Payment Delay Notwithstanding any other terms of this Agreement, no payments will be made to CONTRACTOR until COUNTY is satisfied that work of such value has been rendered pursuant to this Agreement. However, COUNTY will not unreasonably withhold payment and, if a dispute exists, the withheld payment shall be proportional only to the item in dispute.
Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement:
Concurrent Delay When the completion of the Work is simultaneously delayed by an excusable delay and a delay arising from a cause not designated as excusable, Contractor may not be entitled to a time extension for the period of concurrent delay.
PERSONAL SATISFACTION AS A CONDITION PRECEDENT The obligations of County as provided in this Agreement are expressly conditioned upon Contractor’s compliance with the provisions of this Agreement to the personal satisfaction of the County. County shall determine compliance in good faith as a reasonable person would under the circumstances.
Excuse from Performance The Parties shall be excused from performing their respective obligations hereunder if they are prevented from so performing by reason of floods, earthquakes, other acts of nature, war, civil insurrection, riots, acts of any government (including judicial action), and other similar catastrophic events which are beyond the control of and not the fault of the Party claiming excuse from performance hereunder. Labor unrest, including but not limited to strike, work stoppage or slowdown, sick-out, picketing, or other concerted job action conducted by Contractor's employees or directed at Contractor is not an excuse from performance and Contractor shall be obligated to continue to provide service notwithstanding the occurrence of any or all of such events. The Party claiming excuse from performance shall, within two (2) Business Days after such Party has notice of such cause, give the other Party notice of the facts constituting such cause and asserting its claim to excuse under this Section. If either Party validly exercises its rights under this Section, the Parties hereby waive any claim against each other for any damages sustained thereby. The partial or complete interruption or discontinuance of Contractor's services caused by one or more of the events described in this Section shall not constitute a default by Contractor under this Agreement. Notwithstanding the foregoing, however, if Contractor is excused from performing its obligations hereunder for any of the causes listed in this Section for a period of thirty (30) calendar days or more, the SCWMA shall nevertheless have the right, in its sole discretion, to terminate this Agreement by giving ten (10) calendar days notice to Contractor unless Contractor has demonstrated, by the thirtieth (30th) calendar day, to the satisfaction of the SCWMA that the Contractor will resume services no later than the sixtieth (60th) day following the date service was interrupted or discontinued by Contractor.
CONDITIONS OF SETTLEMENT, EFFECT OF DISAPPROVAL, CANCELLATION OR TERMINATION 9.1 The Effective Date of this Settlement Agreement shall not occur unless and until each of the following events occurs and shall be the date upon which the last (in time) of the following events occurs:
Termination Due To Lack Of Funding Appropriation If, in the judgment of the Director of Accounts and Reports, Department of Administration, sufficient funds are not appropriated to continue the function performed in this agreement and for the payment of the charges hereunder, State may terminate this agreement at the end of its current fiscal year. State agrees to give written notice of termination to contractor at least 30 days prior to the end of its current fiscal year, and shall give such notice for a greater period prior to the end of such fiscal year as may be provided in this contract, except that such notice shall not be required prior to 90 days before the end of such fiscal year. Contractor shall have the right, at the end of such fiscal year, to take possession of any equipment provided State under the contract. State will pay to the contractor all regular contractual payments incurred through the end of such fiscal year, plus contractual charges incidental to the return of any such equipment. Upon termination of the agreement by State, title to any such equipment shall revert to contractor at the end of the State's current fiscal year. The termination of the contract pursuant to this paragraph shall not cause any penalty to be charged to the agency or the contractor.
LIABILITY FOR FAILURE TO COMPLETE TRANSACTIONS If We do not properly complete a transaction to or from Your Account according to this Agreement, We will be liable for Your losses or damages. However, We will not be liable if: (a) Your Account does not contain enough available funds to make the transaction through no fault of Ours; (b) the ATM where You are making the transfer does not have enough cash; (c) the terminal was not working properly and You knew about the breakdown when You started the transaction; (d) circumstances beyond Our control prevent the transaction despite reasonable precautions that We have taken; (e) Your Card is retrieved or retained by an ATM;
Performance Delay Time is of the essence in the Vendor’s performance of this Agreement. If at any time it appears to Vendor that it may not meet any of the performance schedules or the scheduled completion date of the services to be performed for any reason, including labor disputes, Vendor shall immediately by verbal means (to be confirmed in writing) notify Customer of the reasons for and the estimated duration of such delay. If requested by Customer, Vendor shall make every effort to avoid or minimize the delay to the maximum extent possible including the expenditure of premium time. Any additional cost caused by these requirements of Customer shall be borne by Vendor, unless the delay in performance arises out of causes beyond the control and without the fault or negligence of Vendor or its subcontractors within the meaning of the Cancellation- Default clause herein. The foregoing requirements are in addition to any of Customer’s other rights and remedies as may be provided by law or this Agreement.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
