Xxxxxx by Xxxxx and Contractor’s Remedies Sample Clauses

Open Split View

Download

Share

Cite

Xxxxxx by Xxxxx and Contractor’s Remedies. Contractor’s remedies herein are in addition to all other legal remedies.

Sample 1Sample 2

Save

Copy

Related to Xxxxxx by Xxxxx and Contractor’s Remedies

• Contractor’s Remedies If the State is in breach of any provision of this Contract and does not cure such breach, Contractor, following the notice and cure period in §14.B and the dispute resolution process in §16 shall have all remedies available at law and equity. If a Purchasing Entity is in breach of a provision of an Order, Contractor shall have all remedies available to it under that Order and available at law and equity.

• Lessor’s Remedies In the event Lessee is in default pursuant to the conditions set forth in Section 15.01 above, Lessor, during the continuation of such default, shall have the option of pursuing either of the following remedies: (a) Lessor may terminate this Lease Agreement, in which event Lessee immediately shall surrender possession of the Demised Premises. All obligations of Lessee under the Lease Agreement, including Lessee’s obligation to pay rent under the Lease Agreement, shall cease upon the date of termination except for Lessee’s obligation to pay rent due and outstanding as of the date of termination. (b) Lessor, without terminating the Lease Agreement, may require Lessee to remove all property from the Common Improvements within thirty (30) days so that Lessor may re-enter and relet the premises to minimize Lessor’s damages. In the event Lessee shall fail to remove all property within thirty (30) days after said demand, Lessor shall be entitled to remove Lessee’s property to a storage facility, and all reasonable costs of such removal and storage shall be deemed additional rent under the Lease Agreement for which Lessee is responsible for payment. Lessor may enforce all of its rights and remedies under this Lease Agreement, including the right to recover the rent as it becomes due hereunder, provided that Lessor shall have an affirmative obligation to use Lessor’s best efforts to re-let the Common Improvements and to mitigate its damages under the Lease Agreement. (c) If this Lease Agreement is terminated as set forth, Lessor may relet the Common Improvements (or any portion thereof) for such rent and upon such terms as Lessor is able to obtain (which may be for lower or higher rent, and for a shorter or longer term), and Lessee shall be liable for all damages sustained by Lessor, including but not limited to any deficiency in Rent for the duration of the Lease Term (or for the period of time which would have remained in the Lease Term in the absence of any termination, leasing fees, attorneys’ fees, other marketing and collection costs and all expenses of placing the Common Improvements in first class rentable condition). (d) Nothing contained herein diminishes any right Lessor may have under South Carolina law to xxx Lessee for damages in the event of any default by Lessee under this Lease Agreement, or from pursuing any other remedy available to Lessor at law or in equity.

