or (c) a fine or penalty imposed by a person who is not a Party.

  • Defense of Third Party Claims In the case of a Third-Party Claim, the Indemnifying Party shall have the right: (a) to control and conduct any proceedings or negotiations in connection therewith and necessary or appropriate to defend the claim, (b) to take all other reasonable steps or proceedings to settle or defend any such Third-Party Claim; provided, that the Indemnifying Party shall not settle any Third-Party Claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, conditioned, or delayed), and (c) to employ counsel designated by the Indemnifying Party to contest any such Third-Party Claim in the name of the Indemnified Party or otherwise. The Indemnifying Party shall, within fifteen (15) days of receipt of a Third-Party Claim Notice (the “Indemnity Notice Period”), give written notice to the Indemnified Party of its intention to assume the defense of such Third-Party Claim. If the Indemnifying Party does not deliver to the Indemnified Party within the Indemnity Notice Period written notice that the Indemnifying Party shall assume the defense of any such Third-Party Claim, then the Indemnified Party may defend against any such Third-Party Claim in any such manner as it may deem appropriate, provided, that the Indemnified Party shall not settle any such Third-Party Claim without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, conditioned, or delayed. In the event that the Indemnifying Party does assume the defense of such Third-Party Claim, the Indemnified Party shall have the right to fully participate in (but not control) such defense (including with counsel of its choice), at its sole expense, and the Indemnifying Party shall reasonably cooperate with the Indemnified Party in connection with such participation. In the event that either the Indemnifying Party or the Indemnified Party assumes the defense of a Third-Party Claim as provided above (the “Controlling Party”), the non-Controlling Party shall have the right to fully participate (but not control) in such defense (including with counsel of its choice), at its sole expense, and the Controlling Party shall reasonably cooperate with the non-Controlling Party in connection with such participation; provided, however, that Buyer and Seller shall each use its commercially reasonable efforts with respect to any information shared pursuant to this Section 7.3(b) to preserve attorney-client privilege.

  • Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined). 22.1.1 For purposes of this Section 22, Claim means any action, cause of action, suit, proceeding, claim, or demand of any third party (and all resulting judgments, bona fide settlements, penalties, damages, losses, liabilities, costs, and expenses including, but not limited to, reasonable costs and attorneys’ fees), (a) based on allegations that, if true, would establish (i) the Indemnifying Party’s breach of this Agreement; (ii) the Indemnifying Party’s misrepresentation, fraud or other misconduct; (iii) the Indemnifying Party’s negligent or willful misconduct or omissions; (iv) infringement by the Indemnifying Party or by any Indemnifying Party product or service of any patent, copyright, trademark, service mark, trade name, right of publicity or privacy, trade secret, or any other proprietary right of any third party; (v) the Indemnifying Party’s liability in relation to any wrongful disclosure of private or personal matters or material which is defamatory; or (vi) the Indemnifying Party’s wrongful use or unauthorized disclosure of data; or (b) that arises out of: (i) any act or omission of the Indemnifying Party or its subcontractors or agents relating to the Indemnifying Party’s performance or obligations under this Agreement or the Indemnifying Party’s use of any services or facilities obtained from or provided by the other Party under this Agreement; (ii) any act or omission of the Indemnifying Party’s customer(s) or End User(s) pertaining to the services or facilities provided under this Agreement; (iii) the bodily injury or death of any person, or the loss or disappearance of or damage to the tangible property of any person, relating to the Indemnifying Party’s performance or obligations under this Agreement; (iv) the Indemnifying Party’s design, testing, manufacturing, marketing, promotion, advertisement, distribution, lease or sale of services and/or products to its customers, or such customers’ use, possession, or operation of those services and/or products; or (v) personal injury to or any unemployment compensation claim by one or more of the Indemnifying Party’s employees, notwithstanding any protections the Indemnifying Party might otherwise have under applicable workers’ compensation or unemployment insurance law, which protections the Indemnifying Party waives, as to the Indemnified Party and other persons and entities to be indemnified under this Section (other than applicable employee claimant(s)). 22.1.2 For purposes of this Section, Reasonable costs and attorneys’ fees, as used in this Section, includes without limitation fees and costs incurred to interpret or enforce this Section. 22.1.3 The Indemnified Party will provide the Indemnifying Party with reasonably prompt written notice of any Claim. At the Indemnifying Party’s expense, the Indemnified Party will provide reasonable cooperation to the Indemnifying Party in connection with the defense or settlement of any Claim. The Indemnified Party may, at its expense, employ separate counsel to monitor and participate in the defense of any Claim.

  • Notice of Loss; Third Party Claims (a) An Indemnified Party shall give the Indemnifying Party notice of any matter that an Indemnified Party has determined has given or could give rise to a right of indemnification under this Agreement, within thirty (30) days of such determination, stating the amount of the Loss, if known, and method of computation thereof, and containing a reference to the provisions of this Agreement in respect of which such right of indemnification is claimed or arises. (b) If an Indemnified Party shall receive notice of any Action, audit, demand or assessment (each, a “Third Party Claim”) against it or which may give rise to a claim for a Loss under this Article VIII, within thirty (30) days of the receipt of such notice, the Indemnified Party shall give the Indemnifying Party notice of such Third Party Claim; provided, however, that the failure to provide such notice shall not release the Indemnifying Party from any of its obligations under this Article VIII except to the extent that the Indemnifying Party is materially prejudiced by such failure and shall not relieve the Indemnifying Party from any other obligation or liability that it may have to any Indemnified Party otherwise than under this Article VIII. If the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party hereunder against any Losses that may result from such Third Party Claim, then the Indemnifying Party shall be entitled to assume and control the defense of such Third Party Claim at its expense and through counsel of its choice if it gives notice of its intention to do so to the Indemnified Party within five (5) days of the receipt of notice from the Indemnified Party of such Third Party Claim; provided, however, that if there exists or is reasonably likely to exist a conflict of interest that would make it inappropriate in the judgment of the Indemnified Party in its sole and absolute discretion for the same counsel to represent both the Indemnified Party and the Indemnifying Party, then the Indemnified Party shall be entitled to retain its own counsel in each jurisdiction for which the Indemnified Party determines counsel is required, at the expense of the Indemnifying Party. In the event that the Indemnifying Party exercises the right to undertake any such defense against any such Third Party Claim as provided above, the Indemnified Party shall cooperate with the Indemnifying Party in such defense and make available to the Indemnifying Party, at the Indemnifying Party’s expense, all witnesses, pertinent records, materials and information in the Indemnified Party’s possession or under the Indemnified Party’s control relating thereto as is reasonably required by the Indemnifying Party. Similarly, in the event the Indemnified Party is, directly or indirectly, conducting the defense against any such Third Party Claim, the Indemnifying Party shall cooperate with the Indemnified Party in such defense and make available to the Indemnified Party, at the Indemnifying Party’s expense, all such witnesses, records, materials and information in the Indemnifying Party’s possession or under the Indemnifying Party’s control relating thereto as is reasonably required by the Indemnified Party. No such Third Party Claim may be settled by the Indemnifying Party without the prior written consent of the Indemnified Party.

  • Non-Third Party Claims Upon discovery of any claim for which Buyer has an indemnification obligation under the terms of Section 12.1 which does not involve a claim by a third party against the Indemnitee, the Indemnitee shall give prompt notice to Buyer of such claim and, in any case, shall give Buyer such notice within 30 days of such discovery. A failure by Indemnitee to timely give the foregoing notice to Buyer shall not excuse Buyer from any indemnification liability except to the extent that Buyer is materially and adversely prejudiced by such failure.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!