Third Party Data Any statistical, industry-related and market-related data, which are included in the Disclosure Package and the Prospectus, is based on or derived from sources that the Company reasonably and in good faith believes to be reliable and accurate, and such data agrees with the sources from which it is derived, and the Company has obtained the written consent for the use of such data from such sources to the extent required.
Third Party Users If required by Applicable Laws and Regulations or if the Parties mutually agree, such agreement not to be unreasonably withheld, to allow one or more third parties to use the Connecting Transmission Owner’s Attachment Facilities, or any part thereof, Developer will be entitled to compensation for the capital expenses it incurred in connection with the Attachment Facilities based upon the pro rata use of the Attachment Facilities by Connecting Transmission Owner, all third party users, and Developer, in accordance with Applicable Laws and Regulations or upon some other mutually-agreed upon methodology. In addition, cost responsibility for ongoing costs, including operation and maintenance costs associated with the Attachment Facilities, will be allocated between Developer and any third party users based upon the pro rata use of the Attachment Facilities by Connecting Transmission Owner, all third party users, and Developer, in accordance with Applicable Laws and Regulations or upon some other mutually agreed upon methodology. If the issue of such compensation or allocation cannot be resolved through such negotiations, it shall be submitted to FERC for resolution.
Third Party Vendors Nothing herein shall impose any duty upon DST in connection with or make DST liable for the actions or omissions to act of the following types of unaffiliated third parties: (a) courier and mail services including but not limited to Airborne Services, Federal Express, UPS and the U.S. Mails, (b) telecommunications companies including but not limited to AT&T, Sprint, MCI and other delivery, telecommunications and other such companies not under the party’s reasonable control, and (c) third parties not under the party’s reasonable control or subcontract relationship providing services to the financial industry generally, such as, by way of example and not limitation, the National Securities Clearing Corporation (processing and settlement services), Fund custodian banks (custody and fund accounting services) and administrators (blue sky and Fund administration services), and national database providers such as Choice Point, Acxiom, TransUnion or Lexis/Nexis and any replacements thereof or similar entities, provided, if DST selected such company, DST shall have exercised due care in selecting the same. Such third party vendors shall not be deemed, and are not, subcontractors for purposes of this Agreement.
Third Party Use You may allow your agents, contractors and outsourcing service providers (each a “Permitted Third Party”) to use the Product(s) licensed to you hereunder solely for your benefit in accordance with the terms of this XXXX and you are responsible for any such Permitted Third Party’s compliance with this XXXX in such use. Any breach by any Permitted Third Party of the terms of this XXXX will be considered your breach.
Third Party Claims The obligation of an indemnifying party to ------------------ indemnify another party to this Agreement under the provisions of this Article with respect to claims resulting from the assertion of liability by Persons not parties to this Agreement (including governmental claims for penalties, fines and assessments) shall be subject to the following terms and conditions:
(a) The indemnified party shall give prompt written notice to the indemnifying party of any assertion of liability by a third party which might give rise to a claim for indemnification, which notice shall state the nature and basis of the assertion and the amount thereof, to the extent known, provided, however, that no delay on the part of the indemnified party in giving notice shall relieve the indemnifying party of any obligation to indemnify unless (and then solely to the extent that) the indemnifying party is prejudiced by such delay.
(b) If any action, suit or proceeding (a "Legal Action") is brought against an indemnified party with respect to which the indemnifying party may have an obligation to indemnify, the Legal Action shall be defended by the indemnifying party and such defense shall include all proceedings and appeals which counsel for the indemnified party shall reasonably deem appropriate.
(c) Notwithstanding the provisions of the previous subsection of this Article, until the indemnifying party shall have assumed the defense of any such Legal Action, the defense shall be handled by the indemnified party. Furthermore, (i) if the indemnified party shall have reasonably concluded that there are likely to be defenses available to the indemnified party that are different from or in addition to those available to the indemnifying party; (ii) if the indemnifying party fails to provide the indemnified party with evidence reasonably acceptable to the indemnified party that the indemnifying party has sufficient financial resources to defend and fulfill its indemnification obligation with respect to the Legal Action; (iii if the Legal Action involves other than money damages and seeks injunctive or other equitable relief; or (iv) if a judgment against the indemnified party will, in the good faith opinion of the indemnified party, establish a custom or precedent which will be materially adverse to the best interests of its continuing business, the indemnifying party shall not be entitled to assume the defense of the Legal Action and the defense shall be handled by the indemnified party. If the defense of the Legal Action is handled by the indemnified party under the provisions of this subsection, the indemnifying party shall pay all legal and other expenses reasonably incurred by the indemnified party in conducting such defense.