• Specific Remedies (a) During any period other than a Cash Dominion Trigger Period and subject to the terms of the Credit Agreement, the Administrative Agent hereby authorizes each Grantor to collect such Grantor’s Accounts in the Ordinary Course of Business. (b) During a Cash Dominion Trigger Period: (i) upon the request of the Administrative Agent, each Grantor shall notify (such notice to be in form and substance satisfactory to the Administrative Agent) its Account Debtors and parties to the Material Contracts subject to a Security Interest that such Accounts and the Material Contracts have been assigned to the Administrative Agent, for the ratable benefit of the Secured Parties; (ii) upon the request of the Administrative Agent, each Grantor shall forward to the Administrative Agent, on the last Business Day of each week, deposit slips related to all cash, money, checks or any other similar items of payment received by the Grantor during such week, and copies of such checks or any other similar items of payment, together with a statement showing the application of all payments on the Collateral during such week and a collection report with regard thereto, in form and substance satisfactory to the Administrative Agent; (iii) the Administrative Agent may deliver such notices and instructions in accordance with control agreements covering Deposit Accounts (other than Excluded Accounts) and/or Securities Accounts. In addition, whenever any Grantor shall receive any cash, money, checks or any other similar items of payment relating to any Collateral (including any Proceeds of any Collateral), subject to the terms of any Permitted Liens, such Grantor agrees that it will, within one (1) Business Day of such receipt, deposit all such items of payment into the Dominion Account, and until such Grantor shall deposit such cash, money, checks or any other similar items of payment in the Dominion Account, such Grantor shall hold such cash, money, checks or any other similar items of payment in trust for the Secured Parties and as property of the Secured Parties, separate from the other funds of such Grantor, and the Administrative Agent shall have the right to transfer or direct the transfer of the balance of each Deposit Account (other than an Excluded Deposit Account) to the Dominion Account. All such Collateral and Proceeds of Collateral received by the Administrative Agent hereunder shall be held by the Administrative Agent in the Dominion Account as collateral security for all the Secured Obligations and shall not constitute payment thereof until applied as provided in Section 5.4; (c) After the occurrence and during the continuance of an Event of Default: (i) the Administrative Agent shall have the right to receive any and all cash dividends, payments or distributions made in respect of any Investment Property, any Partnership/LLC Interests or any other Proceeds paid in respect of any Investment Property or any Partnership/LLC Interests, and any or all of any Investment Property that is included as Collateral or any Partnership/LLC Interests that are Pledged Capital Stock may, at the option of the Administrative Agent and the Secured Parties, be registered in the name of the Administrative Agent or its nominee, and the Administrative Agent or its nominee may thereafter exercise (A) all voting, corporate and other rights pertaining to such Investment Property, or such Partnership/LLC Interests at any meeting of shareholders, partners or members of the relevant Issuers or otherwise and (B) any and all rights of conversion, exchange and subscription and any other rights, privileges or options pertaining to such Investment Property or such Partnership/LLC Interests as if it were the absolute owner thereof (including, without limitation, the right to exchange at its discretion any and all Investment Property or any and all Partnership/LLC Interests issued upon the merger, consolidation, reorganization, recapitalization or other fundamental change in the corporate, partnership or limited liability company structure of any Issuer that is a Grantor (other than Imation) or a Pledged Foreign Subsidiary or upon the exercise by any Grantor or the Administrative Agent of any right, privilege or option pertaining to such Investment Property or such Partnership/LLC Interests, and in connection therewith, the right to deposit and deliver any and all of such Investment Property or any and all of such Partnership/LLC Interests with any committee, depositary, transfer agent, registrar or other designated agency upon such terms and conditions as the Administrative Agent may determine), all without liability except to account for property actually received by it; but the Administrative Agent shall have no duty to any Grantor to exercise any such right, privilege or option and the Administrative Agent and the other Secured Parties shall not be responsible for any failure to do so or delay in so doing. In furtherance thereof, each Grantor hereby authorizes and instructs each Issuer (i) that is a Grantor (other than Imation) or a Pledged Foreign Subsidiary with respect to any Collateral consisting of Investment Property and Partnership/LLC Interests of such Issuer to comply with any instruction received by it from the Administrative Agent in writing that (A) states that an Event of Default has occurred and is continuing and (B) is otherwise in accordance with the terms of this Agreement, without any other or further instructions from such Grantor, and each Grantor agrees that each Issuer shall be fully protected in so complying following receipt of such notice and prior to notice that such Event of Default is no longer continuing, and (ii) except as otherwise expressly permitted hereby and solely during a Cash Dominion Trigger Period, to pay any cash dividends, distributions or other payments with respect to any Investment Property, or Partnership/LLC Interests issued by such Issuer directly to the Dominion Account or such other Controlled Depositary as the Administrative Agent may direct; and (ii) the Administrative Agent shall be entitled to (but shall not be required to): (A) proceed to perform any and all obligations of the applicable Grantor under any Material Contract and exercise all rights of such Grantor thereunder as fully as such Grantor itself could, (B) do all other acts which the Administrative Agent may deem necessary or proper to protect its Security Interest granted hereunder, provided such acts are not inconsistent with or in violation of the terms of any of the Credit Agreement, of the other Loan Documents or applicable Law, and (C) sell, assign or otherwise transfer any Material Contract in accordance with the Credit Agreement, the other Loan Documents and applicable Law, subject, however, to the prior approval of each other party to such Material Contract, to the extent required under the Material Contract. (iii) The Administrative Agent is hereby granted an irrevocable, non-exclusive license or other right to use, license or sub-license (without payment of royalty or other compensation to any Person) of any or all Intellectual Property of each Grantor, computer hardware and software, trade secrets, brochures, customer lists, promotional and advertising materials, labels, packaging materials and other Property, in advertising for sale, marketing, selling, collecting, completing manufacture of, or otherwise exercising any rights or remedies with respect to, any Collateral; provided that the Administrative Agent shall not be entitled to exercise its rights under any such license, sub-license or right to use until such time as the Administrative Agent shall have received consent or direction from the Required Lenders pursuant to Section 8.02(d) of the Credit Agreement. (d) Unless an Event of Default shall have occurred and be continuing and the Administrative Agent shall have given notice to the relevant Grantor of the Administrative Agent’s intent to exercise its corresponding rights pursuant to Section 5.2(b), each Grantor shall be permitted to receive all cash dividends, payments or other distributions made in respect of any Investment Property and any Partnership/LLC Interests, in each case paid in the Ordinary Course of Business to the extent permitted in the Credit Agreement, and to exercise all voting and other corporate, company and partnership rights with respect to any Investment Property and Partnership/LLC Interests; provided that, no vote shall be cast or other corporate, company and partnership right exercised or other action taken which, in the Administrative Agent’s reasonable judgment, would impair the Collateral in any material respect or which would result in a Default or Event of Default under any provision of the Credit Agreement, this Agreement or any other Loan Document.

