LANCASTER COUNTY, NEBRASKA Contract Approved as to Form:
SCOPE OF ARCHITECT’S BASIC SERVICES 3.1 The Architect’s Basic Services consist of those described in this Article 3 and include usual and customary structural, mechanical, and electrical engineering services. Services not set forth in this Article 3 are Supplemental or Additional Services.
§ 3.1.1 The Architect shall manage the Architect’s services, research applicable design criteria, attend Project meetings, communicate with members of the Project team, and report progress to the Owner.
§ 3.1.2 The Architect shall coordinate its services with those services provided by the Owner and the Owner’s consultants. The Architect shall be entitled to rely on, and shall not be responsible for, the accuracy, completeness, and timeliness of, services and information furnished by the Owner and the Owner’s consultants. The Architect shall provide prompt written notice to the Owner if the Architect becomes aware of any error, omission, or inconsistency in such services or information.
§ 3.1.3 As soon as practicable after the date of this Agreement, the Architect shall submit for the Owner’s approval a schedule for the performance of the Architect’s services. The schedule initially shall include anticipated dates for the commencement of construction and for Substantial Completion of the Work as set forth in the Initial Information. The schedule shall include allowances for periods of time required for the Owner’s review, for the performance of the Owner’s consultants, and for approval of submissions by authorities having jurisdiction over the Project. Once approved by the Owner, time limits established by the schedule shall not, except for reasonable cause, be exceeded by the Architect or Owner. With the Owner’s approval, the Architect shall adjust the schedule, if necessary, as the Project proceeds until the commencement of construction.
§ 3.1.4 The Architect shall not be responsible for an Owner’s directive or substitution, or for the Owner’s acceptance of non-conforming Work, made or given without the Architect’s written approval.
§ 3.1.5 The Architect shall contact governmental authorities required to approve the Construction Documents and entities providing utility services to the Project. The Architect shall respond to applicable design requirements imposed by those authorities and entities.
§ 3.1.6 The Architect shall assist the Owner in connection with the Owner’s responsibility for filing documents required for the approval of governmental authorities having jurisdiction over the Project.
PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:
SEC Filings and the Xxxxxxxx-Xxxxx Act (a) As of the date hereof, the Company has Made Available to Parent complete and correct copies of (i) the Company’s annual report on Form 10-K for its fiscal year ended December 31, 2019, (ii) its proxy or information statements relating to meetings of the stockholders of the Company since January 1, 2018 and (iii) all of its other Company SEC Documents.
(b) Since January 1, 2018 through the date hereof, the Company has timely filed with the SEC (subject to extensions pursuant to Exchange Act Rule 12b-25) each report (including each report on Forms 8-K, 10-Q and 10-K), statement (including proxy statement), schedule, exhibit, form or other document or filing required by Applicable Law to be filed by the Company at or prior to the time so required, including all certificates required pursuant to the Xxxxxxxx-Xxxxx Act. No Subsidiary of the Company is required to file or furnish any report, statement, schedule, exhibit, form, certificate or other document with the SEC.
(c) As of its filing date (or, if amended or superseded by a filing prior to the date hereof, on the date of such filing), each Company SEC Document complied as to form in all material respects with the applicable requirements of the Securities Act, the Exchange Act and the Xxxxxxxx-Xxxxx Act and all other Applicable Law.
(d) As of its filing date (or, if amended or superseded by a filing prior to the date hereof, on the date of such filing), no Company SEC Document filed pursuant to the Exchange Act contained any untrue statement of a material fact or omitted to state any material fact necessary in order to make the statements made therein, in light of the circumstances under which they were made, not misleading. No Company SEC Document that is a registration statement, as amended or supplemented, if applicable, filed pursuant to the Securities Act, as of the date such registration statement or amendment became effective, contained any untrue statement of a material fact or omitted to state any material fact required to be stated therein or necessary to make the statements therein not misleading.
(e) The Company has Made Available to Parent correct and complete copies of all comment letters received by the Company from the SEC relating to the Company SEC Documents since January 1, 2019, together with all written responses of the Company thereto. Since the date of the Company’s annual report on Form 10-K for its fiscal year ended December 31, 2019 and as of the date hereof, (i) there are no outstanding or unresolved comments received by the Company from the SEC that would be required to be disclosed under Item 1B of Form 10-K under the Exchange Act, and (ii) to the Knowledge of the Company, none of the Company SEC Documents is the subject of any ongoing investigation by the SEC.
(f) Each required form, report and document containing financial statements that has been filed with or furnished to the SEC by the Company since January 1, 2018 through the date hereof was accompanied by the certifications required to be filed or submitted by the Company’s principal executive officer and principal financial officer, as applicable, pursuant to the Xxxxxxxx-Xxxxx Act and, at the time of filing or submission of each such certification, such certification was true and accurate and complied with the Xxxxxxxx-Xxxxx Act. For purposes of this Section 4.07, “principal executive officer” and “principal financial officer” shall have the meanings given to such terms in the Xxxxxxxx-Xxxxx Act. Neither the Company, any current executive officer nor, to the Knowledge of the Company, any former executive officer of the Company, has received written notice from any Governmental Authority challenging or questioning the accuracy, completeness, form or manner of filing of such certifications made with respect to the Company SEC Documents filed prior to the date hereof. Neither the Company nor any of its Subsidiaries has outstanding (nor has arranged or modified since the enactment of the Xxxxxxxx-Xxxxx Act) any “extensions of credit” (within the meaning of Section 402 of the Xxxxxxxx-Xxxxx Act) to directors or executive officers (as defined in Rule 3b-7 under the Exchange Act) of the Company or any of its Subsidiaries. The Company is otherwise in compliance with all applicable provisions of the Xxxxxxxx-Xxxxx Act and the applicable listing and corporate governance rules of Nasdaq, in each case in all material respects.
