Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
Statutory Penalties The defendant understands that upon his plea of guilty to Count One of the indictment charging him with conspiracy, the maximum penalty the Court may impose is not more than five years of imprisonment, a $250,000.00 fine, three years of supervised release, an order of restitution, and a $100.00 mandatory special assessment which must be paid in full at the time of sentencing. The defendant further understands that this offense is a Class D felony.
Are There Penalties for Early Distribution from a Xxxx XXX As indicated above, earnings on your contributions, as well as amounts contributed to a Xxxx XXX as a rollover from a Traditional IRA, that are distributed before certain events are subject to various taxes. Please see IRS Publication 590 for further information about Xxxx XXX rules and restrictions.
How Are Contributions to a Xxxx XXX Reported for Federal Tax Purposes You must file Form 5329 with the IRS to report and remit any penalties or excise taxes. In addition, certain contribution and distribution information must be reported to the IRS on Form 8606 (as an attachment to your federal income tax return.)
Maximum Statutory Penalties 8. Defendant understands that the charge to which he is pleading guilty carries the following statutory penalties:
Violation; liability for unpaid wages; liquidated damages In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
How Are Contributions to a Xxxxxxxxx Education Savings Account Reported for Federal Tax Purposes? Contributions to a Xxxxxxxxx Education Savings Account are reported on IRS Form 5498-ESA.
How Are Distributions from a Xxxx XXX Taxed for Federal Income Tax Purposes Amounts distributed to you are generally excludable from your gross income if they (i) are paid after you attain age 59½, (ii) are made to your beneficiary after your death, (iii) are attributable to your becoming disabled, (iv) subject to various limits, the distribution is used to purchase a first home or, in limited cases, a second or subsequent home for you, your spouse, or you or your spouse’s grandchild or ancestor, or (v) are rolled over to another Xxxx XXX. Regardless of the foregoing, if you or your beneficiary receives a distribution within the five-taxable-year period starting with the beginning of the year to which your initial contribution to your Xxxx XXX applies, the earnings on your account are includable in taxable income. In addition, if you roll over (convert) funds to your Xxxx XXX from another individual retirement plan (such as a Traditional IRA or another Xxxx XXX into which amounts were rolled from a Traditional IRA), the portion of a distribution attributable to rolled-over amounts which exceeds the amounts taxed in connection with the conversion to a Xxxx XXX is includable in income (and subject to penalty tax) if it is distributed prior to the end of the five-tax-year period beginning with the start of the tax year during which the rollover occurred. An amount taxed in connection with a rollover is subject to a 10% penalty tax if it is distributed before the end of the five-tax-year period. As noted above, the five-year holding period requirement is measured from the beginning of the five-taxable-year period beginning with the first taxable year for which you (or your spouse) made a contribution to a Xxxx XXX on your behalf. Previously, the law required that a separate five-year holding period apply to regular Xxxx XXX contributions and to amounts contributed to a Xxxx XXX as a result of the rollover or conversion of a Traditional IRA. Even though the holding period requirement has been simplified, it may still be advisable to keep regular Xxxx XXX contributions and rollover/ conversion Xxxx XXX contributions in separate accounts. This is because amounts withdrawn from a rollover/conversion Xxxx XXX within five years of the rollover/conversion may be subject to a 10% penalty tax. As noted above, a distribution from a Xxxx XXX that complies with all of the distribution and holding period requirements is excludable from your gross income. If you receive a distribution from a Xxxx XXX that does not comply with these rules, the part of the distribution that constitutes a return of your contributions will not be included in your taxable income, and the portion that represents earnings will be includable in your income. For this purpose, certain ordering rules apply. Amounts distributed to you are treated as coming first from your non-deductible contributions. The next portion of a distribution is treated as coming from amounts which have been rolled over (converted) from any non-Xxxx IRAs in the order such amounts were rolled over. Any remaining amounts (including all earnings) are distributed last. Any portion of your distribution which does not meet the criteria for exclusion from gross income may also be subject to a 10% penalty tax. Note that to the extent a distribution would be taxable to you, neither you nor anyone else can qualify for capital gains treatment for amounts distributed from your account. Similarly, you are not entitled to the special five- or ten- year averaging rule for lump-sum distributions that may be available to persons receiving distributions from certain other types of retirement plans. Rather, the taxable portion of any distribution is taxed to you as ordinary income. Your Xxxx XXX is not subject to taxes on excess distributions or on excess amounts remaining in your account as of your date of death. You must indicate on your distribution request whether federal income taxes should be withheld on a distribution from a Xxxx XXX. If you do not make a withholding election, we will not withhold federal or state income tax. Note that, for federal tax purposes (for example, for purposes of applying the ordering rules described above), Xxxx IRAs are considered separately from Traditional IRAs.
PRESCRIPTION MEDICATION BENEFITS, LIMITATIONS AND EXCLUSIONS The following items are limited or excluded from your Prescription Medication coverage:
CFR PART 200 Domestic Preferences for Procurements As appropriate and to the extent consistent with law, the non-Federal entity should, to the greatest extent practicable under a Federal award, provide a preference for the purchase, acquisition, or use of goods, products, or materials produced in the United States (including but not limited to iron, aluminum, steel, cement, and other manufactured products). The requirements of this section must be included in all subawards including all contracts and purchase orders for work or products under this award. For purposes of 2 CFR Part 200.322, “Produced in the United States” means, for iron and steel products, that all manufacturing processes, from the initial melting stag through the application of coatings, occurred in the United States. Moreover, for purposes of 2 CFR Part 200.322, “Manufactured products” means items and construction materials composed in whole or in part of non-ferrous metals such as aluminum, plastics and polymer-based products such as polyvinyl chloride pipe, aggregates such as concrete, class, including optical fiber, and lumber. Pursuant to the above, when federal funds are expended by ESC Region 8 and TIPS Members, Vendor certifies that to the greatest extent practicable Vendor will provide a preference for the purchase, acquisition, or use of goods, products, or materials produced in the United States (including but not limited to iron, aluminum, steel, cement, and other manufactured products). Does vendor agree? Yes
