WAIVERS OF CONSEQUENTIAL DAMAGES Sample Clauses

WAIVERS OF CONSEQUENTIAL DAMAGES. NEITHER THE PLEDGOR, THE AGENT OR ANY LENDER, NOR ANY EMPLOYEE, AGENT OR ATTORNEY OF ANY OF THEM, SHALL BE LIABLE TO THE OTHER FOR CONSEQUENTIAL DAMAGES ARISING FROM ANY BREACH OF CONTRACT, TORT OR OTHER WRONG RELATING TO THIS AGREEMENT OR THE ESTABLISHMENT, ADMINISTRATION OR COLLECTION OF THE OBLIGATIONS, EXCEPT FOR BAD FAITH.
AutoNDA by SimpleDocs
WAIVERS OF CONSEQUENTIAL DAMAGES. 5.4.1 To the extent the Owner-Contractor Agreement provides for a waiver of consequential damages by the Contractor, the Subcontractor waives claims against the Contractor for consequential damages arising out of or relating to this Agreement. To the extent the Owner-Contractor Agreement provides for a waiver of consequential damages by the Owner, the Contractor waives claims against the Subcontractor for consequential damages arising out of or relating to this Agreement. The Subcontractor shall obtain from its sub- subcontractor(s) waivers of consequential damages that correspond to the Subcontractor’s waiver of consequential damages herein. Except as provided in Section 10.1.2, this waiver applies to consequential damages due to termination by the Contractor or the Owner in accordance with this Agreement or the Owner-Contractor Agreement. To the extent the Owner-Contractor Agreement does not preclude the award of liquidated damages, nothing contained in this Paragraph 5.4 shall preclude the imposition of such damages, if applicable in accordance with the requirements of the Subcontract Documents. 5.4.2 To the extent the Owner-Contractor Agreement provides for waivers of consequential damages between the Owner and the Contractor, damages for which the Contractor is liable to the Owner including those related to Subparagraph 9. 1.1 are not consequential damages for the purpose of this waiver. Similarly, to the extent the Subcontractor-Sub-Subcontractor Agreement provides for waivers of consequential damages between the Owner and the Contractor, damages for which the Subcontractor is liable to lower-tiered parties due to the fault of the Owner or Contractor are not consequential damages for the purpose of this waiver.

Related to WAIVERS OF CONSEQUENTIAL DAMAGES

  • Waiver of Consequential Damages To the fullest extent permitted by applicable Law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document, the Related Documents or any agreement or instrument contemplated hereby or thereby, the transactions contemplated hereby or thereby, any Term Loan or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents, the Related Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

  • Disclaimer of Consequential Damages Notwithstanding any provision to the contrary, in no event shall any Party be liable to another Party for any incidental, consequential, special, exemplary or indirect damages, lost business profits or lost data arising out of or in any way related to the Contract Documents.

  • Exclusion of Consequential Damages ‌ Notwithstanding anything contained herein to the contrary, neither Party will be liable under this Agreement or under any cause of action relating to the subject matter of this Agreement for any special, indirect, incidental, punitive, exemplary or consequential damages, including loss of profits, loss of use of any property or claims of customers or contractors of the Parties for any such damages.

  • Limitation of Consequential Damages EXCEPT FOR (A) THIRD PARTY CLAIMS THAT ARE SUBJECT TO INDEMNIFICATION UNDER THIS ARTICLE 10, (B) CLAIMS ARISING OUT OF A PARTY’S WILLFUL MISCONDUCT OR FRAUD UNDER THIS AGREEMENT, (C) A PARTY’S BREACH OF ARTICLE 4, (D) NOVARTIS’ BREACH OF SECTION 6.5, OR (E) CLAIMS ARISING OUT OF A PARTY’S BREACH OF ITS CONFIDENTIALITY OBLIGATIONS UNDER THIS AGREEMENT, NEITHER PARTY NOR ANY OF ITS AFFILIATES WILL BE LIABLE TO THE OTHER PARTY TO THIS AGREEMENT OR ITS AFFILIATES FOR ANY INCIDENTAL, CONSEQUENTIAL, SPECIAL, PUNITIVE OR OTHER INDIRECT DAMAGES OR LOST OR IMPUTED PROFITS OR ROYALTIES, LOST DATA OR COST OF PROCUREMENT OF SUBSTITUTE GOODS OR SERVICES, WHETHER LIABILITY IS ASSERTED IN CONTRACT, TORT (INCLUDING NEGLIGENCE AND STRICT PRODUCT LIABILITY), INDEMNITY OR CONTRIBUTION, AND IRRESPECTIVE OF WHETHER THAT PARTY OR ANY REPRESENTATIVE OF THAT PARTY HAS BEEN ADVISED OF, OR OTHERWISE MIGHT HAVE ANTICIPATED THE POSSIBILITY OF, ANY SUCH LOSS OR DAMAGE.

