WARRANTY TERMS AND CONDITIONS. The following terms and conditions (the “Warranty Terms and Conditions”) apply to the warranty made by Milliken & Company (“Milliken”) for Milliken TractionBack® for use with modular carpet. These Warranty Terms and Conditions and related warranty do not apply to non-commercial installations. The warranty provided herein is in lieu of any and all other warranties, express or implied, including but not limited to implied warranties of merchantability and fitness for a particular purpose. The warranty is subject to the limitations and exclusions set forth in these Warranty Terms and Conditions and in the individual warranty. The warranty only applies to use of the Milliken TractionBack® product in carpet installations when bond testing, substrate preparation, perimeter adhesive application and carpet installation have all been performed in accordance with the requirements and instructions set forth on the product specification sheet and Xxxxxxxx’x then current published instructions for installation of modular carpet (which are specific for each carpet product), and the then current Carpet and Rug Institute publication CRI 104 (collectively, the “Documentation”). Furthermore, the carpet installation must be in an indoor commercial environment. The warranty shall not apply (i) to installations on substrates that were not prepared and tested, when applicable, as instructed in the Documentation; (ii) to substrates that are not free of silicate penetrating curing compounds and other topical or integral treatments that violate ASTM F710; (iii) to installations over substrates where hydrostatic pressure exists, or moisture readings are higher than specified for the product subject to such limitations; (iv) where the claimant does not have written and photographic documentation of the bond testing conducted prior to the installation, as well as moisture testing if applicable; (v) to installation failures due to outside sources of water, such as where outside grade is above substrate, moisture or ground water intrusion caused by faulty (or lack of) a vapor retarder under the concrete substrate slab per ASTM E1745, sprinklers soaking ground at the building foundation, overflow drains not directed away from the foundation, flooding or other natural disasters or weather conditions;
WARRANTY TERMS AND CONDITIONS. The Object of Purchase has defects if it or its part does not correspond to the result set forth in this Contract.
WARRANTY TERMS AND CONDITIONS. 1.1 The Seller guarantees sold goods against any manufacturing defects for twelve months from the purchasing date. This warranty only covers hardware product components and only applies to hardware products manufactured by or on behalf of the Seller and that can be identified through the mark, the trade name or the “Gilbarco” logo on them, or anyway equipped with the relevant sale invoice. The software (by the Seller or by third parties) is subject to licence contracts with the final user or to distinct warranty conditions.
1.2 Should any manufacturing defects be detected within the warranty period, the Seller or one of its authorised service shops shall repair/replace defective goods within the terms and under the conditions stated below, without any charge to the Buyer for the labour costs incurred to repair and/or replace the goods.
1.3 Replacement under warranty conditions shall only be performed if the defect is notified to the Seller within the warranty period. Procedures to request interventions under warranty conditions are subject to the following rules. In the event of an obvious defectiveness or incompleteness of the service or the supply, we are to be notified thereof in writing without delay, but at the latest within 8 days after receipt of the supply or service, and in the event of hidden deficiencies without delay but at the latest within two weeks after detection of the defect, including a precise description of the defect. At our request the defective goods are to be returned to us. Claims of the Customer on account of defectiveness or incompleteness of the delivery or service are excluded if it fails to comply with this obligation. Apart from that, German law sec. 377 HGB shall apply. Before requesting an intervention under warranty conditions the Seller encourages the user to thoroughly read the relevant operating instructions. This warranty shall not be applicable if the model indication or the serial number on the product have been modified, deleted, removed or made unreadable.
WARRANTY TERMS AND CONDITIONS. THE OBLIGATIONS OF WOODLINE SHADE SOLUTIONS HEREUNDER ARE LIMITED TO REPAIR OR REPLACEMENT OF PARTS OF THE PRODUCT FOUND TO BE DEFECTIVE UNDER THIS LIMITED WARRANTY. IN NO EVENT SHALL WOODLINE SHADE SOLUTIONS BE LIABLE FOR ANY INDIRECT, INCIDENTAL OR CONSEQUENTIAL DAMAGES, INCLUDING BUT NOT LIMITED TO TIME, WAGES OR LOST PROFITS, OF ANY NATURE OR KIND OR FOR DAMAGES TO OR LOSS OF PROPERTY. In addition, Woodline Shade Solutions reserves the right to modify, refine, or improve its products and parts including making substitutions, without incurring any responsibility to modify, exchange, replace or repair any parts or products to meet prior specifications.