WASHINGTON’S STATEWIDE PAYEE DESK Contractor represents and warrants that Contractor is registered with Washington’s Statewide Payee Desk, which registration is a condition to payment.
Joint Funded Project with the Ohio Department of Transportation In the event that the Recipient does not have contracting authority over project engineering, construction, or right-of-way, the Recipient and the OPWC hereby assign certain responsibilities to the Ohio Department of Transportation, an authorized representative of the State of Ohio. Notwithstanding Sections 4, 6(a), 6(b), 6(c), and 7 of the Project Agreement, Recipient hereby acknowledges that upon notification by the Ohio Department of Transportation, all payments for eligible project costs will be disbursed by the Grantor directly to the Ohio Department of Transportation. A Memorandum of Funds issued by the Ohio Department of Transportation shall be used to certify the estimated project costs. Upon receipt of a Memorandum of Funds from the Ohio Department of Transportation, the OPWC shall transfer funds directly to the Ohio Department of Transportation via an Intra- State Transfer Voucher. The amount or amounts transferred shall be determined by applying the Participation Percentages defined in Appendix D to those eligible project costs within the Memorandum of Funds. In the event that the Project Scope is for right-of-way only, notwithstanding Appendix D, the OPWC shall pay for 100% of the right-of-way costs not to exceed the total financial assistance provided in Appendix C.
Settlement of Disputes between the Contracting Parties 1. Disputes between the Contracting Parties concerning the interpretation or application of this Agreement should, if possible, be settled through diplomatic channels.
2. If a dispute between the contracting Parties cannot thus be settled, it shall upon the request of either Contracting Party be submitted to an arbitral tribunal.
3. Such as arbitral tribunal shall be constituted for each individual case in the following way. Within two months of the receipt of the request for arbitration, each Contracting Party shall appoint one member of the tribunal. Those two members shall then select a national of a third State who an approval by the two Contracting Parties shall be appointed Chairman of the tribunal. The Chairman shall be appointed within two months from the date of appointment of the other two members.
4. If within the periods specified in paragraph 3 of this Article the necessary appointments have not been made either Contracting Party may, in the absence of any other agreement, invite the President of the International Court of Justice to make any necessary appointments. If the President is a national of either Contracting Party or if he is otherwise prevented from discharging the said function, the Vice-President shall be invited to make the necessary appointments. If the vice- President is a national of either Contracting Party or if he too is prevented form discharging the said function, the members of the International Court of Justice next in seniority who is not a national of either Contracting Party Shall be invited to make the necessary appointments.
5. The arbitral tribunal shall reach its decision by a majority of votes. Such decision shall be binding on both Contracting Parties. Each Contracting Party shall bear the cost of its own member of the tribunal and of its representation in the arbitral proceedings; the cost of the Chairman and the remaining cost shall be borne in equal parts by the Contracting Parties. The tribunal may, however, in its decision direct that a higher proportion of costs shall be borne by one of the two Contracting Parties, and this award shall be binding on both Contracting Parties. The tribunal shall determine its won procedure.
Professional Engineering and Architect’s Services Professional Engineering and Architect’s Services are not permitted to be provided under this Agreement. Texas statutes prohibit the procurement of Professional Engineering and Architect’s Services through a cooperative agreement.
Perth-Huron The Employer recognizes the Union as the bargaining agent of all Registered Nurses, and Nurses with a Temporary Certificate of Registration employed in a nursing capacity by the VON Canada – Ontario Branch Perth-Huron Site in the City of Stratford and at the satellite office located in Listowel, Ontario (285 Xxxxx Avenue North), save and except Supervisors and persons above the rank of Supervisor.
Disputes between the Contracting Parties (1) Disputes between the Contracting Parties concerning the interpretation or application of this I Agreement should, as far as possible, be settled through negotiation.
(2) If a dispute between the Contracting Parties cannot thus be settled within six months from the ist time the dispute arose, it shall upon the request of either Contracting Party be submitted to an arbitral tribunal.
(3) Such an arbitral tribunal shall be constituted for each individual case in the following way. by Within two months of the receipt of the request for arbitration, each Contracting Party shall appoint one its member of the tribunal. Those two members shall then select a national of a third State who on approval by the two Contracting Parties shall be appointed Chairman of the tribunal. The Chairman shall be appointed within two months from the date of appointment of the other two members.
(4) If within the periods specified in paragraph (3) of this Article the necessary appointments have in not been made, either Contracting Party may, in the absence of any other agreement, invite the President of the International Court of Justice to make any necessary appointments. If the President is a national of either Contracting Party or if he is otherwise prevented from discharging the said function, the Vice President shall be invited to make the necessary appointments. If the Vice President is a national of either Contracting Party or if he too is prevented from discharging the said function, the Member of the International Court of Justice next in seniority who is not a national of either Contracting Party shall be invited to make the necessary appointments.
(5) The arbitral tribunal shall reach its decision by a majority of votes. Such decisions shall be binding on both Contracting Parties. Each Contracting Party shall bear the cost of its own member of the tribunal and of its representation in the arbitral proceedings; the cost of the Chairman and the remaining costs shall be borne in equal parts by the Contracting Parties. The tribunal may, however, in its decision direct that a higher proportion of costs shall be borne by one of the two Contracting Parties, and this award shall be binding on both Contracting Parties. The tribunal shall determine its own procedures.
