Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
REMEDIES AND DAMAGES Section 17.1. (A) If there shall occur any Event of Default, and this Lease and the Term shall expire and come to an end as provided in Article 16 hereof:
INDEMNIFICATION AND PAYMENT OF DAMAGES BY BUYER Buyer will indemnify and hold harmless Sellers, and will pay to Sellers the amount of any Damages arising, directly or indirectly, from or in connection with (a) any Breach of any representation or warranty made by Buyer in this Agreement or in any certificate delivered by Buyer pursuant to this Agreement, (b) any Breach by Buyer of any covenant or obligation of Buyer in this Agreement, or (c) any claim by any Person for brokerage or finder's fees or commissions or similar payments based upon any agreement or understanding alleged to have been made by such Person with Buyer (or any Person acting on its behalf) in connection with any of the Contemplated Transactions.
Payment of Damages The indemnification required hereunder shall be made by periodic payments of the amount thereof during the course of the investigation or defense, within 10 days as and when reasonably specific bills are received or loss, liability, claim, damage or expense is incurred and reasonable evidence thereof is delivered. In calculating any amount to be paid by an indemnifying party by reason of the provisions of this Agreement, the amount shall be reduced by all tax benefits and other reimbursements (including, without limitation, insurance proceeds) credited to or received by the other party related to the Damages.
Indemnification by Buyer Subject to the other terms and conditions of this Article VIII, Buyer shall indemnify and defend each of Seller and its Affiliates and their respective Representatives (collectively, the “Seller Indemnitees”) against, and shall hold each of them harmless from and against, and shall pay and reimburse each of them for, any and all Losses incurred or sustained by, or imposed upon, the Seller Indemnitees based upon, arising out of, with respect to or by reason of:
Indemnification for Attorneys’ Fees (a) The Employer shall indemnify, hold harmless and defend the Executive against reasonable costs, including legal fees and expenses, incurred by him in connection with or arising out of any action, suit or proceeding in which he may be involved, as a result of his efforts, in good faith, to defend or enforce the terms of this Agreement. For purposes of this Agreement, any settlement agreement which provides for payment of any amounts in settlement of the Employer’s obligations hereunder shall be conclusive evidence of the Executive’s entitlement to indemnification hereunder, and any such indemnification payments shall be in addition to amounts payable pursuant to such settlement agreement, unless such settlement agreement expressly provides otherwise.
Indemnification By You 7.1.1 You agree to indemnify and hold harmless the Underwriter, the Trust and each of its Trustees, officers, employees and agents and each person, if any, who controls the Trust within the meaning of Section 15 of the 1933 Act (collectively, the "Indemnified Parties" and individually the "Indemnified Party" for purposes of this Section 7) against any and all losses, claims, damages, liabilities (including amounts paid in settlement with your written consent, which consent shall not be unreasonably withheld) or expenses (including the reasonable costs of investigating or defending any alleged loss, claim, damage, liability or expense and reasonable legal counsel fees incurred in connection therewith) (collectively, "Losses"), to which the Indemnified Parties may become subject under any statute or regulation, or at common law or otherwise, insofar as such Losses are related to the sale or acquisition of shares of the Trust or the Contracts and
