Warranty Period Except as may be otherwise specified or agreed, Contractor shall repair all defects in materials, equipment, or workmanship appearing within one year from the date of Substantial Completion of the Work. If Substantial Completion occurs by phase, then the warranty period for that the Work performed for each phase begins on the date of Substantial Completion of that phase, or as otherwise stipulated on the Certificate of Substantial Completion for the particular phase.
Unpaid Claims If a claim for indemnification (following the final disposition of such action, suit or proceeding) or advancement of expenses under this Section 10.02 is not paid in full within thirty (30) days after a written claim therefor by any person described in Section 10.02(a) has been received by the Partnership, such person may file proceedings to recover the unpaid amount of such claim and, if successful in whole or in part, shall be entitled to be paid the expense of prosecuting such claim. In any such action the Partnership shall have the burden of proving that such person is not entitled to the requested indemnification or advancement of expenses under applicable Law.
Product Claims You acknowledge that Company, not an App Distributor, is responsible for addressing any claims of yours or any third party relating to the Company application or your possession and/or use of the Company application, including, but not limited to: (i) product liability claims; (ii) any claim that the Company application fails to conform to any applicable legal or regulatory requirement; and (iii) claims arising under consumer protection or similar legislation. (5)
Product Warranty and Product Liability Schedule 5.17 of the Disclosure Schedule contains a true, correct and complete copy of Company's standard warranty or warranties for sales of Products (as defined below) and, except as stated therein, there are no warranties, commitments or obligations with respect to the return, repair or replacement of Products. Schedule 5.17 of the Disclosure Schedule contains a description of all product liability claims and similar claims, actions, litigation and other proceedings relating to Products which are presently pending or which to Company's knowledge are threatened, or which have been asserted or commenced against Company within the last two (2) years, in which a party thereto either requests injunctive relief (whether temporary or permanent) or alleges damages in excess of $100,000.00 (whether or not covered by insurance). To the best of the Company's knowledge, there are no defects in design, construction or manufacture of Products which would adversely affect performance or create an unusual risk of injury to persons or property. Except as set forth on Schedule 5.17, none of the Products has been the subject of any replacement, field fix, retrofit, modification or recall campaign other than in the ordinary course of business. The Products have been designed and manufactured so as to meet and comply with all governmental standards and specifications currently in effect, and have received all governmental approvals necessary to allow their sale and use. As used herein, the term "Products" means any and all products currently or at any time previously manufactured, distributed or sold by Company, or by any predecessor of Company under any brand name or xxxx under which products are or have been manufactured over the last three (3) years, distributed or sold by Company, in or through the Business.
Product Warranty; Product Liability (a) Except as set forth on Company Disclosure Schedule 4.23, the products produced, sold or delivered by the Company in conducting the Business have been in all material respects in conformity with all product specifications and all applicable Laws. To the Company’s Knowledge, the Company has no material Liability for damages in connection therewith or any other customer or product obligations not reserved against on the Balance Sheet.
Warranty Claims This Contractual Warranty is provided by Xxxxxxxxx Electric and covers defects in workmanship and materials in your Product. This warranty period lasts from the date of purchase at the point of sale to you, the original end user, unless otherwise agreed in writing (the "Warranty Period"). This Contractual Warranty is transferable to subsequent owners but only for the unexpired portion of the Warranty Period.
Product Warranty Seller provides general warranties of fitness and general warranties that the goods are free from defects, for 1 year from acceptance of the goods, except as may otherwise be set forth in the Description/Proposal, or other attached warranty.
Product Warranties Except as set forth in Schedule 3.15, (a) there are no warranties express or implied, written or oral, with respect to the Business and (b) there are no pending or threatened claims with respect to any such warranty, and Seller has no liability with respect to any such warranty, whether known or unknown, absolute, accrued, contingent or otherwise and whether due or to become due.
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
Forecasts and Purchase Orders On or before the twelfth (12th) day of each month, beginning on January 12, 2022, Indivior shall furnish to Curia a written twelve (12) month rolling forecast of the quantities of Product that Indivior intends to order from Curia during such period ("Rolling Forecast"). The first six (6) months of such Rolling Forecast shall constitute a firm and binding commitment to order quantities of Product specified therein ("Firm Period Forecast"), and the following six (6) months of the Rolling Forecast shall be non-binding, good faith estimates. Each month of the Rolling Forecast shall begin on the twelfth (12th) of the calendar month in which such Rolling Forecast is submitted and end on the eleventh (11th) day of the following calendar month. With exception to the Firm Period Forecast, Curia reserves the right to reject any Rolling Forecast that does not align with the physical Processing capabilities of the Facility(ies) and the parties shall work in good faith to adjust the Rolling Forecast based on available resources, Facility capacity and other relevant factors. Indivior shall have the right to request an increase of the Firm Period Forecast to include additional units of Product. Curia may, in its sole discretion, supply such additional quantities, subject to Curia's other supply commitments and manufacturing capacity. In the event Curia agrees to supply such additional quantities, Indivior shall submit a Purchase Order for such additional quantities, with the required lead times as specified below. In no event shall Curia's inability to fulfill Purchase Orders for quantities in excess of the Firm Period Forecast be deemed a breach of this Agreement, nor relieve Indivior of its obligations under this Agreement. Indivior shall submit with each Rolling Forecast, a non-cancelable Purchase Order for the Firm Period Forecast (or such portion of the Firm Period Forecast not covered by previously submitted Purchase Orders). Indivior may alternatively submit Purchase Orders for certain portions of the Firm Period Forecast subsequent to the submission of the Rolling Forecast, provided the Purchase Orders provide the required lead time for Processing as set forth below. Curia shall notify Indivior of acceptance of the Rolling Forecast and any Purchase Order within seven (7) business days of receipt. Curia shall be deemed to have accepted Purchase Orders which it does not acknowledge within seven (7) business days of receipt. Curia shall have the right to reject Rolling Forecasts and Purchase Orders that are inconsistent with this Agreement. Each Purchase Order shall specify the quantity of Product being ordered, and the desired delivery date. Upon mutual agreement in writing for additional quantities of Product beyond the Firm Period Forecast, including projected delivery date(s), Indivior shall issue the applicable Purchase Order to be accepted by Curia as described above. Once placed, all Purchase Orders for Product shall be non-cancelable. No different or additional terms or conditions set forth in any Purchase Order shall modify in any way the terms and conditions of this Agreement, and in the event of a conflict between terms in any Purchase Order and this Agreement, the terms of this Agreement shall control. All Purchase Orders submitted in accordance with the terms of this Agreement shall be effective and binding on the parties upon acceptance by Curia. Except as otherwise provided herein, neither party shall have the right or power to refuse, reduce, or otherwise modify their obligations under any Purchase Order; however, Purchase Orders may be amended (i) upon written mutual agreement regarding such modification that is signed by both parties; or (ii) as otherwise provided in this Section 4.3 or Section 4.4.