  • Waiver of Consequential Damages, Etc To the fullest extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document or any agreement or instrument contemplated hereby, the transactions contemplated hereby or thereby, any Loan or Letter of Credit or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed to such unintended recipients by such Indemnitee through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

  • No Consequential Damages Other than the Liquidated Damages heretofore described and the indemnity obligations set forth in Article 18.1, in no event shall any Party be liable under any provision of this Agreement for any losses, damages, costs or expenses for any special, indirect, incidental, consequential, or punitive damages, including but not limited to loss of profit or revenue, loss of the use of equipment, cost of capital, cost of temporary equipment or services, whether based in whole or in part in contract, in tort, including negligence, strict liability, or any other theory of liability; provided, however, that damages for which a Party may be liable to another Party under separate agreement will not be considered to be special, indirect, incidental, or consequential damages hereunder.

  • Limitation on Consequential Damages NEITHER PARTY WILL HAVE ANY OBLIGATION OR LIABILITY (WHETHER IN CONTRACT, WARRANTY, TORT (INCLUDING NEGLIGENCE) OR OTHERWISE, AND NOTWITHSTANDING ANY FAULT, NEGLIGENCE (WHETHER ACTIVE, PASSIVE OR IMPUTED), REPRESENTATION, STRICT LIABILITY OR PRODUCT LIABILITY), FOR COVER OR FOR ANY INCIDENTAL, INDIRECT, CONSEQUENTIAL, MULTIPLIED, PUNITIVE, SPECIAL, OR EXEMPLARY DAMAGES OR LOSS OF REVENUE, PROFIT, SAVINGS OR BUSINESS ARISING FROM OR OTHERWISE RELATED TO THIS AGREEMENT, EVEN IF A PARTY OR ITS REPRESENTATIVES HAVE BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. THE PARTIES ACKNOWLEDGE THAT THESE EXCLUSIONS OF POTENTIAL DAMAGES WERE AN ESSENTIAL ELEMENT IN SETTING CONSIDERATION UNDER THIS AGREEMENT.

  • Consequential Damages Neither party to this Agreement shall be liable to the other party for special, indirect or consequential damages under any provision of this Agreement or for any special, indirect or consequential damages arising out of any act or failure to act hereunder.

  • Claims for Consequential Damages The Owner retains its right to claim for consequential damages in the event the Design Professional fails to perform under this Contract.

  • Consequential Damages Waiver NEITHER PARTY SHALL HAVE ANY LIABILITY ARISING OUT OF OR RELATED TO THIS AGREEMENT FOR ANY LOSS OF USE, LOST DATA, LOST PROFITS, FAILURE OF SECURITY MECHANISMS, INTERRUPTION OF BUSINESS, LOSS CAUSED BY THE INTERRUPTION, TERMINATION OR DELAYED OPERATION OF THE INTERNET, THIRD-PARTY TELECOMMUNICATION SERVICES OR THIRD-PARTY SECURITY FEATURES OR SYSTEMS, EXCEPT AS REQUIRED BY LAW. EXCEPT FOR CUSTOMER’S BREACH OF SECTION 1.4 (USE RESTRICTIONS) OR EITHER PARTY’S UNLAWFUL OR WILLFUL MISCONDUCT OR GROSS NEGLIGENCE, NEITHER PARTY SHALL BE LIABLE FOR ANY INDIRECT, SPECIAL, INCIDENTAL, EXEMPLARY, PUNITIVE, RELIANCE, OR CONSEQUENTIAL DAMAGES OF ANY KIND, EVEN IF INFORMED OF THE POSSIBILITY IN ADVANCE, SUFFERED BY ANY PARTY OR ANY PARTY CLAIMING ON BEHALF OF OR THROUGH THE OTHER PARTY, OR ANY OTHER THIRD PARTY RESULTING FROM OR ARISING OUT OF OR RELATED TO THIS AGREEMENT OR THE PERFORMANCE OR BREACH THEREOF.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!