Warranty Claim Article 2 Sample Clauses

Open Split View

Download

Share

Cite

Warranty Claim Article 2 

Sample 1

Save

Copy

Related to Warranty Claim Article 2

• Warranty Claims 8.1 The Supplier shall be obliged to inspect the quantity and the quality of the goods before delivery. 8.2 We shall have no duty to inspect the goods nor to notify any detected defects within a specific time period. In any event, a warranty claim will be timely made if raised prior to the expiration of the warranty period set forth in sub- clause 8.7 hereof. 8.3 We are entitled to demand, at our discretion, that the Supplier either replace defective goods or remedy the defect. The Supplier may only refuse the form of supplementary performance we have chosen on the grounds of dispropor- tionate cost where such costs would exceed the value of the goods in defect-free condition. 8.4 The Supplier warrants that the supplied goods are free of any fault or defect, whether of design, workmanship or materials. 8.5 Where supplementary performance fails, we are entitled to withdraw from the contract according to applicable law. Supplementary performance shall be deemed to have failed after one unsuccessful attempt, provided that the type of product or defect does not indicate that we are required to accept a further attempt at supplementary perfor- xxxxx. 8.6 We are entitled to remedy defects ourselves or to have them remedied at the expense of the Supplier, or to under- take shortfall purchases, where exigency or particular urgency applies and it is no longer possible to notify the Sup- plier with a deadline because of such particular urgency. 8.7 The Supplier shall be liable for any breach of the warranties if, within 18 months after the delivery date, we give no- xxxx in writing to the Supplier of any defect in the goods which shall arise from faulty design, materials or xxxxxxx- ship. This warranty period starts upon delivery of the goods and shall be suspended while the Supplier attempts supplementary performance. With respect to replaced or repaired goods, a new warranty period shall commence upon delivery of the replaced or repaired goods. 8.8 We expressly reserve the right to claim damages under applicable law. Warranty disclaimers and/or limitations of li- ability on the part of the Supplier do not apply. The foregoing warranties shall be without prejudice to any other rights and remedies available to us. 8.9 The Supplier indemnifies and holds us harmless against third party claims in connection with defective, delayed or in other manners faulty delivery, including court and attorney fees.

