Without prejudice to Clause 16.1 the Employer shall:
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Without prejudice to Sections 5.1 and 5.2 above, You are responsible for (a) any required notices, consents and/or authorizations related to Your provision of, and our processing of, Your Content (including any Personal Data) as part of the Services, (b) any security vulnerabilities, and the consequences of such vulnerabilities, arising from Your Content, including any viruses, Trojan horses, worms or other harmful programming routines contained in Your Content, and (c) any use by You or Your Users of the Services in a manner that is inconsistent with the terms of this Agreement. To the extent You disclose or transmit Your Content to a third party, we are no longer responsible for the security, integrity or confidentiality of such content outside of Oracle’s control.
No Waiver of Sovereign Immunity or Powers Nothing in this agreement will be deemed to constitute a waiver of sovereign immunity or powers of licensee, the Xxxxxxxxxx County Commissioners Court, or the Xxxxxxxxxx County Judge.
Express Rights and Remedies Not Limited The express rights and remedies of the LHIN are in addition to and will not limit any other rights and remedies available to the LHIN at law or in equity. For further certainty, the LHIN has not waived any provision of any applicable statute, including LHSIA, nor the right to exercise its rights under these statutes at any time.
Buyer’s Rights and Remedies If at any time an Event of Default with respect to Seller has occurred and is continuing, then, unless the Seller has paid in full all of its obligations that are then due, including those under Section 7.2(c) of this Agreement (“Obligations”), the Buyer may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a Secured Party under applicable law with respect to posted Eligible Collateral held by the Buyer, (ii) the right to set-off any amounts payable by the Seller with respect to any Obligations against any posted Eligible Collateral or the Cash equivalent of any posted Eligible Collateral held by the Buyer, or (iii) the right to liquidate any posted Eligible Collateral held by the Buyer and to apply the proceeds of such liquidation of the posted Eligible Collateral to any amounts payable to the Buyer with respect to the Obligations in such order as the Buyer may elect. For purposes of this Paragraph 6, the Buyer may draw on the entire undrawn portion of any Letter of Credit. Cash proceeds that are not applied to the Obligations shall be maintained in accordance with the terms of this CSA. The Seller shall remain liable for amounts due and owing to the Secured Party that remain unpaid after the application, pursuant to this Paragraph 6, of Eligible Collateral to the Obligations.
No Waiver of Sovereign Immunity Nothing in the Contract will be construed as a waiver of the System Agency’s or the State’s sovereign immunity. This Contract shall not constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to the System Agency or the State of Texas. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to the System Agency or the State of Texas under the Contract or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. System Agency does not waive any privileges, rights, defenses, or immunities available to System Agency by entering into the Contract or by its conduct prior to or subsequent to entering into the Contract.
Waiver of Sovereign Immunity Each Loan Party that is incorporated outside the United States, in respect of itself, its Subsidiaries, its process agents, and its properties and revenues, hereby irrevocably agrees that, to the extent that such Loan Party or its respective Subsidiaries or any of its or its respective Subsidiaries’ properties has or may hereafter acquire any right of immunity, whether characterized as sovereign immunity or otherwise, from any legal proceedings, whether in the United States or elsewhere, to enforce or collect upon the Loans or any Loan Document or any other liability or obligation of such Loan Party or any of their respective Subsidiaries related to or arising from the transactions contemplated by any of the Loan Documents, including, without limitation, immunity from suit, immunity from service of process, immunity from jurisdiction or judgment of any court or tribunal, immunity from execution of a judgment, and immunity of any of its property from attachment prior to any entry of judgment, or from attachment in aid of execution upon a judgment, such Loan Party, for itself and on behalf of its Subsidiaries, hereby expressly waives, to the fullest extent permissible under applicable law, any such immunity, and agrees not to assert any such right or claim in any such proceeding, whether in the United States or elsewhere. Without limiting the generality of the foregoing, each Loan Party further agrees that the waivers set forth in this Section 10.25 shall have the fullest extent permitted under the Foreign Sovereign Immunities Act of 1976 of the United States and are intended to be irrevocable for purposes of such Act.
City’s Right to Suspend for Convenience City may suspend all or any portion of Contractor’s performance under this Contract at its sole option and for its convenience for a reasonable period of time not to exceed six (6) months. City must first give ten (10) days’ written notice to Contractor of such suspension. City will pay to Contractor a sum equivalent to the reasonable value of the goods and/or services satisfactorily provided up to the date of suspension. City may rescind the suspension prior to or at six (6) months by providing Contractor with written notice of the rescission, at which time Contractor would be required to resume performance in compliance with the terms and provisions of this Contract. Contractor will be entitled to an extension of time to complete performance under the Contract equal to the length of the suspension unless otherwise agreed to in writing by the Parties.
City’s Right to Terminate for Convenience City may, at its sole option and for its convenience, terminate all or any portion of this Contract by giving thirty (30) days’ written notice of such termination to Contractor. The termination of the Contract shall be effective upon receipt of the notice by Contractor. After termination of all or any portion of the Contract, Contractor shall: (1) immediately discontinue all affected performance (unless the notice directs otherwise); and (2) complete any and all additional work necessary for the orderly filing of documents and closing of Contractor's affected performance under the Contract. After filing of documents and completion of performance, Contractor shall deliver to City all data, drawings, specifications, reports, estimates, summaries, and such other information and materials created or received by Contractor in performing this Contract, whether completed or in process. By accepting payment for completion, filing, and delivering documents as called for in this section, Contractor discharges City of all of City’s payment obligations and liabilities under this Contract with regard to the affected performance.