WARRANTY TERMS AND CONDITIONS. 8.1 The Seller guarantees the sold goods against any manufacturing defects at the purchasing date. Seller guarantees its Products will be free from manufacturing defects during the Warranty Period. The definitions of the product and its specific Warranty Terms and Conditions shall be governed by the terms of Annex 1 of these General Sale Conditions
8.2 This warranty is exclusive and supersedes any other quality and performance warranties, whether written, verbal or implicit. Any other warranties, including any implied warranties of merchantability or fitness for purpose, are hereby specifically excluded by GVR to the extent legally possible.
WARRANTY TERMS AND CONDITIONS. 1.1 This Warranty is provided by Gilbarco Xxxxxx-Xxxx (hereinafter "GVR" or "Seller") and shall apply between GVR and a customer who has purchased a Product directly from GVR or from an authorized GVR sales partner.
1.2 This Warranty is limited to these terms and conditions. In addition, the products supplied are guaranteed to be compliant to the GVR specifications. In the event a authorized GVR sales partner provides a warranty that is more extensive that this Warranty, GVR shall not, under any circumstances, be liable for any rights, obligations, actions or omissions that are more extensive than provided under this Warranty or any features, defects, errors or failures not covered by this Warranty.
1.3 GVR warrants that its Products are free from defects in materials and workmanship under normal use for the Warranty period. GVR warrants that the products sold are compliant with the Laws, the Certifications and the Regulations of the countries where the product will be sell.
WARRANTY TERMS AND CONDITIONS. The following terms and conditions (the “Warranty Terms and Conditions”) apply to the warranty made by Milliken & Company (“Milliken”) for Milliken Moisture Extreme Spray Adhesive for use with modular carpet. These Warranty Terms and Conditions and related warranty do not apply to non-commercial installations. The warranty provided herein is in lieu of any and all other warranties, express or implied, including but not limited to implied warranties of merchantability and fitness for a particular purpose. This warranty is subject to the limitations and exclusions set forth in these Warranty Terms and Conditions and in the individual warranty. The warranty only applies to use of the Milliken Moisture Extreme Aerosol Adhesive product in carpet installations when bond testing, substrate preparation, adhesive application and carpet installation have all been performed in accordance with the requirements and instructions set forth on the product label, the product specification sheet, Xxxxxxxx’x then current published instructions for installation of modular carpet (which are specific for each carpet product), and the then current Carpet and Rug Institute publication CRI 104 (collectively, the “Documentation”). Furthermore, the carpet installation must be in an indoor commercial environment. The warranty shall not apply (i) to installations on substrates that were not prepared as instructed in the Documentation; (ii) to substrates that are not free of silicate penetrating curing compounds and other topical or integral treatments that violate ASTM F710;
WARRANTY TERMS AND CONDITIONS. The following terms and conditions (the “Warranty Terms and Conditions”) apply to the warranty made by Xxxxxxxx & Company (“Milliken”) for TractionBack® Plus. These Warranty Terms and Conditions and related warranty do not apply to non-commercial installations. The warranty provided herein is in lieu of any and all other warranties, express or implied, including but not limited to implied warranties of merchantability and fitness for a particular purpose. This warranty is subject to the limitations and exclusions set forth in these Warranty Terms and Conditions and in the individual warranty. The warranty only applies to use of TractionBack® Plus in installations when bond testing, substrate preparation, and carpet installation have all been performed in accordance with the product specification sheet, Xxxxxxxx’x then current published instructions for installation of modular carpet with TractionBack® Plus and the then current Carpet and Rug Institute publication CRI 104 (collectively, the “Documentation”). Furthermore, the carpet installation must be in an indoor commercial environment. The warranty shall not apply (i) to installations on substrates that were not prepared as instructed in the Documentation; (ii) to installations over substrates where hydrostatic pressure exists; (iii) to installation failures due to outside sources of water; (iv) to installations with chemically cleaned substrates, where improper cleaning methods have been used, or where adhesive removers have been applied;
WARRANTY TERMS AND CONDITIONS. PROBE CORPORATION undertakes, in its sole discretion to repair the defect, or replace the Battery at its own cost and without charge to the purchaser of the Battery, subject to the following conditions:-
WARRANTY TERMS AND CONDITIONS. 7.1 Standard Limited Warranty. PLISCH warrants that our products shall be free from material defect during the warranty period. Unless otherwise specified, the warranty period for our products shall be twenty-four (24) months from the date of shipment. In case of defect in our products during the warranty period, PLISCH, at its option, will either repair the defective product without charge for parts and labor at its factory, or provide a replacement in exchange for the defective products or parts.
