Termination for Cause with Notice to Cure Requirement Contractor may terminate this contract for the Department’s failure to perform any of its duties under this contract after giving the Department written notice of the failure. The written notice must demand performance of the stated failure within a specified period of time of not less than 30 days. If the demanded performance is not completed within the specified period, the termination is effective at the end of the specified period.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Termination for Force Majeure 15.5.1. The License Agreement may be terminated for Force Majeure Reasons as specified in Article -14.
Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement: a. At DSHS’s discretion, the Contract or Program Agreement may be renegotiated under the revised funding conditions. b. At DSHS’s discretion, DSHS may give notice to Contractor to suspend performance when DSHS determines that there is reasonable likelihood that the funding insufficiency may be resolved in a timeframe that would allow Contractor’s performance to be resumed prior to the normal completion date of this contract. (1) During the period of suspension of performance, each party will inform the other of any conditions that may reasonably affect the potential for resumption of performance. (2) When DSHS determines that the funding insufficiency is resolved, it will give Contractor written notice to resume performance. Upon the receipt of this notice, Contractor will provide written notice to DSHS informing DSHS whether it can resume performance and, if so, the date of resumption. For purposes of this subsubsection, “written notice” may include email. (3) If the Contractor’s proposed resumption date is not acceptable to DSHS and an acceptable date cannot be negotiated, DSHS may terminate the contract by giving written notice to Contractor. The parties agree that the Contract will be terminated retroactive to the date of the notice of suspension. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the retroactive date of termination. c. DSHS may immediately terminate this Contract by providing written notice to the Contractor. The termination shall be effective on the date specified in the termination notice. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the effective date of termination. No penalty shall accrue to DSHS in the event the termination option in this section is exercised.
Share Termination Delivery Property A number of Share Termination Delivery Units, as calculated by the Calculation Agent, equal to the Payment Obligation divided by the Share Termination Unit Price. The Calculation Agent shall adjust the Share Termination Delivery Property by replacing any fractional portion of a security therein with an amount of cash equal to the value of such fractional security based on the values used to calculate the Share Termination Unit Price.
TERMINATION FOR CAUSE BY CONTRACTOR 4.06.1 Contractor may terminate its performance under this Agreement only if the City defaults and fails to cure the default after receiving written notice of it. Default by the City occurs if the City fails to perform one or more of its material duties under this Agreement. If a default occurs and Contractor wishes to terminate the Agreement, then Contractor must deliver a written notice to the Director describing the default and the proposed termination date. The date must be at least 30 days after the Director receives the notice. Contractor, at its sole option, may extend the proposed termination date to a later date. If the City cures the default before the proposed termination date, then the proposed termination is ineffective. If the City does not cure the default before the proposed termination date, then Contractor may terminate its performance under this Agreement on the termination date
Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
