Concealed or Unknown Conditions If the Contractor encounters conditions at the site that are (1) subsurface or otherwise concealed physical conditions that differ materially from those indicated in the Contract Documents or (2) unknown physical conditions of an unusual nature, that differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, the Contractor shall promptly provide notice to the Owner and the Architect before conditions are disturbed and in no event later than twenty-one (21) calendar days after first observance of the conditions. The Owner will promptly investigate such conditions and, if the Owner determines that they differ materially and cause an increase or decrease in the Contractor’s cost of, or time required for, performance of any part of the Work, will authorize an equitable adjustment in the Contract Sum or Contract Time, or both. If the Owner determines that the conditions at the site are not materially different from those indicated in the Contract Documents and that no change in the terms of the Contract is justified, the Owner shall promptly notify the Contractor in writing, stating the reasons. If the Contractor disputes the Owner’s determination, the Contractor party may assert a Claim as provided in Article 15.
No Liability Bank shall not be responsible or liable for any shortage or discrepancy in, damage to, or loss or destruction of, any goods, the sale or other disposition of which gives rise to an Account, or for any error, act, omission, or delay of any kind occurring in the settlement, failure to settle, collection or failure to collect any Account, or for settling any Account in good faith for less than the full amount thereof, nor shall Bank be deemed to be responsible for any of Borrower’s obligations under any contract or agreement giving rise to an Account. Nothing herein shall, however, relieve Bank from liability for its own gross negligence or willful misconduct.
No Additional Releases This Agreement is intended to be for the benefit of the Parties only, and by this instrument the Parties do not release any claims against or by any other person or entity.
Environmental Releases Each Party shall notify the other Parties, first orally and then in writing, of the release of any hazardous substances, any asbestos or lead abatement activities, or any type of remediation activities related to the Small Generating Facility or the Interconnection Facilities, each of which may reasonably be expected to affect the other Parties. The notifying Party shall: (1) provide the notice as soon as practicable, provided such Party makes a good faith effort to provide the notice no later than 24 hours after such Party becomes aware of the occurrence, and (2) promptly furnish to the other Parties copies of any publicly available reports filed with any governmental authorities addressing such events.
Plaintiff’s Release Plaintiff and his or her respective former and present spouses, representatives, agents, attorneys, heirs, administrators, successors, and assigns generally, release and discharge Released Parties from all claims, transactions, or occurrences that occurred during the Class Period, including, but not limited to: (a) all claims that were, or reasonably could have been, alleged, based on the facts contained, in the Operative Complaint and (b) all PAGA claims that were, or reasonably could have been, alleged based on facts contained in the Operative Complaint, Plaintiff’s PAGA Notice, or ascertained during the Action and released under 6.2, below. (“Plaintiff’s Release.”) Plaintiff’s Release does not extend to any claims or actions to enforce this Agreement, or to any claims for vested benefits, unemployment benefits, disability benefits, social security benefits, workers’ compensation benefits that arose at any time, or based on occurrences outside the Class Period. Plaintiff acknowledges that Plaintiff may discover facts or law different from, or in addition to, the facts or law that Plaintiff now knows or believes to be true but agrees, nonetheless, that Plaintiff’s Release shall be and remain effective in all respects, notwithstanding such different or additional facts or Plaintiff’s discovery of them.