• Buyer’s Remedies If SELLER fails to perform its obligations pursuant to this Agreement for any reason except failure by BUYER to perform hereunder, or if prior to Closing any one or more of SELLER’s representations or warranties are breached in any material respect, BUYER shall elect, as its sole remedy (except as provided in this Section and Section 9), either to (i) terminate this Agreement by giving SELLER timely written notice of such election prior to or at Closing and recover the Deposit, (ii) solely enforce specific performance, or (iii) waive said failure or breach and proceed to Closing. Notwithstanding anything herein to the contrary, BUYER shall be deemed to have elected to terminate this Agreement if BUYER fails to deliver to SELLER written notice of its intent to file a claim or assert a cause of action for specific performance against SELLER on or before ten (10) business days following the scheduled Closing Date, or, having given such notice, fails to file a lawsuit asserting such claim or cause of action in the county in which the Property is located within two (2) months following the scheduled Closing Date. BUYER’s remedies shall be limited to those described in this Section hereof. IN NO EVENT SHALL SELLER’S DIRECT OR INDIRECT PARTNERS, SHAREHOLDERS, MEMBERS, MANAGERS, OWNERS OR AFFILIATES, ANY OFFICER, DIRECTOR, MEMBER, MANAGER OR EMPLOYEE OR AGENT OF THE FOREGOING, OR ANY AFFILIATE OR CONTROLLING PERSON THEREOF HAVE ANY LIABILITY FOR ANY CLAIM, CAUSE OF ACTION OR OTHER LIABILITY ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE PROPERTY, WHETHER BASED ON CONTRACT, COMMON LAW, STATUTE, EQUITY OR OTHERWISE.

• WAIVER AND CUMULATIVE REMEDIES No failure or delay by either party in exercising any right under this Agreement shall constitute a waiver of that right. Other than as expressly stated herein, the remedies provided herein are in addition to, and not exclusive of, any other remedies of a party at law or in equity.

• CUSTOMER REMEDIES 5.1. If the Supplier (a) fails to deliver the Goods and/or the Goods do not comply with any of the undertakings or warranties set out in clause 2 and/or (b) fails to deliver and/or perform the Services in accordance with any of the warranties or undertakings contained in clause 4 and/or by the applicable date(s), the Customer shall, without limiting or affecting other rights or remedies available to it, have one or more of the following rights to: 5.1.1. terminate the Agreement with immediate effect by giving written notice to the Supplier; 5.1.2. reject the Goods (in whole or in part) whether or not title has passed and to return them to the Supplier at the Supplier’s own risk and expense; 5.1.3. require the Supplier to repair or replace the rejected Goods, or to provide a full refund of the price of the rejected Goods; 5.1.4. require Supplier to re-perform, rectify or replace the affected Services and/or Deliverables; 5.1.5. refuse to accept any subsequent performance of the Services and/or delivery of the Goods which the Supplier attempts to make; 5.1.6. recover from the Supplier any costs incurred by the Customer in obtaining substitute goods and/or services from a third party; 5.1.7. require a refund from the Supplier of sums paid in advance for Services that the Supplier has not provided and/or Goods that it has not delivered; and 5.1.8. claim damages for any additional costs, loss or expenses incurred by the Customer which are in any way attributable to the Supplier’s breach. 5.2. Notwithstanding any other rights or remedies available to Customer if the Goods are not delivered by the applicable date, the Customer may, at its option, claim or deduct 3% of the price of the Goods for each week’s delay in delivery, up to a maximum of 15% of the total price of the Goods. In the event such delay continues for six (6) weeks or more, Customer may terminate the Agreement with immediate effect upon given Supplier written notice. 5.3. These Terms shall extend to any substituted or remedial services and/or repaired or replacement goods supplied by the Supplier. 5.4. The Customer’s rights under the Agreement are in addition to its rights and remedies implied by statute and common law.