(d) In any Legal Action initiated by a third party and defended by the indemnifying party (i) the indemnified party shall have the right to be represented by advisory counsel and accountants, at its own expense, (ii) the indemnifying party shall keep the indemnified party fully informed as to the status of such Legal Action at all stages thereof, whether or not the indemnified party is represented by its own counsel, (iii) the indemnifying party shall make available to the indemnified party, and its attorneys, accountants and other representatives, all books and records of the indemnifying party relating to such Legal Action and (iv) the parties shall render to each other such assistance as may be reasonably required in order to ensure the proper and adequate defense of the Legal Action.
(e) In any Legal Action initiated by a third party and defended by the indemnifying party, the indemnifying party shall not make any settlement of any claim without the written consent of the indemnified party, which consent shall not be unreasonably withheld. Without limiting the generality of the foregoing, it shall not be deemed unreasonable to withhold consent to a settlement involving injunctive or other equitable relief against the indemnified party or its assets, employees or business, or relief which the indemnified party reasonably believes could establish a custom or precedent which will be adverse to the best interests of its continuing business.
Infringement Claims by Third Parties If the Exploitation of a Licensed Product in the Territory pursuant to this Agreement results in, or is reasonably expected to result in, any claim, suit or proceeding by a Third Party alleging infringement by Licensee or any of its Affiliates or its or their Sublicensees, (a “Third Party Infringement Claim”), including any defense or counterclaim in connection with an Infringement action initiated pursuant to Section 6.3.2, the Party first becoming aware of such alleged infringement shall promptly notify the other Party thereof in writing. As between the Parties, Licensee shall be responsible for defending any such claim, suit or proceeding, at its sole cost and expense using counsel of Licensee’s choice, in relation to technology licensed under any Exclusive Licensed Technology, and MedImmune shall be responsible for defending any such claim, suit or proceeding at proceeding at its sole cost and expense, using counsel of MedImmune’s choice in relation to technology licensed under any Non-Exclusive Licensed Technology. MedImmune shall, and shall cause its Affiliates to, assist and cooperate with Licensee, as Licensee may reasonably request from time to time, in connection with its activities set out in this Section 6.4, including where necessary, furnishing a power of attorney solely for such purpose or joining in, or being named as a necessary party to, such action, providing access to relevant documents and other evidence and making its employees available at reasonable business hours; provided that Licensee shall reimburse MedImmune for its reasonable and verifiable out-of-pocket costs and expenses incurred in connection therewith. Licensee shall keep MedImmune reasonably informed of all material developments in connection with any such claim, suit or proceeding. Licensee agrees to provide MedImmune with copies of all material pleadings filed in such action and to allow MedImmune reasonable opportunity to participate in the defense of the claims. Any damages, or awards, including royalties incurred or awarded in connection with any Third Party Infringement Claim defended under this Section 6.4 shall be [***].
Third Party Links The Service may contain links to other websites for your convenience. We do not control the linked websites or the content provided through such websites, and we have not reviewed, in their entirety, such websites. Your use of linked websites is subject to the privacy policies and terms of use established by the specific linked website, and we disclaim all liability for such use. The fact that we offer such links does not indicate any approval or endorsement by us of any linked website or any material contained on any linked website, and we disclaim any such approval or endorsement.
Third Party Providers Except for those terms and conditions that specifically apply to Third Party Providers, under no circumstances shall any other person be considered a third party beneficiary of this Agreement or otherwise entitled to any rights or remedies under this Agreement. Except as may be provided in Third Party Agreements, Company shall have no rights or remedies against Third Party Providers, Third Party Providers shall have no liability of any nature to the Company, and the aggregate cumulative liability of all Third Party Providers to the Company shall be $1.