• Indemnification Procedure for Third Party Claims (a) In the event that any party (the “Indemnified Person”) desires to make a claim against any other party (the “Indemnifying Person”) in connection with any Losses for which the Indemnified Person may seek indemnification hereunder in respect of a claim or demand made by any Person not a party to this Agreement against the Indemnified Person (a “Third-Party Claim”), such Indemnified Person must notify the Indemnifying Person in writing, of the Third-Party Claim (a “Third-Party Claim Notice”) as promptly as reasonably possible after receipt, but in no event later than fifteen (15) calendar days after receipt, by such Indemnified Person of notice of the Third-Party Claim; provided, that failure to give a Third-Party Claim Notice on a timely basis shall not affect the indemnification provided hereunder except to the extent the Indemnifying Person shall have been actually and materially prejudiced as a result of such failure. Upon receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall be entitled, at the Indemnifying Person’s election, to assume or participate in the defense of any Third-Party Claim at the cost of Indemnifying Person. In any case in which the Indemnifying Person assumes the defense of the Third-Party Claim, the Indemnifying Person shall give the Indemnified Person ten (10) calendar days’ notice prior to executing any settlement agreement and the Indemnified Person shall have the right to approve or reject the settlement and related expenses; provided, however, that upon rejection of any settlement and related expenses, the Indemnified Person shall assume control of the defense of such Third-Party Claim and the liability of the Indemnifying Person with respect to such Third-Party Claim shall be limited to the amount or the monetary equivalent of the rejected settlement and related expenses. (b) The Indemnified Person shall retain the right to employ its own counsel and to discuss matters with the Indemnifying Person related to the defense of any Third-Party Claim, the defense of which has been assumed by the Indemnifying Person pursuant to Section 10.3(a) of this Agreement, but the Indemnified Person shall bear and shall be solely responsible for its own costs and expenses in connection with such participation; provided, however, that, subject to Section 10.3(a) above, all decisions of the Indemnifying Person shall be final and the Indemnified Person shall cooperate with the Indemnifying Person in all respects in the defense of the Third-Party Claim, including refraining from taking any position adverse to the Indemnifying Person. (c) If the Indemnifying Person fails to give notice of the assumption of the defense of any Third-Party Claim within a reasonable time period not to exceed forty-five (45) days after receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall no longer be entitled to assume (but shall continue to be entitled to participate in) such defense. The Indemnified Person may, at its option, continue to defend such Third-Party Claim and, in such event, the Indemnifying Person shall indemnify the Indemnified Person for all reasonable fees and expenses in connection therewith (provided it is a Third-Party Claim for which the Indemnifying Person is otherwise obligated to provide indemnification hereunder). The Indemnifying Person shall be entitled to participate at its own expense and with its own counsel in the defense of any Third-Party Claim the defense of which it does not assume. Prior to effectuating any settlement of such Third-Party Claim, the Indemnified Person shall furnish the Indemnifying Person with written notice of any proposed settlement in sufficient time to allow the Indemnifying Person to act thereon. Within fifteen (15) days after the giving of such notice, the Indemnified Person shall be permitted to effect such settlement unless the Indemnifying Person (a) reimburses the Indemnified Person in accordance with the terms of this Article 10 for all reasonable fees and expenses incurred by the Indemnified Person in connection with such Claim; (b) assumes the defense of such Third-Party Claim; and (c) takes such other actions as the Indemnified Person may reasonably request as assurance of the Indemnifying Person’s ability to fulfill its obligations under this Article 10 in connection with such Third-Party Claim.

• Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.

• Claim Procedure Any Person entitled to indemnification hereunder shall (i) give prompt written notice to the indemnifying party of any claim with respect to which it seeks indemnification (provided that the failure to give prompt notice shall impair any Person’s right to indemnification hereunder only to the extent such failure has prejudiced the indemnifying party) and (ii) unless in such indemnified party’s reasonable judgment a conflict of interest between such indemnified and indemnifying parties may exist with respect to such claim, permit such indemnifying party to assume the defense of such claim with counsel reasonably satisfactory to the indemnified party. If such defense is assumed, the indemnifying party shall not be subject to any liability for any settlement made by the indemnified party without its consent (but such consent shall not be unreasonably withheld, conditioned or delayed). An indemnifying party who is not entitled to, or elects not to, assume the defense of a claim shall not be obligated to pay the fees and expenses of more than one counsel for all parties indemnified by such indemnifying party with respect to such claim, unless in the reasonable judgment of any indemnified party a conflict of interest may exist between such indemnified party and any other of such indemnified parties with respect to such claim. In such instance, the conflicted indemnified parties shall have a right to retain one separate counsel, chosen by the Holders representing a majority of the Registrable Securities included in the registration if such Holders are indemnified parties, at the expense of the indemnifying party.

• Product Liability Claims As soon as it becomes aware, each party will give the other prompt written notice of any defect or alleged defect in a Product, any injury alleged to have occurred as a result of the use or application of a Product, and any circumstances that may give rise to litigation or recall of a Product or regulatory action that may affect the sale or manufacture of a Product, specifying, to the extent the party has such information, the time, place and circumstances thereof and the names and addresses of the persons involved. Each party will also furnish promptly to the other copies of all papers received in respect of any claim, action or suit arising out of such alleged defect, injury or regulatory action.

