Sole Source as Grounds for Rejection of a Change Order If a Change Order is submitted to Contractor for the purposes of adding a Bulletin to this Contract and said Bulletin designates a Sole Source from which Contractor is required to procure goods or services necessary to perform the Work, which Sole Source has not been designated previously, Contractor shall be entitled to reject the proposed Change Order if the designated Sole Source refuses to provide to Contractor the warranties, bonds, terms or schedule required under the Contract Documents, including any warranty or terms or schedule required by Bulletins referenced in the proposed Change Order. In such event, Contractor shall give written notice to the Owner rejecting the proposed Change Order and, if possible, shall accompany said written notice with a proposal from Contractor for changes or modifications to the Bulletin so as to eliminate the Sole Source designation but to achieve goods or services equal in quality or function. The Owner may then require the Design Professional to revise the subject Bulletin so as to eliminate the designation of the Sole Source by incorporation of Contractor's proposal or otherwise. Upon revision of the Bulletin by the Design Professional and approval thereof by the Owner, the Owner shall again submit to the Contractor a proposed Change Order for the purpose of adding the revised Bulletin to this Contract. If the Owner decides to retain the Sole Source in the Change Order and Contractor cannot acquire the full contractually required warranties from the Sole Source, Contractor shall be held only to the warranty terms and schedule obtainable from the Sole Source.
Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.
NOTICE OF SUPPLEMENTAL ALLOCATION OF FUNDS By the signature below, the City Controller certifies that, upon the request of the Director, the supplemental sum set out below has been allocated for the purposes of the Agreement out of funds appropriated for this purpose by the City Council of the City of Houston. This Supplemental Allocation has been charged to such appropriation. $
Cost of Additional Review The Design Professional shall be responsible for an initial and one subsequent review of the Submittal. Where the subsequent Submittal is not accepted due to noncompliance with the Contract Documents, the Contractor shall be responsible for payment for the additional time required by the Design Professional to complete the Submittal review.
Certificate of Adjustment The Corporation shall from time to time immediately after the occurrence of any event which requires an adjustment or readjustment as provided in Section 4.1, deliver a certificate of the Corporation to the Warrant Agent specifying the nature of the event requiring the same and the amount of the adjustment or readjustment necessitated thereby and setting forth in reasonable detail the method of calculation and the facts upon which such calculation is based, which certificate shall be supported by a certificate of the Corporation’s Auditors verifying such calculation. The Warrant Agent shall rely, and shall be protected in so doing, upon the certificate of the Corporation or of the Corporation’s Auditor and any other document filed by the Corporation pursuant to this Article 4 for all purposes.
Funding Adjustments Funding Adjustments may be made for the following reasons and in the following manner:
DATA FOR CALCULATIONS The initial calculations for any payments owing under this Agreement shall be based upon the valuations placed upon the Qualified Property by the Appraisal District in its annual certified appraisal roll submitted to the District pursuant to § 26.01 of the TEXAS TAX CODE in or about July of each year of this Agreement. The certified appraisal roll data shall form the basis from which any and all amounts due under this Agreement are calculated, and the data utilized by the Consultant will be adjusted as necessary to reflect any subsequent adjustments by the Appraisal District to the District’s appraisal roll. Any estimates used by the Consultant to make calculations as required by this Agreement shall be based on the best and most current information available. The Consultant shall from time to time adjust the data utilized to reflect actual amounts, subsequent adjustments by the Appraisal District to the District’s certified appraisal roll, or any other relevant changes to material items such as student counts or tax collections.
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
Payment of Additional Costs If termination of this contract is due to the failure of the Engineer to fulfill its contract obligations, the State may take over the project and prosecute the work to completion, and the Engineer shall be liable to the State for any additional cost to the State.
Equitable Adjustment Trading volume amounts, price/volume amounts and similar figures in the Transaction Documents shall be equitably adjusted (but without duplication) to offset the effect of stock splits, similar events and as otherwise described in this Agreement and Warrants.