Infringement of Third Party Rights Each Party shall promptly notify the other in writing of any allegation by a Third Party that the activity of either of the Parties hereunder infringes or may infringe the intellectual property rights of such Third Party. Genentech shall have the first right but not the obligation to control any defense of any such claim involving alleged infringement of Third Party rights by Genentech’s activities under this Agreement at its own expense and by counsel of its own choice, and Curis shall have the right but not the obligation, at its own expense, to be represented in any such action by counsel of its own choice. If Genentech fails to proceed in a timely fashion with regard to such defense, Curis shall have the right but not the obligation to control any such defense of such claim at its own expense and by counsel of its own choice, and Genentech shall have the right but not the obligation, at its own expense, to be represented in any such action by counsel of its own choice. Curis shall have the first right but not the obligation to control any defense of any such claim involving alleged infringement of Third Party rights by Curis’ activities under this Agreement at its own expense and by counsel of its own choice, and Genentech shall have the right but not the obligation, at its own expense, to be represented in any such action by counsel of its own choice. If Curis fails to proceed in a timely fashion with regard to such defense, Genentech shall have the right but not the obligation to control any such defense of such claim at its own expense and by counsel of its own choice, and Curis shall have the right but not the obligation, at its own expense, to be represented in any such action by counsel of its own choice. Neither Party shall have the right to settle any infringement action under this Section 10.5 in a manner that diminishes the rights or interests of the other Party hereunder without the consent of such Party.
Defense of Third Party Claims An Indemnified Party shall give prompt written notice to VTDC or the Partnership, as applicable (the “Indemnifying Party”), of the commencement or assertion of any Claim by a third party (collectively, a “third-party action”) in respect of which such Indemnified Party seeks indemnification hereunder. Any failure so to notify the Indemnifying Party shall not relieve the Indemnifying Party from any liability that it, he, or she may have to such Indemnified Party under this Article VII unless the failure to give such notice materially and adversely prejudices the Indemnifying Party. The Indemnifying Party shall have the right to assume control of the defense of, settle, or otherwise dispose of such third-party action on such terms as it deems appropriate; provided, however, that:
(a) The Indemnified Party shall be entitled, at its own expense, to participate in the defense of such third-party action (provided, however, that the Indemnifying Party shall pay the attorneys’ fees of the Indemnified Party if (i) the employment of separate counsel shall have been authorized in writing by the Indemnifying Party in connection with the defense of such third-party action; (ii) the Indemnifying Party shall not have employed counsel reasonably satisfactory to the Indemnified Party to have charge of such third-party action; (iii) the Indemnified Party shall have reasonably concluded that there may be defenses available to such Indemnified Party that are different from or additional to those available to the Indemnifying Party; or (iv) the Indemnified Party’s counsel shall have advised the Indemnified Party in writing, with a copy delivered to the Indemnifying Party, that there is a material conflict of interest that could violate applicable standards of professional conduct to have common counsel);
(b) The Indemnifying Party shall obtain the prior written approval of the Indemnified Party before entering into or making any settlement, compromise, admission, or acknowledgment of the validity of such third-party action or any liability in respect thereof if, pursuant to or as a result of such settlement, compromise, admission, or acknowledgment, injunctive or other equitable relief would be imposed against the Indemnified Party or if, in the opinion of the Indemnified Party, such settlement, compromise, admission, or acknowledgment could have a Material Adverse Effect with respect to the Indemnified Party;
(c) The Indemnifying Party shall not consent to the entry of any judgment or enter into any settlement without the consent of the Indemnified Party that does not include as an unconditional term thereof the giving by each claimant or plaintiff to the Indemnified Party of a release from all liability in respect of such third-party action; and
(d) The Indemnifying Party shall not be entitled to control (but shall be entitled to participate at its own expense in the defense of), and the Indemnified Party shall be entitled to have sole control over, the defense or settlement, compromise, admission, or acknowledgment of any third-party action (i) as to which the Indemnifying Party fails to assume the defense within a reasonable length of time or (ii) to the extent the third-party action seeks an order, injunction, or other equitable relief against the Indemnified Party which, if successful, would materially adversely affect the business, operations, assets, or financial condition of the Indemnified Party; provided, however, that the Indemnified Party shall make no settlement, compromise, admission, or acknowledgment that would give rise to liability on the part of any Indemnifying Party without the prior written consent of such Indemnifying Party. The Parties shall extend reasonable cooperation in connection with the defense of any third-party action pursuant to this Article VII and, in connection therewith, shall furnish such records, information, and testimony and attend such conferences, discovery proceedings, hearings, trials, and appeals as may be reasonably requested.