• Specific Performance and Remedies Shareholder acknowledges that it will be impossible to measure in money the damage to Parent if Shareholder fails to comply with the obligations imposed by this Agreement and that, in the event of any such failure, Parent will not have an adequate remedy at law or in equity. Accordingly, Shareholder agrees that injunctive relief or other equitable remedy, in addition to remedies at law or in damages, is the appropriate remedy for any such failure and will not oppose the granting of such relief on the basis that Parent has an adequate remedy at law. Shareholder agrees that Shareholder will not seek, and agrees to waive any requirement for, the securing or posting of a bond in connection with Parent’s seeking or obtaining such equitable relief. In addition, after discussing the matter with Shareholder, Parent shall have the right to inform any third party that Parent reasonably believes to be, or to be contemplating, participating with Shareholder or receiving from Shareholder assistance in violation of this Agreement, of the terms of this Agreement and of the rights of Parent hereunder, and that participation by any such persons with Shareholder in activities in violation of Shareholder’s agreement with Parent set forth in this Agreement may give rise to claims by Parent against such third party.

• Seller’s Remedies If Purchaser fails to perform its obligations pursuant to this Contract at or prior to Closing for any reason except failure by Seller to perform hereunder, or if prior to Closing any one or more of Purchaser's representations or warranties are breached in any material respect, and this failure or breach is not cured within three (3) Business Days after written notice from Seller to Purchaser (other than failure to close for any reason unrelated to a default by Seller, for which there shall be no notice or cure period), then Seller, as its SOLE and EXCLUSIVE remedy (except as provided in Sections 6(c) and 9), may (i) terminate this Contract and receive the Xxxxxxx Money as liquidated damages and not as penalty, in full satisfaction of claims against Purchaser hereunder, or (ii) waive Purchaser’s failure or breach and proceed to Closing. Seller and Purchaser agree that Seller's damages resulting from Purchaser's default are difficult, if not impossible, to determine, and the Xxxxxxx Money is a fair estimate of those damages and has been agreed to in an effort to cause the amount of damages to be certain. Notwithstanding anything in this Section 11(a) to the contrary, in the event of Purchaser's default or termination of this Contract, Seller shall have all remedies available at law or in equity if Purchaser or any party related to or affiliated with Purchaser is asserting any claims or right to the Property that would otherwise delay or prevent Seller from having clear, indefeasible and marketable title to the Property other than as a result of Purchaser’s exercise of its remedies under subsection (b) hereof. If Closing is consummated, then Seller shall have all remedies available at law or in equity if Purchaser fails to perform any post-closing obligation of Purchaser under this Contract.

• Exclusive Remedies Subject to Section 9.12, the parties acknowledge and agree that their sole and exclusive remedy with respect to any and all claims (other than claims arising from intentional fraud on the part of a party hereto in connection with the transactions contemplated by this Agreement) for any breach of any representation, warranty, covenant, agreement or obligation set forth herein or otherwise relating to the subject matter of this Agreement, shall be pursuant to the indemnification provisions set forth in this ARTICLE VII. In furtherance of the foregoing, each party hereby waives, to the fullest extent permitted under the law, any and all rights, claims and causes of action for any breach of any representation, warranty, covenant, agreement or obligation set forth herein or otherwise relating to the subject matter of this Agreement it may have against the other parties hereto and their affiliates and each of their respective representatives arising under or based upon any law, rule or regulation, except pursuant to the indemnification provisions set forth in this ARTICLE VII. Nothing in this Section 7.05 shall limit any person’s right to seek and obtain any equitable relief to which any person shall be entitled pursuant to Section 9.12 or to seek any remedy on account of any intentional fraud by any party hereto.

• Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.