• Maintenance of PMI Policy; Claims With respect to each Mortgage Loan with a loan-to-value ratio in excess of 80% for which a PMI Policy is both required and has been issued, the Servicer shall, to the extent permitted by Accepted Servicing Practices, maintain or cause the Mortgagor to maintain in full force and effect a PMI Policy insuring that portion of the Mortgage Loan in excess of 75% of value, and shall cause the Mortgagor to pay the premium thereon on a timely basis, until the loan-to-value ratio of such Mortgage Loan is reduced to 80% or PMI can otherwise no longer be mandated pursuant to applicable law. In the event that such PMI Policy shall be terminated, the Servicer shall attempt to obtain from another Qualified Insurer a comparable replacement policy, with a total coverage equal to the remaining coverage of such terminated PMI Policy. The Servicer shall not take any action which would result in noncoverage under any applicable PMI Policy of any loss which, but for the actions of the Servicer would have been covered thereunder. In connection with any assumption or substitution agreement entered into or to be entered into pursuant to this Agreement, the Servicer shall promptly notify the insurer under the related PMI Policy, if any, of such assumption or substitution of liability in accordance with the terms of such PMI Policy and shall take all actions which may be required by such insurer as a condition to the continuation of coverage under such PMI Policy. If such PMI Policy is terminated as a result of such assumption or substitution of liability, the Servicer shall obtain a replacement PMI Policy as provided above. With respect to each Mortgage Loan covered by a PMI Policy or LPMI Policy, the Servicer shall take all such actions on behalf of the Owner as are necessary to service, maintain and administer the related Mortgage Loan in accordance with such Policy and to enforce the rights under such Policy. Except as expressly set forth herein, the Servicer shall have full authority on behalf of the Owner to do anything it deems appropriate or desirable in connection with the servicing, maintenance and administration of such Policy; provided that the Servicer shall not take any action to permit any modification or assumption of a Mortgage Loan covered by a LPMI or PMI Policy, or take any other action with respect to such Mortgage Loan, which would result in non-coverage under such Policy of any loss which, but for actions of the Servicer, would have been covered thereunder. The Servicer shall cooperate with the PMI insurers and shall furnish all reasonable evidence and information in the possession of the Servicer to which the Servicer has access with respect to the related Mortgage Loan. The Servicer agrees to prepare and present, on behalf of itself and the Owner, claims to the insurer under any PMI Policy or LPMI Policy in a timely fashion in accordance with the terms of such PMI Policy or LPMI Policy and, in this regard, to take such action as shall be necessary to permit recovery under any PMI Policy or LPMI Policy respecting a defaulted Mortgage Loan. Pursuant to Section 3.04, any amounts collected by the Servicer under any PMI Policy or LPMI Policy shall be deposited in the Collection Account, subject to withdrawal pursuant to Section 3.05.

• Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).

• NOTICE OF INDEMNIFICATION CLAIMS If the Town seeks indemnification pursuant to this Article 13.2, it shall notify Competitive Supplier of the existence of a claim, or potential claim as soon as practicable after learning of such claim, or potential claim, describing with reasonable particularity the circumstances giving rise to such claim. Upon written acknowledgment by the Competitive Supplier that it will assume the defense and indemnification of such claim, the Competitive Supplier may assert any defenses which are or would otherwise be available to the Town.

• Warranty Exclusions The Limited Warranty in clauses 1.2 and 1.3 does not apply: a) if the Product was not purchased and installed in Australia; b) if You do not grant BYD or BYD Partner access to the performance data of the Product over the Internet upon request after reporting the warranty claim and/or manipulate such data; c) to wear and tear in the appearance of the Product (including but not limited to any scratches, stains, mechanical wear, rust or mould) which does not impair its function; d) to any damage to property or personal injury arising from any defect if the state of scientific and technical knowledge at the time when the Product is sold to Original Buyer was not such as to enable the defect to be discovered; e) if the invoice for the Product and the information listed in clause 4 below is not provided with the warranty claim; or f) if the serial number on the Product can no longer be identified or has been modified.

• Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.] 19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor: 12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. 12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University. 12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,